Energy Services of America CORP - Quarter Report: 2021 March (Form 10-Q)

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

FORM 10-Q

(Mark One)

x      Quarterly report pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934

For the quarterly period ended March 31, 2021.

Energy Services of America Corporation

(Exact Name of Registrant as Specified in Its Charter)

(304) 522-3868

(Registrant’s Telephone Number Including Area Code)

Securities Registered Pursuant to Section 12(b) of the Act:

Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports) and (2) has been subject to such requirements for the past 90 days. YES x NO ¨.

Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter period that the registrant was required to submit such files).      YES x NO ¨.

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definition of “large accelerated filer,” “accelerated filer”, “smaller reporting company”, or an “emerging growth company” in Rule 12b-2 of the Exchange Act. (Check one):

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act.      ¨

Indicate by check mark whether the Registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). YES ¨ NO x

As of May 11, 2021, there were 13,621,406 outstanding shares of the Registrant’s Common Stock.

Part 1. Financial Information

Item 1. Financial Statements (Unaudited):

Energy Services of America Corporation

Consolidated Balance Sheets

The Accompanying Notes are an Integral Part of These Financial Statements

Energy Services of America Corporation

Consolidated Statements of Income

Unaudited

The Accompanying Notes are an Integral Part of These Financial Statements

Energy Services of America Corporation

Consolidated Statements of Cash Flows

Unaudited

The Accompanying Notes are an Integral Part of These Financial Statements

Energy Services of America Corporation

Consolidated Statements of Changes in Shareholders’ Equity

For the six months ended March 31, 2021 and 2020

The Accompanying Notes are an Integral Part of These Financial Statements

ENERGY SERVICES OF AMERICA CORPORATION

NOTES TO UNAUDITED CONSOLIDATED FINANCIAL STATEMENTS

1. BUSINESS AND ORGANIZATION

Energy Services of America Corporation (“Energy Services” or the “Company”) is a contractor and service company that operates primarily in the mid-Atlantic region of the United States and provides services to customers in the natural gas, petroleum, water distribution, automotive, chemical and power industries. C.J. Hughes Construction Company, Inc. (“C.J. Hughes”), a wholly owned subsidiary of the Company, is a general contractor primarily engaged in pipeline construction for utility companies. Contractors Rental Corporation (“Contractors Rental”), a wholly owned subsidiary of C.J. Hughes, provides union building trade employees for projects managed by C.J. Hughes. Nitro Construction Services, Inc. (“Nitro”), a wholly owned subsidiary of C.J. Hughes, provides electrical, mechanical, HVAC/R and fire protection services to customers primarily in the automotive, chemical and power industries. Pinnacle Technical Solutions, Inc. (“Pinnacle”), a wholly owned subsidiary of Nitro, operates as a data storage facility within Nitro’s office building. Pinnacle is supported by Nitro and has no employees of its own. All C.J. Hughes, Nitro, and Contractors Rental construction personnel are union members of various related construction trade unions and are subject to collective bargaining agreements that expire at varying time intervals.

On December 31, 2020, Energy Services completed the purchase of West Virginia Pipeline, Inc. (“West Virginia Pipeline”), a West Virginia corporation located in Princeton, West Virginia. West Virginia Pipeline, a wholly owned subsidiary of Energy Services, operates as a gas and water distribution contractor primarily in southern West Virginia. West Virginia Pipeline’s employees are non-union, and the company is managed independently from C.J. Hughes and Nitro.

On March 22, 2021, the Company established a new wholly owned subsidiary, SQP Construction Group, Inc. (“SQP”), that will operate as a general contractor primarily in West Virginia, Ohio, and Kentucky. SQP will primarily engage in the construction and renovation of buildings and other civil construction projects. As a general contractor, SQP will manage the overall construction project and subcontract most of the work. SQP had not been awarded any projects as of March 31, 2021. The Company did not incur significant expenses in setting up the new subsidiary for the three and six months ended March 31, 2021.

The Company’s stock is quoted under the symbol “ESOA” on the OTC QB marketplace operated by the OTC Markets Group.

Interim Financial Statements

The accompanying unaudited consolidated financial statements have been prepared pursuant to the rules and regulations of the Securities and Exchange Commission (“SEC”) and should be read in conjunction with the Company’s audited consolidated financial statements and footnotes thereto for the years ended September 30, 2020 and 2019 included in the Company’s Annual Report on Form 10-K filed with the SEC on January 4, 2021. Certain information and footnote disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America have been omitted pursuant to the interim financial reporting rules and regulations of the SEC. The financial statements reflect all adjustments (consisting primarily of normal recurring adjustments) that are, in the opinion of management, necessary for a fair presentation of the Company’s financial position and results of operations. The operating results for the three and six months ended March 31, 2021 and 2020 are not necessarily indicative of the results to be expected for the full year or any other interim period.

Principles of Consolidation

The consolidated financial statements of Energy Services include the accounts of Energy Services, its wholly owned subsidiaries West Virginia Pipeline, SQP and C.J. Hughes and its subsidiaries, Contractors Rental, Nitro, and Pinnacle. All significant intercompany accounts and transactions have been eliminated in the consolidation. Unless the context requires otherwise, references to Energy Services include Energy Services, West Virginia Pipeline, SQP, and C.J. Hughes and its subsidiaries.

2. REVENUE RECOGNITION

Our revenue is primarily derived from construction contracts that can span several quarters. We recognize revenue in accordance with Accounting Standards Codification (“ASC”) Topic 606, Revenue from Contracts with Customers (“ASC 606” or “Topic 606”) which provides for a five-step model for recognizing revenue from contracts with customers as follows:

The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our estimates of the cost to complete each project. We believe our experience allows us to create materially reliable estimates. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include:

The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins may cause fluctuations in gross profit from period to period. Significant changes in cost estimates, particularly in our larger, more complex projects have had, and can in future periods have, a significant effect on our profitability.

Our contract assets may include cost and estimated earnings in excess of billings that represent amounts earned and reimbursable under contracts, including claim recovery estimates, but have a conditional right for billing and payment such as achievement of milestones or completion of the project. With the exception of customer affirmative claims, generally, such unbilled amounts will become billable according to the contract terms and generally will be billed and collected over the next three months. Settlement with the customer of outstanding affirmative claims is dependent on the claims resolution process and could extend beyond one year. Based on our historical experience, we generally consider the collection risk related to billable amounts to be low. When events or conditions indicate that it is probable that the amounts outstanding become unbillable, the transaction price and associated contract asset is reduced.

Our contract liabilities may consist of provisions for losses and billings in excess of costs and estimated earnings. Provisions for losses are recognized in the consolidated statements of income at the uncompleted performance obligation level for the amount of total estimated losses in the period that evidence indicates that the estimated total cost of a performance obligation exceeds its estimated total revenue. Billings in excess of costs and estimated earnings are billings to customers on contracts in advance of work performed, including advance payments negotiated as a contract condition. Generally, unearned project-related costs will be earned over the next twelve months.

3. DISAGGREGATION OF REVENUE

We disaggregate our revenue based on our operating groups and contract types as it is the format that is regularly reviewed by management. Our reportable operating groups are: Gas & Water Distribution, Gas & Petroleum Transmission, and Electrical & Mechanical services. The operating groups for the three and six months ended March 31, 2020 have been revised to reflect the current presentation. Our contract types are: Lump Sum, Unit Price, Cost Plus and Time and Materials (“T&M”). The following tables present our disaggregated revenue for the three and six months ended March 31, 2021 and 2020:

4. CONTRACT BALANCES

The Company’s accounts receivable consists of amounts that have been billed to customers. Collateral is generally not required. A majority of the Company’s contracts have monthly billing terms and payment terms within 30 to 45 days after invoices have been issued. The Company attempts to negotiate two-week billing terms and 15-day payment terms on larger projects. The timing of billings to customers may generate contract assets or contract liabilities.

During the six months ended March 31, 2021, we recognized revenue of $4.8 million that was included in the contract liability balance at September 30, 2020.

Accounts receivable-trade, net of allowance for doubtful accounts, retentions receivable, contract assets and contract liabilities consisted of the following:

5. PERFORMANCE OBLIGATIONS

The Company provides construction services that can be classified into several groups: Gas & Water Distribution, Gas & Petroleum Transmission, and Electrical & Mechanical services. Generally, our contracts contain one performance obligation that is satisfied over time because our performance typically creates or enhances an asset that the customer controls as the asset is created or enhanced. We recognize revenue as performance obligations are satisfied and control of the promised good and service is transferred to the customer. Revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward complete satisfaction of the performance obligation(s) using an input (i.e., “cost-to-cost”) method. Under the cost-to-cost method, costs incurred to-date are generally the best depiction of transfer of control. All contract costs, including those associated with affirmative claims, change orders and back charges, are recorded as incurred and revisions to estimated total costs are reflected as soon as the obligation to perform is determined. Contract costs consist of direct costs on contracts, including labor and materials, amounts payable to subcontractors, direct overhead costs and equipment expense (primarily depreciation, fuel, maintenance and repairs).

During the six months ended March 31, 2021, we recognized revenue of $1.0 million as a result of changes in contract transaction price related to performance obligations that were satisfied prior to September 30, 2020. The changes in contract transaction price were from items such as changes in projected profit, executed or estimated change orders, and unresolved contract modifications and claims.

The Company does not sell warranties for its construction services. At March 31, 2021, the Company had $10.9 million in remaining unsatisfied performance obligations, in which revenue is expected to be recognized in less than twelve months.

6. UNCOMPLETED CONTRACTS

Costs, estimated earnings, and billings on uncompleted contracts as of March 31, 2021 and September 30, 2020 are summarized as follows:

Backlog at March 31, 2021 and September 30, 2020 was $61.2 million and $63.8 million, respectively.

7. FAIR VALUE MEASUREMENTS

The Fair Value Measurements and Disclosures Topic of the Financial Accounting Standards Board (FASB) Accounting Standards Codification defines fair value, establishes a framework for measuring fair value in generally accepted accounting principles and expands disclosures about fair value measurements.

Under the FASB’s authoritative guidance on fair value measurements, fair value is the price that would be received to sell an asset or paid to transfer a liability in an orderly transaction between market participants at the measurement date. The Fair Value Measurements Topic of the FASB Accounting Standards Codification establishes a three-level hierarchy for fair value measurements based upon the transparency of inputs to the valuation of an asset or liability as of the measurement date.

As noted above, there is a three-level valuation hierarchy for disclosure of fair value measurements. The valuation hierarchy is based upon the transparency of inputs to the valuation of an asset or liability as of the measurement date. The three levels are defined as follows:

Level 1 — Quoted prices for identical assets and liabilities traded in active exchange markets, such as the New York Stock Exchange.

Level 2 — Observable inputs other than Level 1 including quoted prices for similar assets or liabilities, quoted prices in less active markets, or other observable inputs that can be corroborated by observable market data.

Level 3 — Unobservable inputs supported by little or no market activity for financial instruments whose value is determined using pricing models, discounted cash flow methodologies, or similar techniques, as well as instruments for which the determination of fair value requires significant management judgment or estimation; also includes observable inputs for nonbinding single dealer quotes not corroborated by observable market data.

A financial instrument’s categorization within the valuation hierarchy is based upon the lowest level of input that is significant to the fair value measurement.

The carrying amount for borrowings under the Company’s revolving credit facility approximates fair value because of the variable market interest rate charged to the Company for these borrowings. The fair value of the Company’s long term fixed-rate debt to unrelated parties was estimated using a discounted cash flow analysis and a yield rate that was estimated based on the borrowing rates for bank loans with similar terms and maturities. The fair value of the aggregate principal amount of the Company’s fixed-rate debt of $18.7 million at March 31, 2021 was $17.9 million. The fair value of the aggregate principal amount of the Company’s fixed-rate debt of $15.8 million at September 30, 2020 was $14.8 million.

All receivables and payables are carried at net realizable value which approximates fair value because of their short duration to maturity.

8. LOSS PER SHARE

The amounts used to compute the loss per share for the three and six months ended March 31, 2021 and 2020 are summarized below.

9. INCOME TAXES

The components of income taxes are as follows:

The effective income tax rate for the three months ended March 31, 2021 was (20.4%), as compared to (23.2%) for the same period in 2020. The effective income tax rate for the six months ended March 31, 2021 was (17.1%), as compared to (23.6%) for the same period in 2020. Effective income tax rates are estimates and may vary from period to period due to changes in the amount of taxable income and non-deductible expenses. Per diem paid to employees on construction projects is only partially deductible from taxable income and can have a significant impact on the effective tax rate.

The income tax effects of temporary differences giving rise to the deferred tax assets and liabilities are as follows:

The Company and all subsidiaries file a consolidated federal and various state income tax returns on a fiscal year basis. With few exceptions, the Company is no longer subject to U.S. federal, state, or local income tax examinations for years ended prior to September 30, 2017.

The Company does not believe that it has any unrecognized tax benefits included in its consolidated financial statements that require recognition. The Company has not had any settlements in the current period with taxing authorities, nor has it recognized tax benefits as a result of a lapse of the applicable statute of limitations. The Company recognizes interest and penalties accrued related to unrecognized tax benefits, if applicable, in selling and administrative expenses.

10. SHORT-TERM AND LONG-TERM DEBT

Short-term debt consists of the following:

On July 30, 2020, the Company received a one-year extension on its line of credit (“Operating Line of credit (2020)”) effective June 28, 2020. The $15.0 million revolving line of credit has a $12.5 million component and a $2.5 million component, each with separate borrowing requirements. The interest rate on the line of credit is the “Wall Street Journal” Prime Rate (the index) with a floor of 4.99%. The line of credit expires on June 28, 2021. Based on the borrowing base calculation, the Company was able to borrow up to $11.3 million as of March 31, 2021. The Company had $3.5 million in borrowings on the line of credit, leaving $7.8 million available on the line of credit as of March 31, 2021. The interest rate at March 31, 2021 was 4.99%. Based on the borrowing base calculation, the Company was able to borrow up to $11.1 million as of September 30, 2020. The Company had no borrowings on the line of credit, leaving $11.1 million available on the line of credit as of September 30, 2020. The interest rate at September 30, 2020 was 4.99%.

Major items excluded from the borrowing base calculation are receivables from bonded jobs and retainage as well as all items greater than ninety (90) days old. Line of credit borrowings are collateralized by the Company’s accounts receivable. Cash available under the line is calculated based on 70.0% of the Company’s eligible accounts receivable.

Under the terms of the agreement, the Company must meet the following loan covenants to access the first $12.5 million:

Under the terms of the agreement, the Company must meet the following additional requirements for draw requests causing the borrowings to exceed $12.5 million:

The Company believes it was in compliance with all covenants for the $12.5 million component of Operating Line of Credit (2020) at March 31, 2021.

The Company also finances insurance policy premiums on a short-term basis through a financing company. These insurance policies include workers’ compensation, general liability, automobile, umbrella, and equipment policies. It is typical that the Company makes a down payment in January and finances the remaining premium amount over ten monthly payments. In January 2021, the Company financed $3.2 million in insurance premiums. At March 31, 2021, the balance of the insurance premiums was $2.2 million.

A summary of short-term and long-term debt as of March 31, 2021 and September 30, 2020 is as follows:

The SBA has announced, in consultation with the Department of the Treasury, that it will review all loans in excess of $2 million, following the lender’s submission of the borrower’s loan forgiveness application. The SBA will be reviewing a borrower’s required certification that current economic uncertainty at the time of the loan made the PPP loan request necessary to support the ongoing operations of the Applicant. Borrowers must make this certification in good faith, taking into account their current business activity and their ability to access other sources of liquidity sufficient to support their ongoing operations in a manner that is not significantly detrimental to the business. The SBA has noted it is unlikely that a public company with substantial market value and access to capital markets will be able to make the required certification in good faith, and such a company should be prepared to demonstrate to the SBA, upon request, the basis for its certification.

The Company’s lender approved its forgiveness applications and forwarded them to the SBA in early March 2021. The SBA has up to 90 days to reach a decision on forgiveness; however, the process could take longer due to the size of the loans or administrative backlog at the SBA. Any portion of the loan that is not forgiven will be converted to a five-year note with 1.0% interest.

11. ACQUISITION

On December 31, 2020, Energy Services completed an asset purchase of West Virginia Pipeline, which became a wholly owned subsidiary of Energy Services that operates as a gas and water distribution contractor primarily in southern West Virginia. Energy Services paid $3.5 million in cash and acquired a $3.0 million seller note with a term of five years with an interest rate of 3.25%. Previous owners, David Bolton and Daniel Bolton, have continued their roles as President and Vice President, respectively. The Company incurred approximately $150,000 in expenses related to the acquisition.

West Virginia Pipeline earned revenues of $1.2 million for the three months ended March 31, 2021. ASC 805-10-50-2 requires public companies that present comparative financial statements to present pro forma financial statements as though the business combination that occurred during the current fiscal year had occurred as of the beginning of the comparable prior annual reporting period. As allowed under ASC 805-10-50-2, the Company finds this information impracticable to provide for the interim periods presented due to the lack of availability of meaningful financial statements of the acquired company that comply with U.S. Generally Accepted Accounting Principles.

Energy Services accounts for business combinations under the acquisition method in accordance with ASC Topic 805, Business Combinations. Accordingly, for each transaction, the purchase price is allocated to the fair value of the assets acquired and liabilities assumed as of the date of the acquisition. In conjunction with the adoption of Accounting Standards Update (“ASU”) 2015-16, upon receipt of final fair value estimates during the measurement period, which must be within one year of the acquisition date, Energy Services records any adjustments to the preliminary fair value estimates in the reporting period in which the adjustments are determined. Energy Services is continuing to finalize the purchase price allocations related to the West Virginia Pipeline acquisition. Based on management's preliminary valuation of tangible and intangible assets acquired and liabilities assumed, the purchase price for the West Virginia Pipeline acquisition is allocated in the table below. These allocations are subject to change.

West Virginia Pipeline’s past financial performance, experienced management and workforce and relationships with its customers made it an attractive acquisition for the Company. Going back to 1963, West Virginia Pipeline has a long history of excellent work performance in southern West Virginia. Their geographic region compliments Energy Services as the two companies rarely competed for work previously. The $4.2 million in goodwill generated by the acquisition is largely the result of the high return on capital generated by West Virginia Pipeline. While West Virginia Pipeline will be managed separately from the Company’s other union operations, it is expected that relationships built by all the companies will help provide new opportunities within the organization.

12. SUBSEQUENT EVENTS

On April 30, 2021, the Company’s Nitro subsidiary completed the purchase of Revolt Energy, Inc. (“Revolt Energy”, a Delaware corporation located in Nitro, WV for $150,000. Revolt Energy will operate primarily in West Virginia as a solar installation division of Nitro. All employees of Revolt Energy agreed to employment with Nitro. Revolt’s construction workers are union members of the International Brotherhood of Electrical Workers and are subject to collective bargaining agreements that expire at varying time intervals.

Management has evaluated subsequent events through May 12, 2021, the date which the financial statements were available for issue.  There have been no other material events during the period, other than noted above, that would either impact the results reflected in the report or the Company’s results going forward.

ITEM 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

You should read the following discussion of the financial condition and results of operations of Energy Services in conjunction with the “Financial Statements” appearing in this report as well as the historical financial statements and related notes contained elsewhere herein. Among other things, those historical consolidated financial statements include more detailed information regarding the basis of presentation for the following information. The term “Energy Services” refers to the Company, West Virginia Pipeline, SQP and C.J. Hughes and C.J. Hughes’ wholly owned subsidiaries on a consolidated basis.

Forward Looking Statements

Within Energy Services’ consolidated financial statements and this discussion and analysis of the financial condition and results of operations, there are included statements reflecting assumptions, expectations, projections, intentions or beliefs about future events that are intended as “forward-looking statements” under the Private Securities Litigation Reform Act of 1995. You can identify these statements by the fact that they do not relate strictly to historical or current facts. They use words such as “anticipate,” “estimate,” “project,” “forecast,” “may,” “will,” “should,” “could,” “expect,” “believe,” “intend” and other words of similar meaning.

These forward-looking statements are not guarantees of future performance and involve or rely on a number of risks, uncertainties, and assumptions that are difficult to predict or beyond Energy Services’ control. Energy Services has based its forward-looking statements on management’s beliefs and assumptions based on information available to management at the time the statements are made. Actual outcomes and results may differ materially from what is expressed, implied and forecasted by forward-looking statements and any or all of Energy Services’ forward-looking statements may turn out to be wrong. The accuracy of such statements can be affected by inaccurate assumptions and by known or unknown risks and uncertainties.

All of the forward-looking statements, whether written or oral, are expressly qualified by these cautionary statements and any other cautionary statements that may accompany such forward-looking statements or that are otherwise included in this report. In addition, Energy Services does not undertake and expressly disclaims any obligation to update or revise any forward-looking statements to reflect events or circumstances after the date of this report or otherwise.

Company Overview

Energy Services of America Corporation (“Energy Services” or the “Company”) is a contractor and service company that operates primarily in the mid-Atlantic region of the United States and provides services to customers in the natural gas, petroleum, water distribution, automotive, chemical and power industries. C.J. Hughes Construction Company, Inc. (“C.J. Hughes”), a wholly owned subsidiary of the Company, is a general contractor primarily engaged in pipeline construction for utility companies. Contractors Rental Corporation (“Contractors Rental”), a wholly owned subsidiary of C.J. Hughes, provides union building trade employees for projects managed by C.J. Hughes. Nitro Construction Services, Inc. (“Nitro”), a wholly owned subsidiary of C.J. Hughes, provides electrical, mechanical, HVAC/R and fire protection services to customers primarily in the automotive, chemical and power industries. Pinnacle Technical Solutions, Inc. (“Pinnacle”), a wholly owned subsidiary of Nitro, operates as a data storage facility within Nitro’s office building. Pinnacle is supported by Nitro and has no employees of its own. All C.J. Hughes, Nitro, and Contractors Rental construction personnel are union members of various related construction trade unions and are subject to collective bargaining agreements that expire at varying time intervals.

On December 31, 2020, Energy Services completed the purchase of West Virginia Pipeline, Inc. (“West Virginia Pipeline”), a West Virginia corporation located in Princeton, West Virginia. West Virginia Pipeline, a wholly owned subsidiary of Energy Services, operates as a gas and water distribution contractor primarily in southern West Virginia. West Virginia Pipeline’s employees are non-union, and the company is managed independently from C.J. Hughes and Nitro.

On March 22, 2021, the Company established a new wholly owned subsidiary, SQP Construction Group, Inc. (“SQP”), that will operate as a general contractor primarily in West Virginia, Ohio, and Kentucky. SQP will primarily engage in the construction and renovation of buildings and other civil construction projects. As a general contractor, SQP will manage the overall construction project and subcontract most of the work. SQP had not been awarded any projects as of March 31, 2021. The Company did not incur significant expenses in setting up the new subsidiary for the three and six months ended March 31, 2021.

Energy Services provides contracting services for utilities and energy related companies including gas distribution and transmission, petroleum, power, chemical, water & sewer and automotive industries. For the gas industry, the Company is primarily engaged in the construction, replacement and repair of natural gas pipelines and storage facilities for utility companies and private natural gas companies. Energy Services is involved in the construction of both interstate and intrastate pipelines, with an emphasis on the latter. For the oil industry, the Company provides a variety of services relating to pipeline, storage facilities and plant work. For the power, chemical, and automotive industries, the Company provides a full range of electrical and mechanical installations and repairs including substation and switchyard services, site preparation, equipment setting, pipe fabrication and installation, packaged buildings, transformers and other ancillary work with regards thereto. Energy Services’ other services include liquid pipeline construction, pump station construction, production facility construction, water and sewer pipeline installations, various maintenance and repair services and other services related to pipeline construction. The majority of the Company’s customers are located in West Virginia, Virginia, Ohio, Pennsylvania, and Kentucky.

Energy Services’ customers include many of the leading companies in the industries it serves, including:

TransCanada Corporation

Columbia Gas Distribution

Marathon Petroleum

Mountaineer Gas

American Electric Power

Toyota Motor Manufacturing

Bayer Chemical

Dow Chemical

Kentucky American Water

WV American Water

Various state, county and municipal public service districts.

Energy Services’ sales force consists of industry professionals with significant relevant sales experience, who utilize industry contacts and available public data to determine how to most appropriately market the Company’s line of products. The Company relies on direct contact between its sales force and customers’ engineering and contracting departments in order to obtain new business. The Company’s website address is www.energyservicesofamerica.com.

COVID-19 Response

In March 2020, the World Health Organization recognized the novel strain of coronavirus, COVID-19, as a pandemic. This coronavirus outbreak has significantly impacted both the world and U.S. economies. In response to this coronavirus outbreak, the governments of many cities, counties, states and other geographic regions have taken preventative or protective actions, such as imposing restrictions on travel and business operations and advising or requiring individuals to limit or forego their time outside of their homes which has created significant uncertainties in the U.S. economy. In certain geographic regions in which the Company operates, temporary closures of businesses have been ordered or suggested and numerous other businesses have temporarily closed voluntarily. Further, individuals' ability to travel has been curtailed through mandated travel restrictions and may be further limited through additional voluntary or mandated closures of travel-related businesses.

Some of the procedures that the Company has implemented to help protect employees from COVID-19 exposure are guidelines for social distancing, office sanitation, hand washing, mask wearing, limited office admittance and immediate symptom reporting. The Company has provided personal protective equipment and hand-sanitizers to employees and has made arrangements for administrative personnel to work from home. The Company works closely with our customers to limit exposure risk and cooperate with symptom reporting and contact tracing. Construction employees are required to meet all procedures established by our customers in addition to the Company’s own procedures. The Company also followed the paid sick and expanded family and medical leave guidelines set forth in the Families First Coronavirus Response Act, which expired on December 31, 2020. As of March 31, 2021, the Company has not had significant issues with COVID-19 exposure among its employees.

As of March 31, 2021, most of the Company’s existing customers had resumed projects that were affected by the March 2020 shutdowns. As a result, the Company has increased its employment level of construction personnel as compared to March 31, 2020. Given the uncertainty regarding the spread of this coronavirus, the related financial impact on the Company’s results of operations, financial position, and liquidity or capital resources cannot be reasonably estimated at this time.

Seasonality: Fluctuation of Results

Our revenues and results of operations can and usually are subject to seasonal variations. These variations are the result of weather, customer spending patterns, bidding seasons and holidays. The first quarter of the calendar year is typically the slowest in terms of revenues because inclement weather conditions cause delays in production and customers usually do not plan large projects during that time. While usually better than the first quarter, the second calendar year quarter often has some inclement weather which can cause delays in production, reducing the revenues the Company receives and/or increasing the production costs. The third and fourth calendar year quarters usually are less impacted by weather and usually have the largest number of projects underway. Many projects are completed in the fourth calendar year quarter and revenues are often impacted by customers seeking to either spend their capital budget for the year or scale back projects due to capital budget overruns.

In addition to the fluctuations discussed above, the pipeline industry can be highly cyclical, reflecting variances in capital expenditures in proportion to energy price fluctuations. As a result, our volume of business may be adversely affected by where our customers are in the cycle and thereby their financial condition as to their capital needs and access to capital to finance those needs.

Three and Six Months Ended March 31, 2021 and 2020 Overview

The following is an overview of results from operations for the three and six months ended March 31, 2021 and 2020:

Results of Operations for the Three and Six Months Ended March 31, 2021 Compared to the Three and Six Months Ended March 31, 2020

Revenues. A table comparing the Company’s revenues for the three and six months ended March 31, 2021 compared to the three and six months ended March 31, 2020 is below:

Total revenues for the three and six months ended March 31, 2021 increased by $7.5 million and $13.7 million, respectively, compared to the same periods in 2020.

Gas & Water Distribution revenues totaled $8.6 million for the three months ended March 31, 2021, a $4.2 million increase from $4.4 million for the three months ended March 31, 2020. Gas & Water Distribution revenues totaled $15.7 million for the six months ended March 31, 2021, a $3.5 million increase from $12.2 million for the six months ended March 31, 2020. The increase was primarily related to the Company’s overall commitment to growing this line of business. Most of the work was from the Company’s blanket distribution contracts, but the Company did complete a highly successful gas distribution bid project during the three months ended March 31, 2021. West Virginia Pipeline, acquired on December 31, 2020, contributed revenues of $1.2 million for the three months ended March 31, 2021.

Gas & Petroleum Transmission revenues totaled $3.7 million for the three months ended March 31, 2021, a $522,000 increase from $3.2 million for the three months ended March 31, 2020. Gas & Petroleum Transmission revenues totaled $12.4 million for the six months ended March 31, 2021, a $4.1 million increase from $8.2 million for the six months ended March 31, 2020. The increases were primarily related to several short-duration repair and replacement projects that were substantially complete by March 31, 2021.

Electrical & Mechanical revenues totaled $13.3 million for the three months ended March 31, 2021, a $2.8 million increase from $10.5 million for the three months ended March 31, 2020. Electrical & Mechanical revenues totaled $29.5 million for the six months ended March 31, 2021, a $6.1 million increase from $23.4 million for the six months ended March 31, 2020. The increases were primarily related to a significant increase in electrical work performed at an automotive facility in Alabama.

Cost of Revenues. A table comparing the Company’s costs of revenues for the three and six months ended March 31, 2021 compared to the three and six months ended March 31, 2020 is below:

Total cost of revenues for the three and six months ended March 31, 2021 increased by $5.7 million and $11.4 million, respectively, compared to the same periods in 2020.

Gas & Water Distribution cost of revenues totaled $7.2 million for the three months ended March 31, 2021, a $3.0 million increase from $4.2 million for the three months ended March 31, 2020. Gas & Water Distribution cost of revenues totaled $13.3 million for the six months ended March 31, 2021, a $2.7 million increase from $10.6 million for the six months ended March 31, 2020. The increase was primarily related to the Company’s overall commitment to growing this line of business.

Gas & Petroleum Transmission cost of revenues totaled $2.8 million for the three months ended March 31, 2021, a $558,000 increase from $2.2 million for the three months ended March 31, 2020. The increase was primarily due to the increased revenue; however, one transmission project suffered from production issues during the three months ended March 31, 2021. Gas & Petroleum Transmission cost of revenues totaled $9.5 million for the six months ended March 31, 2021, a $3.3 million increase from $6.2 million for the six months ended March 31, 2020. The increase was primarily related to several short-duration repair and replacement projects that were substantially complete by March 31, 2021.

Electrical & Mechanical cost of revenues totaled $12.3 million for the three months ended March 31, 2021, a $2.4 million increase from $9.9 million for the three months ended March 31, 2020. Electrical & Mechanical cost of revenues totaled $27.5 million for the six months ended March 31, 2021, a $5.4 million increase from $22.1 million for the six months ended March 31, 2020. The increases were primarily related to a significant increase in electrical work performed at an automotive facility in Alabama.

Gross Profit. A table comparing the Company’s gross profit for the three and six months ended March 31, 2021 compared to the three and six months ended March 31, 2020 is below:

Total gross profit for the three and six months ended March 31, 2021 increased by $1.8 million and $2.3 million, respectively, compared to the same periods in 2020.

Gas & Water Distribution gross profit totaled $1.4 million for the three months ended March 31, 2021, a $1.2 million increase from $158,000 for the three months ended March 31, 2020. Gas & Water Distribution gross profit totaled $2.5 million for the six months ended March 31, 2021, a $793,000 increase from $1.7 million for the six months ended March 31, 2020. The increases were primarily related to the Company’s overall commitment to growing this line of business. Most of the work was from the Company’s blanket distribution contracts, but the Company did complete a highly successful gas distribution bid project during the three months ended March 31, 2021. West Virginia Pipeline, acquired on December 31, 2020, contributed gross profit of $394,000 for the three months ended March 31, 2021.

Gas & Petroleum Transmission gross profit totaled $915,000 for the three months ended March 31, 2021, a $36,000 decrease from $951,000 for the three months ended March 31, 2020. The decrease was primarily related to one transmission project that suffered production issues during the three months ended March 31, 2021. Gas & Petroleum Transmission gross profit totaled $2.9 million for the six months ended March 31, 2021, an $824,000 increase from $2.1 million for the six months ended March 31, 2020. The increase was primarily related to several short-duration repair and replacement projects that were substantially complete by March 31, 2021.

Electrical & Mechanical gross profit totaled $1.0 million for the three months ended March 31, 2021, a $368,000 increase from $654,000 for the three months ended March 31, 2020. Electrical & Mechanical gross profit totaled $2.0 million for the six months ended March 31, 2021, a $704,000 increase from $1.3 million for the six months ended March 31, 2020. The increases were primarily related to a significant increase in electrical work performed at an automotive facility in Alabama.

Selling and administrative expenses. Total selling and administrative expenses increased by $1.5 million to $3.8 million for the three months ended March 31, 2021 from $2.3 million for the same period in 2020. A one-time $651,000 Qualified Non-Elective Contribution (“QNEC”) adjustment to the Company’s 401(k) plan (“Plan”) attributable to the 2021 Plan year increased selling and administrative costs for the three months ended March 31, 2021 as compared to 2020. The reason for the QNEC adjustment was to correct Plan participant’s balances due to a third-party administrator’s actions. Approximately $200,000 of the selling and administrative expense increase for the three months ended March 31, 2021 was from the operations of the newly acquired West Virginia Pipeline. Also, approximately $150,000 of the selling and administrative expense increase related to the acquisition of West Virginia Pipeline.

Total selling and administrative expenses increased by $2.5 million to $7.4 million for the six months ended March 31, 2021 from $4.9 million for the same period in 2020. This increase was primarily related to higher labor costs. Incentive compensation increased by $481,000 for the six months ended March 31, 2021 compared to the same period in 2020. The Company also incurred an additional $450,000 in labor costs during the six months ended March 31, 2021 due to investing in personnel to increase management, estimating and customer contacts in the transmission division, develop a quality assurance/quality control program, and improve production tracking. The overall increase in selling and administrative expense, including the increase in incentive compensation, related to an initiative launched by the Company to increase and incentivize operational talent within the Company and increase revenue and profit margins. Other increases in selling and administrative expenses for the six months ended March 31, 2021 as compared to the same period in 2020 included approximately $150,000 in expenses related to the Family First Coronavirus Response Act.

Interest Expense. Interest expense increased by $31,000 or 27.7% to $143,000 for the three months ended March 31, 2021 from $112,000 for the same period in 2020. This increase in interest expense for the three months ended March 31, 2021 was primarily due to the financing of the West Virginia Pipeline acquisition.

Interest expense decreased by $79,000 or 26.6% to $220,000 for the six months ended March 31, 2021 from $299,000 for the same period in 2020. This decrease in interest expense for the six months ended March 31, 2021 was primarily due to the timing of debt repayment and debt proceeds received in the Company’s first quarter of fiscal year 2021 compared to 2020.

Net loss. Loss before income taxes was ($1.6 million) for the three months ended March 31, 2021, compared to loss before income taxes of ($2.2 million) for the same period in 2020. Loss before income taxes was ($2.4 million) for the six months ended March 31, 2021, compared to loss before income taxes of ($2.3 million) for the same period in 2020. The loss before income taxes for the respective periods were due to the items mentioned above.

Income tax benefit for the three months ended March 31, 2021 was ($336,000) compared to income tax benefit of ($511,000) for the same period in 2020. Income tax benefit for the six months ended March 31, 2021 was ($405,000) compared to income tax benefit of ($548,000) for the same period in 2020.

The effective income tax rate for the three months ended March 31, 2021 was (20.4%), as compared to (23.2%) for the same period in 2020. The effective income tax rate for the six months ended March 31, 2021 was (17.1%), as compared to (23.6%) for the same period in 2020. Effective income tax rates are estimates and may vary from period to period due to changes in the amount of taxable income and non-deductible expenses. Per diem paid to employees on construction projects is only partially deductible from taxable income and can have a significant impact on the effective tax rate.

Dividends on preferred stock for the three and six months ended March 31, 2021 and 2020 were $77,250 and $154,500, respectively.

Net loss available to common shareholders for the three months ended March 31, 2021 was ($1.4 million) compared to net loss available to common shareholders of ($1.8 million) for the same period in 2020. Net loss available to common shareholders for the six months ended March 31, 2021 was ($2.1 million) compared to net loss available to common shareholders of ($1.9 million) for the same period in 2020.

Comparison of Financial Condition at March 31, 2021 and September 30, 2020

The Company had total assets of $60.3 million at March 31, 2021, an increase of $2.1 million from the prior fiscal year end balance of $58.2 million.

Goodwill and acquired intangible assets resulting from the West Virginia Pipeline acquisition totaled $4.5 million at March 31, 2021, as compared to no goodwill and acquired intangible assets at the prior fiscal year end.

The Company had property, plant and equipment of $20.1 million at March 31, 2021, an increase of $3.7 million from the prior fiscal year end balance of $16.4 million. The increase was due to $6.0 million in property, plant and equipment acquisitions, of which $1.9 million related to the acquisition of West Virginia Pipeline, partially offset by depreciation of $2.2 million.

Prepaid expenses and other totaled $4.9 million at March 31, 2021, an increase of $1.6 million from the prior fiscal year end balance of $3.3 million. The increase was primarily due to prepaid insurance premiums that were financed during the three months ended March 31, 2021.

Other receivables totaled $354,000 at March 31, 2021, a $345,000 increase from the prior fiscal year end balance of $9,000. The increase was primarily due to a reclass of federal and state income tax estimate payments made in the three months ended March 31, 2021. The Company will reclass the payments to offset any income taxes payable at the end of fiscal year 2021.

Accounts receivable, which totaled $18.4 million at March 31, 2021, increased by $136,000 from the prior fiscal year end balance of $18.2 million. The increase was primarily due to the timing of current year billings and collections partially offset by the collection of receivables from September 30, 2020.

Cash and cash equivalents totaled $5.1 million at March 31, 2021, a decrease of $5.1 million from the prior fiscal year end balance of $11.2 million. The decrease was primarily due to property, plant, and equipment acquisitions, partially offset by normal operating cash flow activities.

Contract assets totaled $4.3 million at March 31, 2021, a decrease of $2.2 million from the prior fiscal year end balance of $6.5 million. The decrease was due to a difference in the timing of project billings at March 31, 2021 compared to September 30, 2020.

Retainages receivable totaled $1.8 million at March 31, 2021, a $723,000 decrease from the prior fiscal year end balance of $2.5 million. The decrease was primarily due to the timing of retainages collection and fewer current projects that require retainages to be withheld.

The Company had total liabilities of $36.5 million at March 31, 2021, an increase of $4.2 million from the prior fiscal year end balance of $32.3 million.

Lines of credit and short-term borrowings totaled $5.7 million at March 31, 2021, an increase of $5.2 million from the prior fiscal year end balance of $510,000. The increase was primarily due to net line of credit borrowings of $3.5 million and $1.6 million in insurance premiums financed, net of repayments.

Long-term debt totaled $17.5 million at March 31, 2021, an increase of $2.2 million from the prior fiscal year end balance of $15.3 million. The increase in long-term debt was due to the $3.0 million note payable related to the West Virginia Pipeline acquisition, partially offset by scheduled debt payments.

Contract liabilities totaled $3.5 million at March 31, 2021, a decrease of $1.4 million from the prior fiscal year end total of $4.9 million. The decrease was due to a difference in the timing of project billings at March 31, 2021 compared to at September 30, 2020.

Accrued expenses and other current liabilities totaled $3.2 million at March 31, 2021, a decrease of $1.0 million from the prior fiscal year end balance of $4.2 million. The decrease was primarily due to the payment of accrued expenses in the six months ended March 31, 2021.

Deferred tax liabilities totaled $1.8 million at March 31, 2021, a decrease of $442,000 from the prior fiscal year end balance of $2.3 million. The decrease was primarily related to the net operating loss carry forward for the six months ended March 31, 2021.

Accounts payable totaled $4.9 million at March 31, 2021, a decrease of $341,000 from the prior fiscal year end balance of $5.2 million. The decrease was due to the timing of accounts payable payments as compared to September 30, 2020.

Shareholders’ equity was $23.7 million at March 31, 2021, a decrease of $2.1 million from the prior fiscal year end balance of $25.8 million. This decrease was due to the net loss available to common shareholders of ($2.1 million) for the six months ended March 31, 2021.

Liquidity and Capital Resources

Indebtedness

On December 16, 2014, the Company’s Nitro subsidiary entered into a 20-year $1.2 million loan agreement with First Bank of Charleston, Inc. (West Virginia) to purchase the office building and property it had previously been leasing for $6,300 monthly. The interest rate on this loan agreement is 4.82% with monthly payments of $7,800. The interest rate on this note is subject to change from time to time based on changes in The U.S. Treasury yield, adjusted to a constant maturity of three years as published by the Federal Reserve weekly. As of March 31, 2021, the Company had made principal payments of $256,000. The loan is collateralized by the building purchased under this agreement.

On September 16, 2015, the Company entered into a $2.5 million Non-Revolving Note agreement with United Bank, Inc. This six-year agreement gave the Company access to a $2.5 million line of credit (“Equipment Line of Credit”), specifically for the purchase of equipment, for the period of one year with an interest rate of 5.0%. After the first year, all borrowings against the Equipment Line of Credit were converted to a five-year term note agreement with an interest rate of 5.0%. As of March 31, 2021, the Company had borrowed $2.46 million against this note and made principal payments of $2.2 million. The loan is collateralized by the equipment purchased under this agreement.

On November 13, 2015, the Company entered into a 10-year $1.1 million loan agreement with United Bank, Inc. to purchase the fabrication shop and property Nitro had previously been leasing for $12,900 each month. The interest rate on the new loan agreement is 4.25% with monthly payments of $11,602. As of March 31, 2021, the Company had made principal payments of $512,000. The loan is collateralized by the building and property purchased under this agreement.

On June 28, 2017, the Company entered into a $5.0 million Non-Revolving Note agreement with United Bank, Inc. This five-year agreement gave the Company access to a $5.0 million line of credit (“Equipment Line of Credit 2017”), specifically for the purchase of equipment, for a period of three months with an interest rate of 4.99%. After three months, all borrowings against the Equipment Line of Credit 2017 were converted to a five-year term note agreement with an interest rate of 4.99%. As of March 31, 2021, the Company had borrowed $5.0 million against this note and made principal payments of $3.6 million. The loan is collateralized by the equipment purchased under this agreement.

On December 31, 2020, West Virginia Pipeline Acquisition Company, later renamed West Virginia Pipeline, Inc., entered into a $3.0 million sellers’ note agreement with David and Daniel Bolton for the remaining purchase price of West Virginia Pipeline, Inc. As part of the $6.5 million acquisition, the acquisition company paid $3.5 million in cash in addition to the note. The unsecured five-year term note requires equal annual payments with a fixed interest rate of 3.25%. As of March 31, 2021, the Company has made interest payments of $24,000 and plans to make the first installment payment in December 2021.

On January 5, 2021, the Company entered into a $3.0 million Non-Revolving Note agreement with United Bank, Inc. This five-year agreement gave the Company access to a $3.0 million line of credit (“Equipment Line of Credit 2021”), specifically for the purchase of equipment, for a period of twelve months with a variable interest rate initially established at 4.25% as based on the Prime Rate as published by The Wall Street Journal. After twelve months, all borrowings against the Equipment Line of Credit 2021 will be converted to a four-year term note agreement with a variable interest rate initially established at 4.25%. The loan will be collateralized by the equipment purchased under this agreement. As of March 31, 2021, the Company had not borrowed against this line of credit.

Paycheck Protection Program Loans

Due to the economic uncertainties created by COVID-19 and the limited operating funds available, the Company applied for loans under the Paycheck Protection Program (“PPP”). On April 15, 2020, Energy Services of America Corporation and subsidiaries C.J. Hughes Construction Company, Contractors Rental Corporation and Nitro Construction Services, Inc. entered into separate Paycheck Protection Program Notes effective April 7, 2020 with United Bank, Inc. as the lender (“Lender”) in an aggregate principal amount of $13,139,100 pursuant to the PPP (collectively, the “PPP Loan”). In a special meeting held on April 27, 2020, the Board of Directors of the Company unanimously voted to return $3.3 million of the PPP Loan funds after discussing the financing needs of the Company and subsidiaries. That left the Company and subsidiaries with $9.8 million in PPP Loans to fund operations.

The SBA has announced, in consultation with the Department of the Treasury, that it will review all loans in excess of $2 million, following the lender’s submission of the borrower’s loan forgiveness application. The SBA will be reviewing a borrower’s required certification that current economic uncertainty at the time of the loan made the PPP loan request necessary to support the ongoing operations of the Applicant. Borrowers must make this certification in good faith, taking into account their current business activity and their ability to access other sources of liquidity sufficient to support their ongoing operations in a manner that is not significantly detrimental to the business. The SBA has noted it is unlikely that a public company with substantial market value and access to capital markets will be able to make the required certification in good faith, and such a company should be prepared to demonstrate to the SBA, upon request, the basis for its certification. The Company had used all the available PPP Loan funds as of March 31, 2021 and had filed for loan forgiveness with its Lender. The Lender approved the Company’s forgiveness applications and forwarded them to the SBA in early March 2021. The SBA has up to 90 days to reach a decision on forgiveness; however, the process could take longer due to the size of the loans or administrative backlog at the SBA. Any portion of the loan that is not forgiven will be converted to a five-year note with 1.0% interest.

The Company believes it meets the SBA’s certification requirement based on its limited access to capital, weakening business operations and small market value as described above. The Company’s shares of common stock do not trade on a national exchange. However, no assurance can be given as to the outcome of the SBA’s audit of the Company’s PPP Loan. The SBA could determine that the Company does not qualify in whole or in part for loan forgiveness. In addition, it is unknown what type of penalties could be assessed against the Company if the SBA disagrees with the Company’s certification. The Company could be required to return its PPP Loan. Any penalties in addition to the potential return of the PPP Loan could negatively impact the Company’s business, financial condition and results of operations and prospects.

Operating Line of Credit

On July 30, 2020, the Company received a one-year extension on its line of credit (“Operating Line of credit (2020)”) effective June 28, 2020. The $15.0 million revolving line of credit has a $12.5 million component and a $2.5 million component, each with separate borrowing requirements. The interest rate on the line of credit is the “Wall Street Journal” Prime Rate (the index) with a floor of 4.99%. The line of credit expires on June 28, 2021. Based on the borrowing base calculation, the Company was able to borrow up to $11.3 million as of March 31, 2021. The Company had $3.5 million in borrowings on the line of credit, leaving $7.8 million available on the line of credit as of March 31, 2021. The interest rate at March 31, 2021 was 4.99%. Based on the borrowing base calculation, the Company was able to borrow up to $11.1 million as of September 30, 2020. The Company had no borrowings on the line of credit, leaving $11.1 million available on the line of credit as of September 30, 2020. The interest rate at September 30, 2020 was 4.99%.

Major items excluded from the borrowing base calculation are receivables from bonded jobs and retainage as well as all items greater than ninety (90) days old. Line of credit borrowings are collateralized by the Company’s accounts receivable. Cash available under the line is calculated based on 70.0% of the Company’s eligible accounts receivable.

Under the terms of the agreement, the Company must meet the following loan covenants to access the first $12.5 million:

Under the terms of the agreement, the Company must meet the following additional requirements for draw requests causing the borrowings to exceed $12.5 million:

The Company believes it was in compliance with all covenants for the $12.5 million component of Operating Line of Credit (2020) at March 31, 2021.

Off-Balance Sheet Arrangements

Due to the nature of our industry, we often enter into certain off-balance sheet arrangements in the ordinary course of business that result in risks not directly reflected in our balance sheets. Though for the most part not material in nature, some of these are:

Leases

In February 2016, the FASB issued ASU 2016-02, “Leases (Topic 842)”. ASU 2016-02 is effective for public business entities for fiscal years beginning after December 15, 2018 including interim periods within those fiscal years. Among other things, lessees are required to recognize the following for all leases (except for short-term leases) at the commencement date: a lease liability, which is a lessee’s obligation to make lease payments arising from a lease, measured on a discounted basis; and a right-of-use asset, which is an asset that represents the lessee’s right to use, or control the use of, a specified asset for the lease term. It is the Company’s preference to acquire equipment needed for long-term use through purchase, by cash or finance. For equipment needed on a short-term basis, the Company will enter into short-term rental agreements with the equipment provider where the agreement is cancellable at any time. The adoption of ASU 2016-02 had an immaterial impact, if any, on its consolidated financial statements.

The Company rents equipment for use on construction projects with rental agreements being week to week or month to month. Rental expense can vary by fiscal year due to equipment requirements on construction projects and the availability of Company owned equipment. Rental expense, which is included in cost of goods sold on the Consolidated Income Statement, was $1.9 million and $1.2 million for the six months ended March 31, 2021 and 2020, respectively.

Letters of Credit

Certain of our customers or vendors may require letters of credit to secure payments that the vendors are making on our behalf or to secure payments to subcontractors and vendors on various customer projects. At March 31, 2021, the Company did not have any letters of credit outstanding.

Performance Bonds

Some customers, particularly new ones or governmental agencies require the Company to post bid bonds, performance bonds and payment bonds (collectively, performance bonds). These bonds are obtained through insurance carriers and guarantee to the customer that we will perform under the terms of a contract and that we will pay subcontractors and vendors. If the Company fails to perform under a contract or to pay subcontractors and vendors, the customer may demand that the insurer make payments or provide services under the bond. The Company must reimburse the insurer for any expenses or outlays it is required to make.

The ability to obtain bonding for future contracts is an important factor in the contracting industry with respect to the type and number of contracts that can be bid. Depending upon the size and conditions of a contract, the Company may be required to post letters of credit or other collateral in favor of the insurer. Posting of these letters or other collateral will reduce our borrowing capabilities. The Company does not anticipate any claims against outstanding performance bonds in the foreseeable future. At March 31, 2021, the Company had $4.5 million in performance bonds outstanding.

Concentration of Credit Risk

In the ordinary course of business, the Company grants credit under normal payment terms, generally without collateral, to our customers, which include natural gas and oil companies, general contractors, and various commercial and industrial customers located within the United States. Consequently, the Company is subject to potential credit risk related to business and economic factors that would affect these companies. However, the Company generally has certain statutory lien rights with respect to services provided. Under certain circumstances such as foreclosure, the Company may take title to the underlying assets in lieu of cash in settlement of receivables.

Please see the tables below for customers that represent 10.0% or more of the Company’s revenue or accounts receivable net of retention for the six months ended March 31, 2021 and 2020:

Litigation

In February 2018, the Company filed a lawsuit against a former customer related to a dispute over changes on a pipeline construction project. The Company is seeking $10.0 million in the lawsuit, none of which has been recognized in the Company’s financial statements. Although no trial date has been set, the Company expects the case to go to trial in fiscal year 2021 barring a mediation settlement between the parties. Other than described above, at March 31, 2021, the Company was not involved in any legal proceedings other than in the ordinary course of business. The Company is a party from time to time to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, punitive damages, civil penalties or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims, and proceedings, we record reserves when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. At March 31, 2021, the Company does not believe that any of these proceedings, separately or in aggregate, would be expected to have a material adverse effect on our financial position, results of operations or cash flows.

Related Party Transactions

We intend that all transactions between us and our executive officers, directors, holders of 10% or more of the shares of any class of our common stock and affiliates thereof, will be on terms no less favorable than those terms given to unaffiliated third parties and will be approved by a majority of our independent outside directors not having any interest in the transaction.

On December 16, 2014, the Company’s Nitro subsidiary entered into a 20-year $1.2 million loan agreement with First Bank of Charleston, Inc. (West Virginia) to purchase the office building and property it had previously been leasing for $6,300 each month. Mr. Douglas Reynolds, President of Energy Services, was a director and secretary of First Bank of Charleston. Mr. Samuel Kapourales, a director of Energy Services, was also a director of First Bank of Charleston. On October 15, 2018, First Bank of Charleston was merged into Premier Bank, Inc., a wholly owned subsidiary of Premier Financial Bancorp, Inc. Mr. Marshall Reynolds, Chairman of the Board of Energy Services, holds the same position with Premier Financial Bancorp Inc. Mr. Neal Scaggs is a director of Energy Services and holds the same position with Premier Financial Bancorp, Inc. Mr. Douglas Reynolds is the president and a director of Energy Services and a director of Premier Financial Bancorp, Inc. The interest rate on the loan agreement is 4.82% with monthly payments of $7,800. As of March 31, 2021, we have paid approximately $329,000 in principal and approximately $585,000 in interest since the beginning of the loan. There were no new material related party transactions entered into during the three and six months ended March 31, 2021.

Certain Energy Services subsidiaries routinely engage in transactions in the normal course of business with each other, including sharing employee benefit plan coverage, payment for insurance and other expenses on behalf of other affiliates, and other services incidental to business of each of the affiliates. All revenue and related expense transactions, as well as the related accounts payable and accounts receivable have been eliminated in consolidation.

Inflation

Due to relatively low levels of inflation during the three and six months ended March 31, 2021 and 2020, inflation did not have a significant effect on our results.

Critical Accounting Policies

The discussion and analysis of the Company’s financial condition and results of operations are based on our consolidated financial statements, which have been prepared in accordance with accounting principles generally accepted in the United States. The preparation of these consolidated financial statements requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities, disclosures of contingent assets and liabilities known to exist at the date of the consolidated financial statements and reported amounts of revenues and expenses during the reporting period. We evaluate our estimates on an ongoing basis, based on historical experience and on various other assumptions that are believed to be reasonable under the circumstances. There can be no assurance that actual results will not differ from those estimates. Management believes the following accounting policies affect our more significant judgments and estimates used in the preparation of our consolidated financial statements.

Revenue Recognition

On October 1, 2018, the Company adopted an Accounting Standard Update, Revenue from Contracts with Customers (Topic 606). The core principle of Topic 606 is that revenue will be recognized when promised goods or services are transferred to customers in an amount that reflects consideration for which entitlement is expected in exchange for those goods or services. We adopted Topic 606 using a modified retrospective transition approach and elected to apply Topic 606 to contracts with customers that are not substantially complete, i.e. less than 90% complete, as of October 1, 2018. The adoption of Topic 606 did not have a material impact on the Company’s financial statements.

In addition, as of October 1, 2018, we began to separately present contract assets and liabilities on the Company’s consolidated balance sheet. Contract assets may include costs and estimated earnings in excess of billings that were previously separately presented. Contract liabilities may include billings in excess of costs and estimated earnings that were previously separately presented as well as provisions for losses, when occurred, that were previously included in accrued expenses and other current liabilities.

The accounting policies that were affected by Topic 606 and the changes thereto are as follows:

Revenue Recognition:

Our revenue is primarily derived from construction contracts that can span several quarters. We recognize revenue in accordance with Topic 606. Topic 606 provides for a five-step model for recognizing revenue from contracts with customers as follows:

Identify the Contract

The first step in applying Accounting Standards Codification (ASC) 606 is to identify the contract(s) with the customer. To do so, the Company evaluates indicators of the existence of the contract.

Certain conditions must be present for there to be a contract with a customer:

It is probable that the Company will collect the consideration to which it will be entitled in exchange for the goods or services that will be transferred to the customer. In evaluating whether collectability of an amount of consideration is probable, the Company shall consider only the customer’s ability and intention to pay that amount of consideration when it is due. The amount of consideration to which the entity will be entitled may be less than the price stated in the contract if the consideration is variable because the entity may offer the customer a price concession.

Identify Performance Obligations

Once the Company has determined that it has a contract with a customer as defined in Accounting Standards Codification (ASC) 606, the Company must determine what the performance obligations are. A performance obligation is defined in the ASC Master Glossary as:

A promise in a contract with a customer to transfer to the customer either:

Generally, performance obligations are clearly stated in the contract. The Company’s contracts usually contain one performance obligation that is satisfied over time because our performance typically creates or enhances an asset that the customer controls as the asset is created or enhanced.

In assessing whether promises to transfer goods or service to the customer are separately identifiable, a company considers the following factors:

Under ASC 606, contracts will be required to be combined when certain criteria are met. The new accounting standard requires contracts be combined prior to further assessment of the five elements, if one or more of the following criteria are met:

If the promises do not meet the requirements for separating, the performance obligations shall be combined into one performance obligation.  A contract could have several performance obligations which in themselves include sets of promises that are not distinct and cannot be separated.

Management has made the assessment that the company is acting as a principal rather than as an agent (i.e., the company integrates the materials, labor and equipment into the deliverables promised to the customer) in all contract performed by the Company.

Determine Transaction Price

The transaction price is the amount of consideration to which the Company expects to be entitled in exchange for transferring goods and services to the customer. The consideration promised in a contract with customers may include both fixed amounts and variable amounts (e.g. bonuses/incentives or penalties/liquidated damages) to the extent that a significant reversal of cumulative revenue recognized will not occur when the uncertainty associated with the variable consideration is subsequently resolved (i.e., probable and estimable).

Variable consideration is defined broadly and can take many forms, such as incentives, penalty provisions, price concessions, rebates or refunds.  Consideration is also considered variable if the amount the Company will receive is contingent on a future event occurring or not occurring, even though the amount itself is fixed.

The following are examples of variable considerations within a contract:

Subsequent to the inception of a contract, the transaction price could change for various reasons, including the executed or estimated amount of change orders and unresolved contract modifications and claims to or from owners. Changes that are accounted for as an adjustment to existing performance obligations are allocated on the same basis at contract inception. Otherwise, changes are accounted for as separate performance obligation(s) and the separate transaction price is allocated as discussed above. Changes are made to the transaction price from unapproved change orders to the extent the amount can be reasonably estimated, and recovery is probable. On certain projects we have submitted and have pending unresolved contract modifications and affirmative claims (“affirmative claims”) to recover additional costs and the associated profit, if applicable, to which the Company believes it is entitled under the terms of contracts with customers, subcontractors, vendors or others. The owners or their authorized representatives and/or other third parties may be in partial or full agreement with the modifications or affirmative claims or may have rejected or disagree entirely or partially as to such entitlement.

Allocate Transaction Price

When a contract has a single performance obligation, the entire transaction price is attributed to that performance obligation. When a contract has more than one performance obligation, the transaction price is allocated to each performance obligation based on estimated relative standalone selling prices of the goods or services at the inception of the contract, which typically is determined using cost plus an appropriate margin.

In accordance with Topic 606, the Company is required to estimate variable consideration when determining the contract transaction price by taking into account all the information (historical, current and forecasted) that is reasonably available and identifying a reasonable number of possible consideration amounts.  Management must include an estimate of any variable consideration using either the “expected value” method or the “most likely amount” method.

The “expected value” method estimates variable consideration based on the range of possible outcomes and the probabilities of each outcome.  This method might be most appropriate when the Company has a large number of contracts that have similar characteristics because it will likely have better information about the probabilities of various outcomes when there are a large number of similar transactions.

The “most likely amount” method estimates variable consideration based on the single most likely amount in a range of possible consideration amounts. This method might be the most predictive if the Company will receive one of only two possible amounts.

The method used is not a policy choice and should be applied consistently throughout a contract, however, is subject to guidance on constraining estimates of variable consideration. The Company may only include variable consideration within the transaction price to the extent that it is probable that a significant reversal of revenue will not occur when the uncertainty is subsequently resolved. This assessment will require the application of judgment.  While no single factor is determinative, the revenue standard includes factors to consider when assessing whether variable consideration should be constrained.

The following factors may increase the likelihood or the magnitude of a revenue reversal:

Recognize Revenue

The Company disaggregates revenue based on our operating groups and contract types as it is the format that is regularly reviewed by management. Our reportable operating groups are: Gas & Water Distribution, Gas & Petroleum Transmission, Petroleum, and Electrical & Mechanical services. Our contract types are: Lump Sum, Unit Price, and Cost Plus and Time and Material (T&M).

The Company recognizes revenue as performance obligations are satisfied and control of the promised good and service is transferred to the customer. For Lump Sum contracts, revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward complete satisfaction of the performance obligation(s) using an input (i.e., “cost to cost”) method. For Unit Price, Cost Plus and T&M contracts, revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward satisfaction of the performance obligation(s) using an output method.

The Company does have certain service and maintenance contracts in which each customer purchase order is considered its own performance obligation recognized over time and would be recognized depending on the type of contract mentioned above. The Company also does certain T&M service work that is generally completed in a short duration and is recognized at a point in time.

All contract costs, including those associated with affirmative claims, change orders and back charges, are recorded as incurred and revisions to estimated total costs are reflected as soon as the obligation to perform is determined. Contract costs consist of direct costs on contracts, including labor and materials, amounts payable to subcontractors and outside equipment providers, direct overhead costs and internal equipment expense (primarily depreciation, fuel, maintenance and repairs).

The company recognizes revenue, but not profit, on certain uninstalled materials. Revenue on these uninstalled materials is recognized when the cost is incurred (when control is transferred), but the associated profit is not recognized until the end of the project. The costs of uninstalled materials will be tracked separately within the Company’s accounting software.

Pre-contract and bond costs, if required, on projects are generally immaterial to the total value of the Company’s contracts and are expensed when incurred. Project mobilization costs are also generally immaterial and charged to project costs as incurred. As a practical expedient, the Company recognizes these incremental costs as an expense when incurred if the amortization period of the asset that the entity otherwise would have recognized is one year or less. For projects expected to last greater than one year, mobilization costs will be capitalized as incurred and amortized over the expected duration of the project. For these projects, mobilization costs will be tracked separately in the Company’s accounting software. This includes costs associated with setting up a project lot or lay-down yard, equipment, tool and supply transportation, temporary facilities and utilities and worker qualification and safety training.

Contracts may require the Company to warranty that work is performed in accordance with the contract; however, the warranty is not priced separately, and the Company does not offer customers an option to purchase a warranty. As of March 31, 2021, the Company does not have a material amount of costs expensed that would otherwise be capitalized and amortized.

The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our estimates of the cost to complete each project. We believe our experience allows us to create materially reliable estimates. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include:

The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins may cause fluctuations in gross profit from period to period. Significant changes in cost estimates, particularly in our larger, more complex projects have had, and can in future periods have, a significant effect on our profitability.

Contract Assets:

Our contract assets may include cost and estimated earnings in excess of billings that represent amounts earned and reimbursable under contracts, including claim recovery estimates, but have a conditional right for billing and payment such as achievement of milestones or completion of the project. With the exception of customer affirmative claims, generally, such unbilled amounts will become billable according to the contract terms and generally will be billed and collected over the next three months. Settlement with the customer of outstanding affirmative claims is dependent on the claims resolution process and could extend beyond one year. Based on our historical experience, we generally consider the collection risk related to billable amounts to be low. When events or conditions indicate that it is probable that the amounts outstanding become unbillable, the transaction price and associated contract asset is reduced.

Contract Liabilities:

Our contract liabilities may consist of provisions for losses and billings in excess of costs and estimated earnings. Provisions for losses are recognized in the consolidated statements of income at the uncompleted performance obligation level for the amount of total estimated losses in the period that evidence indicates that the estimated total cost of a performance obligation exceeds its estimated total revenue. Billings in excess of costs and estimated earnings are billings to customers on contracts in advance of work performed, including advance payments negotiated as a contract condition. Generally, unearned project-related costs will be earned over the next twelve months.

Income Taxes

The Company and all subsidiaries file a consolidated federal and various state income tax returns on a fiscal year basis. With few exceptions, the Company is no longer subject to U.S. federal, state, or local income tax examinations for years ended prior to September 30, 2017.

The Company follows the liability method of accounting for income taxes in accordance with the Income Taxes topic of the ASC 740. Under this method, deferred tax assets and liabilities are recorded for future tax consequences of temporary differences between financial reporting and tax bases of assets and liabilities and are measured using the enacted tax rates and laws that are expected to be in effect when the underlying assets or liabilities are recovered or settled. A valuation allowance is established to reduce deferred tax assets if it is more likely than not that a portion of the deferred tax asset will not be realized.

U.S. GAAP also prescribes a comprehensive model for how companies should recognize, measure, present and disclose in their financial statements uncertain tax positions taken or to be taken on a tax return. This evaluation is a two-step process.  First, the recognition process determines if it is more likely than not that a tax position will be sustained based on the merits of the tax position upon examination by the appropriate taxing authority.  Second, a measurement process is calculated to determine the amount of benefit/expense to recognize in the financial statements if a tax position meets the more likely than not recognition threshold.  The tax position is measured at the greatest amount of benefit/expense that is more likely than not of being realized upon ultimate settlement.  Any interest and penalty related to the unrecognized tax benefits, as the result of recognition of tax obligations resulting from uncertain tax positions, are included in the provision for income taxes. The Company had not recognized any uncertain tax positions at March 31, 2021.

Claims

Claims are amounts in excess of the agreed contract price that a contractor seeks to collect from customers or others for customer-caused delays, errors in specifications and designs, contract terminations, change orders in dispute or unapproved as to both scope and price, or other causes of unanticipated additional costs. The Company records revenue on claims that have a high probability of success. Revenue from a claim is recorded only to the extent that contract costs relating to the claim have been incurred.

Self-Insurance

The Company has its workers’ compensation, general liability and auto insurance through a captive insurance company. While the Company believes that this arrangement has been very beneficial in reducing and stabilizing insurance costs; the Company does have to maintain a surety deposit to guarantee payments of premiums. That account had a balance of $2.1 million as of March 31, 2021. Should the captive insurance company experience severe losses over an extended period, it could have a detrimental effect on the Company.

Current and Non-Current Accounts Receivable and Provision for Doubtful Accounts

The Company provides an allowance for doubtful accounts when collection of an account is considered doubtful. Inherent in the assessment of the allowance for doubtful accounts are certain judgments and estimates relating to, among others, our customers’ access to capital, our customers’ willingness or ability to pay, general economic conditions and the ongoing relationship with the customers. While most of our customers are large well capitalized companies, should they experience material changes in their revenues and cash flows or incur other difficulties and not be able to pay the amounts owed, this could cause reduced cash flows and losses in excess of our current reserves. At March 31, 2021, the management review deemed that the allowance for doubtful accounts was adequate.

Operating Leases

In February 2016, the FASB issued ASU 2016-02, “Leases (Topic 842)”. ASU 2016-02 is effective for public business entities for fiscal years beginning after December 15, 2018 including interim periods within those fiscal years. Among other things, lessees are required to recognize the following for all leases (except for short-term leases) at the commencement date: a lease liability, which is a lessee’s obligation to make lease payments arising from a lease, measured on a discounted basis; and a right-of-use asset, which is an asset that represents the lessee’s right to use, or control the use of, a specified asset for the lease term. It is the Company’s preference to acquire equipment needed for long-term use through purchase, by cash or finance. For equipment needed on a short-term basis, the Company will enter into short-term rental agreements with the equipment provider where the agreement is cancellable at any time. The adoption of ASU 2016-02 had an immaterial impact, if any, on its consolidated financial statements.

The Company rents equipment for use on construction projects with rental agreements being week to week or month to month. Rental expense can vary by fiscal year due to equipment requirements on construction projects and the availability of Company owned equipment. Rental expense, which is included in cost of goods sold on the Consolidated Income Statement, was $1.9 million and $1.2 million for the six months ended March 31, 2021 and 2020, respectively.

Goodwill and other intangible assets

Assets acquired and liabilities assumed as part of a business acquisition are generally recorded at their fair value at the date of acquisition. The excess of purchase price over the fair value of assets acquired and liabilities assumed is recorded as goodwill. Determining fair value of identifiable assets, particularly intangibles, and liabilities acquired also requires management to make estimates, which are based on all available information and in some cases assumptions with respect to the timing and amount of future revenues and expenses associated with an asset. The process of evaluating the potential impairment of goodwill is subjective and requires significant judgment at many points during the analysis, including the identification of our reporting units, identification and allocation of the assets and liabilities to each of our reporting units and determination of fair value. In estimating the fair value of a reporting unit for the purposes of our annual or periodic impairment analyses, we make estimates and significant judgments about the future cash flows of that reporting unit. Our cash flow forecasts are based on assumptions that represent the highest and best use for our reporting units. Changes in judgment on these assumptions and estimates could result in further goodwill impairment charges.

New Accounting Pronouncements

In January 2017, the FASB issued ASU 2017-04, “Intangibles-Goodwill and Other (Topic 350): Simplifying the Test for Goodwill Impairment”. ASU 2017-04 is effective for public business entities for fiscal years beginning after December 15, 2019 including interim periods within those fiscal years. The update was issued to simplify the subsequent measurement of goodwill by eliminating Step 2 from the goodwill impairment test. Under the amendments in this Update, an entity should perform its annual, or interim, goodwill impairment test by comparing the fair value of a reporting unit with its carrying amount. An entity should recognize an impairment charge for the amount by which the carrying amount exceeds the reporting unit’s fair value; however, the loss recognized should not exceed the total amount of goodwill allocated to that reporting unit. Additionally, an entity should consider income tax effects from any tax-deductible goodwill on the carrying amount of the reporting unit when measuring the goodwill impairment loss, if applicable. The Company has adopted ASU 2017-04 and it did not have a material impact on its financial statements or disclosure.

Subsequent Events

On April 30, 2021, the Company’s Nitro subsidiary completed the purchase of Revolt Energy, Inc. (“Revolt Energy”, a Delaware corporation located in Nitro, WV for $150,000. Revolt Energy will operate primarily in West Virginia as a solar installation division of Nitro. All employees of Revolt Energy agreed to employment with Nitro. Revolt’s construction workers are union members of the International Brotherhood of Electrical Workers and are subject to collective bargaining agreements that expire at varying time intervals.

Management has evaluated subsequent events through May 12, 2021, the date which the financial statements were available for issue.  There have been no other material events during the period, other than noted above, that would either impact the results reflected in the report or the Company’s results going forward.

Outlook

The following statements are based on current expectations. These statements are forward looking, and actual results may differ materially.

As a contractor providing electrical, mechanical, HVAC and underground piping installation and maintenance services to customers in the petroleum, natural gas, public utilities and power industries, the Company and its subsidiaries are considered an “Essential Business” in the various states in which it operates. While it is unknown how long the COVID-19 virus will last and what the complete financial effect will be to the Company, the coronavirus outbreak is expected to have a significant effect on the Company's 2021 operating results. As of March 31, 2021, many of the Company’s existing customers had resumed projects that were affected by the March 2020 shutdowns. As a result, the Company has increased its employment level of construction personnel as compared to March 31, 2020. Given the uncertainty regarding the spread of this coronavirus, the related financial impact on the Company’s results of operations, financial position, and liquidity or capital resources cannot be reasonably estimated at this time.

Currently, the Company is receiving bid opportunities from existing and potentially new customers; however, gas transmission bid opportunities have been fewer and are being released later than expected. The Company is experiencing greater competition due to both the number of non-union and larger union competitors bidding on and driving down pricing on smaller transmission projects. The Company is working to increase the number of transmission customers in which it has master services agreements in order to increase bidding opportunities. The Company is experiencing a greater demand for its gas and water distribution services. The Company’s backlog at March 31, 2021 was $61.2 million. While adding additional projects appears likely, no assurances can be given that the Company will be successful in bidding on projects that become available. Moreover, even if the Company obtains contracts, there can be no guarantee that the projects will go forward.

With the recent acquisitions of West Virginia Pipeline and Revolt and the start-up of SQP, the Company believes it has made additions that will help diversify its services provided and that will lead to greater opportunities for future growth and profitability.

ITEM 3. Quantitative and Quantitative Disclosures About Market Risk

Not required for a smaller reporting company.

ITEM 4. Controls and Procedures

Under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer, we evaluated the effectiveness of the design and operation of our disclosure controls and procedures (as defined in Rule 13a-15(e) under the Securities Exchange Act of 1934) as of the end of the period covered by this report. Based upon that evaluation, the Chief Executive Officer and Chief Financial Officer concluded that, as of the end of the period covered by this report, our disclosure controls and procedures were effective to ensure that information required to be disclosed in the reports that Energy Services of America Corporation files or submits under the Securities Exchange Act of 1934, is (1) recorded, processed, summarized and reported, within the time periods specified in the SEC’s rules and forms, and (2) accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate to allow timely decisions regarding required disclosure.

There has been no change in Energy Services of America Corporation’s internal control over financial reporting during Energy Services of America Corporation’s second quarter of fiscal year 2021 that has materially affected, or is reasonably likely to materially affect, Energy Services of America Corporation’s internal control over financial reporting.

PART II

OTHER INFORMATION

ITEM 1. Legal Proceedings

In February 2018, the Company filed a lawsuit against a former customer related to a dispute over changes on a pipeline construction project. The Company is seeking $10.0 million in the lawsuit, none of which has been recognized in the Company’s financial statements. Although no trial date has been set, the Company expects the case to go to trial in fiscal year 2021 barring a mediation settlement between the parties. Other than described above, at March 31, 2021, the Company was not involved in any legal proceedings other than in the ordinary course of business. The Company is a party from time to time to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, punitive damages, civil penalties or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims, and proceedings, we record reserves when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. At March 31, 2021, the Company does not believe that any of these proceedings, separately or in aggregate, would be expected to have a material adverse effect on our financial position, results of operations or cash flows.

ITEM 1A. Risk Factors

Please see the information disclosed in the “Risk Factors” section of our Annual Report on Form 10-K as filed with the Securities and Exchange Commission on January 4, 2021. There have been no material changes to the risk factors since the filing of the Annual Report on Form 10-K.

ITEM 2. Unregistered Sales of Equity Securities and Use of Proceeds.

(a) There have been no unregistered sales of equity securities during the period covered by the report.

(b)  None.

(c)  There were no repurchases of Energy Services of America Corporation’s shares of its common stock during the three months ended March 31, 2021.

ITEM 6. Exhibits

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the Company has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

ENERGY SERVICES OF AMERICA CORPORATION