Annual Statements Open main menu

Primoris Services Corp - Quarter Report: 2017 June (Form 10-Q)

Table of Contents 

 

 

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

 

FORM 10-Q

 

(Mark One)

 

QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934.

 

For the quarterly period ended June 30, 2017

 

OR

 

TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934.

 

For the transition period from                    to                      .

 

Commission file number 0001-34145

 

Primoris Services Corporation

(Exact name of registrant as specified in its charter)

 

Delaware

    

20-4743916

(State or Other Jurisdiction of

 

(I.R.S. Employer

Incorporation or Organization)

 

Identification No.)

 

 

 

2100 McKinney Avenue, Suite 1500

 

 

Dallas, Texas

 

75201

(Address of Principal Executive Offices)

 

(Zip Code)

 

Registrant’s telephone number, including area code: (214) 740-5600

 

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.  Yes ☒  No ☐

 

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (Section 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files).  Yes  ☒ No ☐

 

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definitions of “large accelerated filer”, “accelerated filer”, “smaller reporting company”, and “emerging growth company” in Rule 12b-2 of the Exchange Act. (Check one):

 

 

 

Large accelerated filer  ☒

    

Accelerated filer  ☐

 

 

 

Non-accelerated filer  ☐

 

Smaller reporting company  ☐

Do not check if a smaller reporting company.

 

 

 

 

Emerging growth company  ☐

 

      If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

 

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).  Yes ☐  No ☒

 

At August 7, 2017, 51,437,305 shares of the registrant’s common stock, par value $0.0001 per share, were outstanding.

 

 

 

 


 

Table of Contents 

PRIMORIS SERVICES CORPORATION

 

INDEX

 

 

    

Page No.

 

 

 

Part I. Financial Information 

 

 

 

 

 

 

 

 

 

 

 

—Condensed Consolidated Balance Sheets at June 30, 2017 (Unaudited) and December 31, 2016 

 

3

 

 

 

—Condensed Consolidated Statements of Income for the three and six months ended June 30, 2017 and 2016 (Unaudited) 

 

4

 

 

 

— Condensed Consolidated Statements of Cash Flows for the six months ended June 30, 2017 and 2016 (Unaudited) 

 

5

 

 

 

—Notes to Condensed Consolidated Financial Statements (Unaudited) 

 

7

 

 

 

Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations 

 

27

 

 

 

Item 3. Quantitative and Qualitative Disclosures About Market Risk 

 

43

 

 

 

Item 4. Controls and Procedures 

 

43

 

 

 

Part II. Other Information 

 

 

 

 

 

Item 1. Legal Proceedings 

 

44

 

 

 

Item 1A. Risk Factors 

 

44

 

 

 

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds 

 

44

 

 

 

Item 3. Defaults Upon Senior Securities 

 

44

 

 

 

Item 4. (Removed and Reserved) 

 

44

 

 

 

Item 5. Other Information 

 

44

 

 

 

Item 6. Exhibits 

 

45

 

 

 

Signatures 

 

46

 

2


 

Table of Contents 

PART I.  FINANCIAL INFORMATION

 

ITEM 1.  FINANCIAL STATEMENTS

 

PRIMORIS SERVICES CORPORATION

CONDENSED CONSOLIDATED BALANCE SHEETS

(In Thousands, Except Share Amounts)

(Unaudited)

 

 

 

 

 

 

 

 

 

 

 

June 30, 

 

 

December 31, 

 

 

    

2017

    

2016

 

ASSETS

 

 

 

 

 

 

 

Current assets:

 

 

 

 

 

 

 

Cash and cash equivalents ($48,094 and $7,045 related to VIEs. See Note 11)

 

$

111,676

 

$

135,823

 

Customer retention deposits

 

 

906

 

 

481

 

Accounts receivable, net

 

 

355,231

 

 

388,000

 

Costs and estimated earnings in excess of billings

 

 

158,741

 

 

138,618

 

Inventory and uninstalled contract materials

 

 

42,318

 

 

49,201

 

Prepaid expenses and other current assets

 

 

16,082

 

 

19,258

 

Total current assets

 

 

684,954

 

 

731,381

 

Property and equipment, net

 

 

309,013

 

 

277,346

 

Intangible assets, net

 

 

51,228

 

 

32,841

 

Goodwill

 

 

150,672

 

 

127,226

 

Other long-term assets

 

 

1,624

 

 

2,004

 

Total assets

 

$

1,197,491

 

$

1,170,798

 

LIABILITIES AND STOCKHOLDERS’ EQUITY

 

 

 

 

 

 

 

Current liabilities:

 

 

 

 

 

 

 

Accounts payable

 

$

134,091

 

$

168,110

 

Billings in excess of costs and estimated earnings

 

 

158,698

 

 

112,606

 

Accrued expenses and other current liabilities

 

 

116,244

 

 

108,006

 

Dividends payable

 

 

2,829

 

 

2,839

 

Current portion of capital leases

 

 

186

 

 

188

 

Current portion of long-term debt

 

 

58,031

 

 

58,189

 

Current portion of contingent earnout liabilities

 

 

1,213

 

 

 —

 

Total current liabilities

 

 

471,292

 

 

449,938

 

Long-term capital leases, net of current portion

 

 

170

 

 

15

 

Long-term debt, net of current portion

 

 

183,140

 

 

203,381

 

Deferred tax liabilities

 

 

9,830

 

 

9,830

 

Other long-term liabilities

 

 

11,623

 

 

9,064

 

Total liabilities

 

 

676,055

 

 

672,228

 

Commitments and contingencies

 

 

 

 

 

 

 

Stockholders’ equity

 

 

 

 

 

 

 

Common stock—$.0001 par value; 90,000,000 shares authorized; 51,437,305 and 51,576,442 issued and outstanding at June 30, 2017 and December 31, 2016

 

 

 5

 

 

 5

 

Additional paid-in capital

 

 

159,761

 

 

162,128

 

Retained earnings

 

 

358,779

 

 

335,218

 

Non-controlling interest

 

 

2,891

 

 

1,219

 

Total stockholders’ equity

 

 

521,436

 

 

498,570

 

Total liabilities and stockholders’ equity

 

$

1,197,491

 

$

1,170,798

 

 

See Accompanying Notes to Condensed Consolidated Financial Statements

3


 

Table of Contents 

PRIMORIS SERVICES CORPORATION

CONDENSED CONSOLIDATED STATEMENTS OF INCOME

(In Thousands, Except Per Share Amounts)

(Unaudited)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended

 

Six Months Ended

 

 

 

June 30, 

 

June 30, 

 

 

    

2017

    

2016

    

2017

    

2016

 

Revenue

 

$

631,165

 

$

456,811

 

$

1,192,667

 

$

887,257

 

Cost of revenue

 

 

546,682

 

 

413,526

 

 

1,053,131

 

 

804,695

 

Gross profit

 

 

84,483

 

 

43,285

 

 

139,536

 

 

82,562

 

Selling, general and administrative expenses

 

 

45,977

 

 

32,498

 

 

85,831

 

 

65,156

 

Operating income

 

 

38,506

 

 

10,787

 

 

53,705

 

 

17,406

 

Other income (expense):

 

 

 

 

 

 

 

 

 

 

 

 

 

Foreign exchange gain

 

 

109

 

 

21

 

 

132

 

 

380

 

Other expense

 

 

(13)

 

 

 —

 

 

(13)

 

 

 —

 

Interest income

 

 

114

 

 

52

 

 

183

 

 

91

 

Interest expense

 

 

(2,145)

 

 

(2,240)

 

 

(4,407)

 

 

(4,508)

 

Income before provision for income taxes

 

 

36,571

 

 

8,620

 

 

49,600

 

 

13,369

 

Provision for income taxes

 

 

(14,175)

 

 

(3,333)

 

 

(18,692)

 

 

(5,166)

 

Net income

 

$

22,396

 

$

5,287

 

$

30,908

 

$

8,203

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Less net income attributable to noncontrolling interests

 

 

(851)

 

 

(231)

 

$

(1,672)

 

$

(454)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net income attributable to Primoris

 

$

21,545

 

$

5,056

 

$

29,236

 

$

7,749

 

Earnings per share:

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

$

0.42

 

$

0.10

 

$

0.57

 

$

0.15

 

Diluted

 

$

0.42

 

$

0.10

 

$

0.56

 

$

0.15

 

Weighted average common shares outstanding:

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

 

51,437

 

 

51,772

 

 

51,515

 

 

51,749

 

Diluted

 

 

51,688

 

 

52,022

 

 

51,771

 

 

51,950

 

 

See Accompanying Notes to Condensed Consolidated Financial Statements

 

4


 

Table of Contents 

 

PRIMORIS SERVICES CORPORATION

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

(In Thousands)

(Unaudited)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Six Months Ended

 

 

 

June 30, 

 

 

    

2017

    

2016

 

Cash flows from operating activities:

 

 

 

 

 

 

 

Net income

 

$

30,908

 

$

8,203

 

Adjustments to reconcile net income to net cash provided by operating activities:

 

 

 

 

 

 

 

Depreciation

 

 

28,139

 

 

30,850

 

Amortization of intangible assets

 

 

3,611

 

 

3,239

 

Intangible asset impairment

 

 

477

 

 

 —

 

Stock-based compensation expense

 

 

690

 

 

710

 

Gain on sale of property and equipment

 

 

(3,208)

 

 

(2,293)

 

Changes in assets and liabilities:

 

 

 

 

 

 

 

Customer retention deposits

 

 

(425)

 

 

(435)

 

Accounts receivable

 

 

43,792

 

 

2,514

 

Costs and estimated earnings in excess of billings

 

 

(19,572)

 

 

(17,151)

 

Other current assets

 

 

11,920

 

 

2,708

 

Other long-term assets

 

 

380

 

 

(747)

 

Accounts payable

 

 

(37,060)

 

 

(11,065)

 

Billings in excess of costs and estimated earnings

 

 

45,791

 

 

(17,584)

 

Accrued expenses and other current liabilities

 

 

8,154

 

 

7,337

 

Other long-term liabilities

 

 

2,692

 

 

(788)

 

Net cash provided by operating activities

 

 

116,289

 

 

5,498

 

Cash flows from investing activities:

 

 

 

 

 

 

 

Purchase of property and equipment

 

 

(44,697)

 

 

(42,140)

 

Proceeds from sale of property and equipment

 

 

4,664

 

 

5,723

 

Cash paid for acquisitions

 

 

(66,205)

 

 

(4,108)

 

Net cash used in investing activities

 

 

(106,238)

 

 

(40,525)

 

Cash flows from financing activities:

 

 

 

 

 

 

 

Repayment of capital leases

 

 

(117)

 

 

(468)

 

Repayment of long-term debt

 

 

(24,562)

 

 

(24,262)

 

Proceeds from issuance of common stock purchased under a long-term incentive plan

 

 

1,148

 

 

1,439

 

Repurchase of common stock

 

 

(4,999)

 

 

 —

 

Dividends paid

 

 

(5,668)

 

 

(5,689)

 

Net cash used in financing activities

 

 

(34,198)

 

 

(28,980)

 

Net change in cash and cash equivalents

 

 

(24,147)

 

 

(64,007)

 

Cash and cash equivalents at beginning of the period

 

 

135,823

 

 

161,122

 

Cash and cash equivalents at end of the period

 

$

111,676

 

$

97,115

 

 

See Accompanying Notes to Condensed Consolidated Financial Statements

5


 

Table of Contents 

SUPPLEMENTAL DISCLOSURES OF CASH FLOW INFORMATION

 

 

 

 

 

 

 

 

 

 

 

Six Months Ended June 30, 

 

 

    

2017

    

2016

 

 

 

(Unaudited)

 

Cash paid:

 

 

 

 

 

 

 

Interest

 

$

4,663

 

$

4,412

 

 

 

 

 

 

 

 

 

Income taxes, net of refunds received

 

$

15,554

 

$

1,299

 

 

SUPPLEMENTAL DISCLOSURES OF NONCASH INVESTING AND FINANCING ACTIVITIES

 

 

 

 

 

 

 

 

 

 

 

Six Months Ended June 30, 

 

 

    

2017

    

2016

 

 

 

(Unaudited)

 

Obligations incurred for the acquisition of property

 

$

4,163

 

$

 —

 

 

 

 

 

 

 

 

 

Dividends declared and not yet paid

 

$

2,829

 

$

2,847

 

 

 

See Accompanying Notes to Condensed Consolidated Financial Statements

 

6


 

Table of Contents 

PRIMORIS SERVICES CORPORATION

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(Dollars In Thousands, Except Share and Per Share Amounts)

(Unaudited)

 

Note 1—Nature of Business

 

Organization and operations  Primoris Services Corporation is a holding company of various construction and product engineering subsidiaries. The Company’s underground and directional drilling operations install, replace and repair natural gas, petroleum, telecommunications and water pipeline systems, including large diameter pipeline systems. The Company’s industrial, civil and engineering operations build and provide maintenance services to industrial facilities including power plants, petrochemical facilities, and other processing plants; construct multi-level parking structures; and engage in the construction of highways, bridges and other environmental construction activities. The Company is incorporated in the State of Delaware, and its corporate headquarters is located at 2100 McKinney Avenue, Suite 1500, Dallas, Texas 75201.

 

Reportable Segments — Through the end of the year 2016, the Company segregated its business into three reportable segments: the Energy segment, the East Construction Services segment and the West Construction Services segment. In the first quarter 2017, the Company changed its reportable segments in connection with a realignment of the Company’s internal organization and management structure. The segment changes during the quarter reflect the focus of our chief operating decision maker (“CODM”) on the range of services we provide to our end user markets. Our CODM regularly reviews the operating and financial performance of our business units based on these segments.

 

The current reportable segments include the Power, Industrial and Engineering (“Power”) segment, the Pipeline and Underground (“Pipeline”) segment, the Utilities and Distribution (“Utilities”) segment and the Civil segment.  Segment information for prior periods have been restated to conform to the new segment presentation.  See Note 18 – “Reportable Segments” for a brief description of the reportable segments and their operations.

 

The classification of our business unit revenues and gross profit for segment reporting purposes can at times require judgment on the part of management. Our business units may perform services across industries or perform joint services for customers in multiple industries. To determine reportable segment gross profit, certain allocations, including allocations of shared and indirect costs, such as facility costs, equipment costs and indirect operating expenses were made.

 

7


 

Table of Contents 

The following table lists the Company’s primary business units and their reportable segment:

 

 

 

 

 

 

 

Subsidiary

    

Reportable Segment

    

Prior Operating Segment

 

ARB Industrial (a division of ARB, Inc.)

 

Power

 

West

 

ARB Structures

 

Power

 

West

 

Primoris Power (formerly PES Saxon division)

 

Power

 

Energy

 

Primoris Renewable Energy (a division of Primoris Aevenia, Inc.)

 

Power

 

Energy

 

Primoris Industrial Constructors (formerly PES Industrial Division)

 

Power

 

Energy

 

Primoris Fabrication (a division of PES)

 

Power

 

Energy

 

Primoris Mechanical Contractors (a combination of a division of PES and Cardinal Contractors)

 

Power

 

Energy

 

OnQuest

 

Power

 

Energy

 

OnQuest Canada

 

Power

 

Energy

 

Primoris Design and Construction (“PD&C”); created 2017

 

Power

 

NA

 

Rockford Corporation (“Rockford”)

 

Pipeline

 

West

 

Vadnais Trenchless Services (“Vadnais Trenchless”)

 

Pipeline

 

West

 

Primoris Field Services (a division of PES Primoris Pipeline)

 

Pipeline

 

Energy

 

Primoris Pipeline (a division of PES Primoris Pipeline)

 

Pipeline

 

Energy

 

Primoris Coastal Field Services; created 2017

 

Pipeline

 

NA

 

ARB Underground (a division of ARB, Inc.)

 

Utilities

 

West

 

Q3 Contracting (“Q3C”)

 

Utilities

 

West

 

Primoris AV

 

Utilities

 

Energy

 

Primoris Distribution Services; created 2017

 

Utilities

 

NA

 

Primoris Heavy Civil (formerly JCG Heavy Civil Division)

 

Civil

 

East

 

Primoris I&M (formerly JCG Infrastructure & Maintenance Division)

 

Civil

 

East

 

BW Primoris

 

Civil

 

East

 

 

The Company owns a 50% interest in two separate joint ventures, both formed in 2015.  The Carlsbad Power Constructors joint venture (“Carlsbad”) is engineering and constructing a gas-fired power generation facility, and the “ARB Inc. & B&M Engineering Co.” joint venture (“Wilmington”) is also engineering and constructing a gas-fired power generation facility.  Both projects are located in the Southern California area.  The joint venture operations are included as part of the Power division of the Power segment.  As a result of determining that the Company is the primary beneficiary of the two variable interest entities (“VIEs”), the results of the Carlsbad and Wilmington joint ventures are consolidated in the Company’s financial statements.  Both projects are expected to be completed in 2018.  Financial information for the joint ventures is presented in Note 11 – “Noncontrolling Interests”.

 

On January 29, 2016, the Company acquired the net assets of Mueller Concrete Construction Company (“Mueller”) for $4.1 million, and on November 18, 2016, the Company acquired the net assets of Northern Energy & Power (“Northern”) for $6.8 million.  On May 26, 2017, the Company acquired the net assets of Florida Gas Contractors (“FGC”) for $37.7 million, on May 30, 2017 the Company acquired certain engineering assets for approximately $2.3 million, and on June 16, 2017, the Company acquired the net assets of Coastal Field Services (“Coastal”) for $27.5 million.  Both Mueller and FGC operations are included in the Utilities segment, Northern operations are included in the Power segment, and Coastal operations are included in the Pipeline segment.  See Note 7— “Business Combinations”.

 

Unless specifically noted otherwise, as used throughout these consolidated financial statements, “Primoris”, “the Company”, “we”, “our”, “us” or “its” refers to the business, operations and financial results of the Company and its wholly-owned subsidiaries.

 

Note 2—Basis of Presentation

 

Interim consolidated financial statements  The interim condensed consolidated financial statements for the three and six month periods ended June 30, 2017 and 2016 have been prepared in accordance with Rule 10-01 of Regulation S-X of the Securities Exchange Act of 1934, as amended (the “Exchange Act”). As such, certain disclosures, which would substantially duplicate the disclosures contained in the Company’s Annual Report on Form 10-K, filed on February 28, 2017, which contains the Company’s audited consolidated financial statements for the year ended December 31, 2016, have been omitted. 

8


 

Table of Contents 

 

This Second Quarter 2017 Report should be read in concert with the Company’s most recent Annual Report on Form 10-K. The interim financial information is unaudited.  In the opinion of management, the interim information includes all adjustments (consisting of normal recurring adjustments) necessary for the fair presentation of the interim financial information. 

 

Revenue recognition

 

Fixed-price contracts — Historically, a substantial portion of the Company’s revenue has been generated under fixed-price contracts.  For fixed-price contracts, the Company recognizes revenues primarily using the percentage-of-completion method, which may result in uneven and irregular results. In the percentage-of-completion method, estimated contract values, estimated cost at completion and total costs incurred to date are used to calculate revenues earned. Unforeseen events and circumstances can alter the estimate of the costs and potential profit associated with a particular contract.  Total estimated costs, and thus contract revenues and income, can be impacted by changes in productivity, scheduling, the unit cost of labor, subcontracts, materials and equipment. Additionally, external factors such as weather, client needs, client delays in providing permits and approvals, labor availability, governmental regulation and politics may affect the progress of a project’s completion and thus the timing of revenue recognition.  To the extent that original cost estimates are modified, estimated costs to complete increase, delivery schedules are delayed, or progress under a contract is otherwise impeded, cash flow, revenue recognition and profitability from a particular contract may be adversely affected.

 

Other contract forms — The Company also uses unit price, time and material, and cost reimbursable plus fee contracts.  For these jobs, revenue is recognized primarily based on contractual terms. Generally, time and material and cost reimbursement contract revenues are recognized on an input basis, based on labor hours incurred and on purchases made.  Unit price contracts generally recognize revenue on an output based measurement such as the completion of specific units at a specified unit price.

 

The Company considers unapproved change orders to be contract variations for which customers have not agreed to both scope and price.  Costs associated with unapproved change orders are included in the estimated cost to complete and are treated as project costs as incurred. The Company will recognize revenue if it is probable that the contract price will be adjusted and can be reliably estimated.  Unapproved change orders involve the use of estimates, and it is reasonably possible that revisions to the estimated costs and recoverable amounts may be required in future reporting periods to reflect changes in estimates or final agreements with customers.

 

The Company considers claims to be amounts it seeks, or will seek, to collect from customers or others for customer-caused changes in contract specifications or design, or other customer-related causes of unanticipated additional contract costs on which there is no agreement with customers. Claims can also be caused by non-customer-caused changes, such as weather delays or rain.  Costs associated with claims are included in the estimated costs to complete the contracts and are treated as project costs when incurred.  Claims are included in revenue to the extent the related costs have been incurred, realization is probable, and amounts can be reliably estimated.  Revenue in excess of contract costs from claims is recognized when an agreement is reached with customers as to the value of the claims, which in some instances may not occur until after completion of work under the contract.

 

At any time, if an estimate of total contract cost indicates a loss on a contract, the projected loss is recognized in full at that time and recognized as an “accrued loss provision” which is included in the accrued expenses and other current liabilities amount on the balance sheet. For fixed price contracts, as the percentage-of-completion method is used to calculate revenues, the accrued loss provision is changed so that the gross profit for the contract remains zero in future periods. If we anticipate that there will be a loss for unit price or cost reimbursable contracts, the projected loss is recognized in full at that time.

 

Changes in job performance, job conditions and estimated profitability, including those arising from final contract settlements, may result in revisions to costs and income. These revisions are recognized in the period in which the revisions are identified.

 

9


 

Table of Contents 

In all forms of contracts, the Company estimates its collectability of contract amounts at the same time that it estimates project costs.  If the Company anticipates that there may be issues associated with the collectability of the full amount calculated as revenues, the Company may reduce the amount recognized as revenue to reflect the uncertainty associated with realization of the eventual cash collection. For example, when a cost reimbursable project exceeds the client’s expected budget amount, the client frequently requests an adjustment to the final amount. Similarly, some utility clients reserve the right to audit costs for significant periods after performance of the work. In these situations, the Company may choose to defer recognition of revenue until the client pays for the services.

 

The caption “Costs and estimated earnings in excess of billings” in the Consolidated Balance Sheets represents unbilled receivables which arise when revenues have been recorded but the amount will not be billed until a later date.  Balances represent:  (a) unbilled amounts arising from the use of the percentage-of-completion method of accounting which may not be billed under the terms of the contract until a later date or project milestone; (b) incurred costs to be billed under cost reimbursement type contracts; (c) amounts arising from routine lags in billing; or (d) the revenue associated with unapproved change orders or claims when realization is probable and amounts can be reliably determined.  For those contracts in which billings exceed contract revenues recognized to date, the excess amounts are included in the caption “Billings in excess of costs and estimated earnings”.

 

In accordance with applicable terms of certain construction contracts, retainage amounts may be withheld by customers until completion and acceptance of the project.  Some payments of the retainage may not be received for a significant period after completion of our portion of a project.  In some jurisdictions, retainage amounts are deposited into an escrow account.

 

Significant revisions in contract estimates  Revenue recognition is based on the percentage-of-completion method for firm fixed-price contracts. Under this method, the costs incurred to date as a percentage of total estimated costs are used to calculate revenue. Total estimated costs, and thus contract revenues and margin, are impacted by many factors, which can cause significant changes in estimates during the life cycle of a project.

 

For projects that were in process at the end of the prior year or a prior quarter, there can be a difference in revenues and profits that would have been recognized in the prior year or prior quarter had current estimates of costs to complete been used at the end of the prior year or prior quarter.

 

Customer concentration — The Company operates in multiple industry segments encompassing the engineering and construction of commercial, industrial and public works infrastructure assets throughout primarily the United States. Typically, the top ten customers in any one calendar year generate revenues in excess of 50% of total revenues; however, the group that comprises the top ten customers varies from year to year.

 

During the three and six months ended June 30, 2017, revenues generated by the top ten customers were approximately $330.2 million and $713.5 million, respectively, which represented 52.3% and 59.8%, respectively, of total revenues during the period. During the periods, two large pipeline projects represented 11.0% and 19.2% of total revenues, respectively and Texas Department of Transportation (“TXDOT”) represented 10.6% and 10.5% of total revenues, respectively.

 

During the three and six months ended June 30, 2016, revenues generated by the top ten customers were $263.0 million and $533.0 million, respectively, which represented 57.7% and 60.1%, respectively, of total revenues during the period.  During the periods, a Louisiana petrochemical project represented 11.3% and 12.4% of total revenues, respectively and TXDOT represented 10.2% and 11.8% of total revenues, respectively.

 

At June 30, 2017, approximately 11.7% of the Company’s accounts receivable were due from one customer, and that customer provided 8.8% of the Company’s revenues for the six months ended June 30, 2017. In addition, of total accounts receivable, approximately 11.0% are from one customer with whom the Company is currently in dispute resolution. See Note 17 – “Commitments and Contingencies”.

 

At June 30, 2016, approximately 15.6% of the Company’s accounts receivable were due from one customer, and that customer provided 12.4% of the Company’s revenues for the six months ended June 30, 2016. In addition, approximately 16.0% of total accounts receivable at June 30, 2016 were in dispute resolution.

 

10


 

Table of Contents 

Multiemployer plans  Various subsidiaries are signatories to collective bargaining agreements.  These agreements require that the Company participate in and contribute to a number of multiemployer benefit plans for its union employees at rates determined by the agreements. The trustees for each multiemployer plan determine the eligibility and allocations of contributions and benefit amounts, determine the types of benefits, and administer the plan. Federal law requires that if the Company were to withdraw from an agreement, it would incur a withdrawal obligation. The potential withdrawal obligation may be significant. In accordance with Generally Accepted Accounting Principles (“GAAP”), any withdrawal liability would be recorded when it is probable that a liability exists and can be reasonably estimated.

 

Inventory and uninstalled contract materials — Inventory consists of expendable construction materials and small tools that will be used in construction projects and is valued at the lower of cost, using first-in, first-out method, or at net realizable value. Uninstalled contract materials are certain job specific materials not yet installed, primarily for highway construction projects, which are valued using the specific identification method relating the cost incurred to a specific project. In most cases, the Company is able to invoice a state agency for the materials, but title will not pass to the state agency until the materials are installed.

 

Note 3—Recent Accounting Pronouncements

 

In May 2014, the FASB issued ASU No. 2014-09, “Revenue from Contracts with Customers (Topic 606)”, with several clarifying updates issued during 2016. The new standard is effective for reporting periods beginning after December 15, 2017. The new standard will supersede all current revenue recognition standards and guidance.  Revenue recognition will occur when promised goods or services are transferred to customers in amounts that reflect the consideration to which the company expects to be entitled to in exchange for those goods or services. The mandatory adoption will require new qualitative and quantitative disclosures about the nature, amount, timing and uncertainty of revenue and cash flows arising from customer contracts, including significant judgments and changes in judgments, information about contract balances and performance obligations, and assets recognized from costs incurred to obtain or fulfill a contract. The standard permits the “modified retrospective method”, which requires prospective application of the new standard as a cumulative-effect adjustment. The Company expects to adopt this new standard using the modified retrospective method that will result in a cumulative-effect adjustment to retained earnings as of the date of adoption.  The adoption will only apply to customer contracts that are not substantially complete as of January 1, 2018.

 

The Company is currently evaluating the impact of adopting the standard on the Company’s financial position, results of operations, cash flows and related disclosures.  Although it is early in our evaluation process, we do not expect Topic 606 to have a material impact on our financial statements, though internal documentation and record keeping may be significantly impacted.  The impact to our results is not believed to be material because Topic 606 generally supports the recognition of revenue over time under the cost-to-cost method for the majority of our contracts, which is consistent with our current percentage of completion revenue recognition model.  In most of our fixed price contracts, the customer typically controls the work in process as evidenced either by contractual termination clauses or by our rights to payment for work performed to date to deliver services that do not have an alternative use to us. 

 

The Company does not expect the new standard to materially affect the total revenue that can be recognized over the life of a construction project; however, the revenue recognized on a quarterly basis during the construction period may change. We believe that Topic 606 is likely to be more impactful to certain of our lump sum projects as a result of the following potential changes from our current practices:

 

§

Performance obligations – Topic 606 requires a review of contracts and contract modifications to determine whether there are multiple performance obligations.  Each separate performance obligation must be accounted for as a distinct project, which could impact the timing of revenue recognition.  There is a potential that some of our contracts may have multiple performance obligations which may affect the timing of revenue recognition.

 

§

Variable consideration – In accordance with Topic 606, revenue recognition must account for variable consideration, including potential liquidated damages and customer discounts. Currently, we assess the impact of liquidated damages as an estimated cost of the project.  The adoption of the new standard may affect the timing of the recognition of revenue for both liquidated damages and discounts. 

 

11


 

Table of Contents 

§

Mobilization costs – Mobilization costs typically include costs to provide labor, equipment and facilities to a project site and they are recorded currently as project costs as incurred.  Topic 606 requires these costs to be capitalized as an asset and amortized over the duration of the project.

 

§

Significant components – For some projects, we may purchase equipment from a third party, such as micro–LNG equipment, and install the equipment at the project site.  Under today’s standard, the Company recognizes the associated revenue and profit for the equipment.  Depending on the terms of the contract, under the new standard, revenue may be recognized without profit.   

 

We do not expect Topic 606 to have a material impact on our consolidated balance sheets, though we expect certain reclassifications among financial statement accounts to align with the new standard.  We also expect significant expanded disclosures relating to revenue recognized during each period.

 

In February 2016, the FASB issued ASU 2016-02 “Leases (Topic 842)”. The ASU will require recognition of operating leases with lease terms of more than twelve months on the balance sheet as both assets for the rights and liabilities for the obligations created by the leases. The ASU will require disclosures that provide qualitative and quantitative information for the lease assets and liabilities recorded in the financial statements. The guidance is effective for fiscal years beginning after December 15, 2018. The Company is reviewing the impact of the ASU and will establish procedures to adopt the ASU.

 

In March 2016, the FASB issued ASU 2016-09 “Compensation — Stock Compensation (Topic 718) — Improvements to Employee Share-Based Payment Accounting”. The ASU modifies the accounting for excess tax benefits and tax deficiencies associated with share-based payments by requiring that excess tax benefits or deficiencies be included in the income statement rather than in equity.  Additionally, the tax benefits for dividends on share-based payment awards will also be reflected in the income statement. As a result of these modifications, the ASU requires that the tax-related cash flows resulting from share-based payments will be shown on the cash flow statement as operating activities rather than as financing activities. The Company adopted the ASU as of January 1, 2017, which did not have a material impact on the Company’s consolidated financial statements.

 

In January 2017, the FASB issued ASU 2017-01, "Business Combinations (Topic 805): Clarifying the Definition of a Business" which changes the definition of a business to assist entities with evaluating when a set of transferred assets and activities is a business. ASU 2017-01 requires an entity to evaluate if substantially all of the fair value of the gross assets acquired is concentrated in a single identifiable asset or a group of similar identifiable assets; if so, the set of transferred assets and activities is not a business. ASU 2017-01 is effective for interim and annual reporting periods beginning after December 15, 2017. The Company does not expect the adoption of ASU 2017-01 to have an impact on its financial position, results of operations or cash flows.

 

In January 2017, the FASB issued ASU 2017-04, "Simplifying the Test for Goodwill Impairment". ASU 2017-04 removes the second step of the goodwill impairment test, which requires a hypothetical purchase price allocation. A goodwill impairment will now be the amount by which a reporting unit's carrying value exceeds its fair value, not to exceed the carrying amount of goodwill. ASU 2017-04 is effective for interim and annual reporting periods beginning after December 15, 2019 and will be applied prospectively. The Company does not expect the adoption of ASU 2017-04 to have an impact on its financial position, results of operations or cash flows.

 

In May 2017, the FASB issued ASU 2017-09, “Compensation — Stock Compensation (Topic 718) — Scope of Modification Accounting”.  The ASU amends the scope of modification accounting for share-based payment arrangements.  The amendments in the ASU provide guidance on types of changes to the terms or conditions of share-based payment awards would be required to apply modification accounting under ASC 718, “Compensation — Stock Compensation”.  The ASU is effective for interim and annual reporting periods beginning after December 15, 2017 with early adoption permitted. The Company does not expect the adoption of ASU 2017-09 to have an impact on its financial position, results of operations or cash flows.

 

Note 4—Fair Value Measurements

 

ASC Topic 820, “Fair Value Measurements and Disclosures” defines fair value, establishes a framework for measuring fair value in GAAP and requires certain disclosures about fair value measurements.  ASC Topic 820 addresses fair value GAAP for financial assets and financial liabilities that are re-measured and reported at fair value at

12


 

Table of Contents 

each reporting period and for non-financial assets and liabilities that are re-measured and reported at fair value on a non-recurring basis.

 

In general, fair values determined by Level 1 inputs use quoted prices (unadjusted) in active markets for identical assets or liabilities. Fair values determined by Level 2 inputs use data points that are observable such as quoted prices, interest rates and yield curves. Fair values determined by Level 3 inputs are “unobservable data points” for the asset or liability and include situations where there is little, if any, market activity for the asset or liability.

 

The following table presents, for each of the fair value hierarchy levels identified under ASC Topic 820, the Company’s financial assets and liabilities that are required to be measured at fair value at June 30, 2017 and December 31, 2016:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Fair Value Measurements at Reporting Date

 

 

    

 

 

    

 

 

    

Significant

    

 

 

 

 

 

Amount

 

Quoted Prices

 

Other

 

Significant

 

 

 

Recorded

 

in Active Markets

 

Observable

 

Unobservable

 

 

 

on Balance

 

for Identical Assets

 

Inputs

 

Inputs

 

 

 

Sheet

 

(Level 1)

 

(Level 2)

 

(Level 3)

 

Assets as of June 30, 2017:

 

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

111,676

 

$

111,676

 

 —

 

 

 —

 

Liabilities as of June 30, 2017: 

 

 

 

 

 

 

 

 

 

 

 

 

Contingent consideration

 

$

1,213

 

 

 —

 

 —

 

 

1,213

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Assets as of December 31, 2016:

 

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

135,823

 

$

135,823

 

 —

 

 

 —

 

Liabilities as of December 31, 2016: 

 

 

 

 

 

 

 

 

 

 

 

 

    None

 

 

 

 

 

 

 

 

 

 

 

 

 

Other financial instruments of the Company not listed in the table consist of accounts receivable, accounts payable and certain accrued liabilities.  These financial instruments generally approximate fair value based on their short-term nature.  The carrying value of the Company’s long-term debt approximates fair value based on comparison with current prevailing market rates for loans of similar risks and maturities. 

 

The following table provides changes to the Company’s contingent consideration liability Level 3 fair value measurements during the six months ended June 30, 2017 and 2016:

 

 

 

 

 

 

 

 

 

 

 

Significant Unobservable Inputs

 

 

 

(Level 3)

 

Contingent Consideration Liability

    

2017

    

2016

 

Beginning balance, January 1,

 

$

 —

 

$

 —

 

Additions to contingent consideration liability:

 

 

 

 

 

 

 

Florida Gas Contractors acquisition

 

 

1,200

 

 

 —

 

Change in fair value of contingent consideration liability during year

 

 

13

 

 

 —

 

Ending balance, June 30, 

 

$

1,213

 

$

 —

 

 

On a quarterly basis, the Company assesses the estimated fair value of the contractual obligation to pay the contingent consideration and any changes in estimated fair value are recorded as a non-operating charge in the Company’s statement of income.  Fluctuations in the fair value of contingent consideration are impacted by two unobservable inputs, management’s estimate of the probability of the acquired company meeting the contractual operating performance target and the estimated discount rate (a rate that approximates the Company’s cost of capital). Significant changes in either of those inputs in isolation would result in a different fair value measurement.  Generally, a change in the assumption of the probability of meeting the performance target is accompanied by a directionally similar change in the fair value of contingent consideration liability, whereas a change in assumption used of the estimated discount rate is accompanied by a directionally opposite change in the fair value of contingent consideration liability.

 

 

 

13


 

Table of Contents 

Note 5—Accounts Receivable

 

The following is a summary of the Company’s accounts receivable:

 

 

 

 

 

 

 

 

 

 

 

June 30, 

 

December 31, 

 

 

 

2017

 

2016

 

Contracts receivable, net of allowance for doubtful accounts of $1,654 at June 30, 2017 and $1,030 at December 31, 2016, respectively

 

$

294,670

 

$

340,871

 

Retention receivable

 

 

56,251

 

 

46,394

 

 

 

 

350,921

 

 

387,265

 

Other accounts receivable

 

 

4,310

 

 

735

 

 

 

$

355,231

 

$

388,000

 

 

 

Note 6—Costs and Estimated Earnings on Uncompleted Contracts

 

Costs and estimated earnings on uncompleted contracts consist of the following:

 

 

 

 

 

 

 

 

 

 

June 30, 

 

December 31, 

 

 

2017

 

2016

Costs incurred on uncompleted contracts

 

$

4,900,812

 

$

5,391,124

Gross profit recognized

 

 

390,252

 

 

456,871

 

 

 

5,291,064

 

 

5,847,995

Less: billings to date

 

 

(5,291,021)

 

 

(5,821,983)

 

 

$

43

 

$

26,012

 

This amount is included in the accompanying consolidated balance sheets under the following captions:

 

 

 

 

 

 

 

 

 

 

June 30, 

 

December 31, 

 

 

2017

 

2016

Costs and estimated earnings in excess of billings

 

$

158,741

 

$

138,618

Billings in excess of cost and estimated earnings

 

 

(158,698)

 

 

(112,606)

 

 

$

43

 

$

26,012

 

 

Note 7 — Business Combinations

 

On January 29, 2016, the Company’s subsidiary, Primoris AV, acquired certain assets and liabilities of Mueller Concrete Construction Company for $4.1 million. The purchase was accounted for using the acquisition method of accounting.  During the second quarter of 2016, the Company finalized its estimate of fair value of the acquired assets of Mueller, which included $2.0 million of fixed assets, $2.0 million of goodwill and $0.1 million of inventory. Mueller operates as a division of Primoris AV, within the Utilities segment.  Goodwill largely consists of expected benefits from providing foundation expertise for Primoris AV’s construction efforts in underground line work, substations and telecom/fiber.  Goodwill also includes the value of the assembled workforce that the Mueller acquisition provides to the Primoris AV business.  Based on the current tax treatment, goodwill and other intangible assets will be deductible for income tax purposes over a fifteen-year period.

 

On June 24, 2016, the Company’s subsidiary, Vadnais Trenchless, purchased property, plant and equipment from Pipe Jacking Unlimited, Inc., consisting of specialty directional drilling and tunneling equipment for $13.4 million in cash. The Company determined this purchase did not meet the definition of a business as defined under ASC 805. The estimated fair value of the equipment was equal to the purchase price.  The Company believes the purchase of the equipment will aid in the Company’s pipeline construction projects and enhance the work provided to our utility clients.

 

On November 18, 2016, the Company’s subsidiary, Primoris AV, acquired certain assets and liabilities of Northern Energy & Power for $6.8 million.  The acquired business unit name was changed to Primoris Renewable Energy (“PRE”).  PRE operates in the Power segment and serves the renewable energy sector with a specific focus on solar photovoltaic installations in the United States.  The purchase was accounted for using the acquisition method of accounting.  During the second quarter of 2017, the Company finalized its estimated fair value of the acquired assets of

14


 

Table of Contents 

PRE, which resulted in a $0.1 million reduction in goodwill compared to amounts previously disclosed.  The allocation of the total purchase price included fixed assets of $0.1 million; intangible assets of $3.0 million; and goodwill of $3.7 million.  Goodwill largely consists of synergies expected from expanded operations as well as the value of the assembled workforce that PRE provides.  Based on the current tax treatment, goodwill will be deductible for income tax purposes over a fifteen-year period. 

 

On May 26, 2017, the Company acquired certain assets of Florida Gas Contractors, a utility contractor specializing in underground natural gas infrastructure, for approximately $33.0 million in cash.  In addition, the sellers could receive a contingent earnout amount of up to $1.5 million over a one-year period ending May 26, 2018, based on the achievement of certain operating targets.  The estimated fair value of the potential contingent consideration on the acquisition date was $1.2 million.  FGC operates in the Utilities segment and expands the Company’s presence in the Florida and Southeast markets.  The purchase was accounted for using the acquisition method of accounting.  The preliminary allocation of the total purchase price consisted of $4.8 million of fixed assets; $4.2 million of working capital; $10.5 million of intangible assets; and $14.7 million of goodwill. In connection with the FGC acquisition, the Company also paid $3.5 million to acquire certain land and buildings.  Goodwill associated with the FGC acquisition principally consists of expected benefits from providing expertise for the Company’s construction efforts in the underground utility business as well as the expansion of the Company’s geographic presence.  Goodwill also includes the value of the assembled workforce that the FGC acquisition provides to the Company.  Based on the current tax treatment, goodwill will be deductible for income tax purposes over a fifteen-year period.

 

On May 30, 2017, the PD&C acquired certain engineering assets for approximately $2.3 million in cash.  PD&C operates in the Power segment and the acquisition futher enhances its ability to provide quality service for engineering and design projects.  The purchase was accounted for using the acquisition method of accounting.  The preliminary allocation of the total purchase price consisted of $0.2 million of fixed assets and $2.1 million of intangible assets.

 

On June 16, 2017, the Company acquired certain assets and liabilities of Coastal Field Services for approximately $27.5 million in cash.  Coastal provides pipeline construction and maintenance, pipe and vessel coating and insulation, and integrity support services for companies in the oil and gas industry.  Coastal operates in the Pipeline segment and increases the Company’s market share in the Gulf Coast energy market.  The purchase was accounted for using the acquisition method of accounting.  The preliminary allocation of the total purchase price consisted of $4.0 million of fixed assets; $4.8 million of working capital; $9.9 million of intangible assets and $8.8 million of goodwill. Goodwill associated with the Coastal acquisition principally consists of expected benefits from providing expertise for the Company’s expansion of services in the pipeline construction and maintenance business.  Goodwill also includes the value of the assembled workforce that the Coastal acquisition provides to the Company.  Based on the current tax treatment, goodwill will be deductible for income tax purposes over a fifteen-year period.

 

Supplemental Unaudited Pro Forma Information for the three and six months ended June 30, 2017 and 2016

 

The following pro forma information for the three and six months ended June 30, 2017 and 2016 presents the results of operations of the Company as if the acquisitions had occurred at the beginning of 2016. The supplemental pro forma information has been adjusted to include:

 

·

the pro forma impact of amortization of intangible assets and depreciation of property, plant and equipment, based on the purchase price allocations; and

 

·

the pro forma tax effect of both the income before income taxes and the pro forma adjustments, calculated using a tax rate of 40.0% for the three and six months ended June 30, 2017 and the same period in 2016.

 

The pro forma results are presented for illustrative purposes only and are not necessarily indicative of, or intended to represent, the results that would have been achieved had the various acquisitions been completed on January

15


 

Table of Contents 

1, 2016.  For example, the pro forma results do not reflect any operating efficiencies and associated cost savings that the Company might have achieved with respect to the acquisitions.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended June 30, 

 

Six Months Ended June 30, 

 

 

 

2017

    

2016

    

2017

    

2016

 

 

 

(unaudited)

 

(unaudited)

 

(unaudited)

 

(unaudited)

 

Revenues

 

$

641,592

 

$

479,326

 

$

1,218,734

 

$

933,491

 

Income before provision for income taxes

 

$

37,224

 

$

10,362

 

$

51,372

 

$

16,942

 

Net income attributable to Primoris

 

$

21,937

 

$

6,101

 

$

31,409

 

$

9,893

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Weighted average common shares outstanding:

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

 

51,437

 

 

51,772

 

 

51,515

 

 

51,749

 

Diluted

 

 

51,688

 

 

52,022

 

 

51,771

 

 

51,950

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per share:

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

$

0.43

 

$

0.12

 

$

0.61

 

$

0.19

 

Diluted

 

$

0.42

 

$

0.12

 

$

0.61

 

$

0.19

 

 

 

Note 8—Goodwill and Intangible Assets

 

Goodwill by segment was recorded as follows:

 

 

 

 

 

 

 

 

 

 

    

June 30, 

 

December 31, 

 

Reporting Segment

 

2017

 

2016

 

Power

 

$

24,391

 

$

24,512

 

Pipeline

 

 

51,075

 

 

42,252

 

Utilities

 

 

35,056

 

 

20,312

 

Civil

 

 

40,150

 

 

40,150

 

Total Goodwill

 

$

150,672

 

$

127,226

 

 

At June 30, 2017 and December 31, 2016, intangible assets totaled $51.2 million and $32.8 million, respectively, net of amortization.  The table below summarizes the intangible asset categories, amounts and the average amortization periods, which are on a straight-line basis:

 

 

 

 

 

 

 

 

 

 

 

 

 

Amortization

 

June 30, 

 

December 31, 

 

 

    

Period

    

2017

    

2016

 

Tradename

 

3 to 10 years

 

$

11,902

 

$

11,754

 

Customer relationships

 

3 to 15 years

 

 

37,755

 

 

20,136

 

Non-compete agreements

 

2 to 5 years

 

 

1,304

 

 

951

 

Other

 

3 years

 

 

267

 

 

 —

 

 

 

 

 

$

51,228

 

$

32,841

 

 

Amortization expense of intangible assets was $1.9 million and $1.6 million for the three months ended June 30, 2017 and 2016, respectively and amortization expense for the six months ended June 30, 2017 and 2016 was $3.6 million and $3.2 million, respectively. Estimated future amortization expense for intangible assets is as follows:

 

 

 

 

 

 

 

    

Estimated

 

 

 

Intangible

 

For the Years Ending

 

Amortization

 

December 31, 

 

Expense

 

2017 (remaining six months)

 

$

5,107

 

2018

 

 

9,741

 

2019

 

 

9,393

 

2020

 

 

6,650

 

2021

 

 

5,413

 

Thereafter

 

 

14,924

 

 

 

$

51,228

 

 

 

16


 

Table of Contents 

Note 9—Accounts Payable and Accrued Liabilities

 

At June 30, 2017 and December 31, 2016, accounts payable were $134.1 million and $168.1 million, respectively.  These balances included retention amounts for the same periods of approximately $10.7 million and $10.6 million, respectively.  The retention amounts are due to subcontractors and have been retained pending contract completion and customer acceptance of jobs.

 

The following is a summary of accrued expenses and other current liabilities:

 

 

 

 

 

 

 

 

 

 

June 30, 

 

December 31, 

 

 

2017

 

2016

Payroll and related employee benefits

 

$

45,474

 

$

42,718

Insurance, including self-insurance reserves

 

 

44,034

 

 

42,546

Reserve for estimated losses on uncompleted contracts

 

 

13,019

 

 

12,801

Corporate income taxes and other taxes

 

 

7,623

 

 

3,368

Accrued administrative cost

 

 

3,515

 

 

3,791

Other

 

 

2,579

 

 

2,782

 

 

$

116,244

 

$

108,006

 

 

Note 10—Credit Arrangements

 

Long-term debt and credit facilities consist of the following:

 

Commercial Notes Payable and Mortgage Notes Payable

 

From time to time, the Company enters into commercial equipment notes payable with various equipment finance companies and banks. Interest rates range from 1.78% to 3.51% per annum and maturity dates range from August 13, 2017 to October 14, 2021. The notes are secured by certain construction equipment of the Company.

 

The Company also entered into two secured mortgage notes payable to a bank in December 2015, with interest rates of 4.3% per annum and maturity dates of January 1, 2031. The mortgage notes are secured by two buildings.

 

During the six months ended June 30, 2017, the Company acquired three properties from a related party and assumed mortgage notes secured by the properties totaling $4.2 million.

 

Revolving Credit Facility

 

As of June 30, 2017, the Company had a revolving credit facility, as amended on March 7, 2017 (the “Credit Agreement”) with The PrivateBank and Trust Company, as administrative agent (the “Administrative Agent”) and co-lead arranger, The Bank of the West, as co-lead arranger, and IBERIABANK Corporation, Branch Banking and Trust Company and UMB Bank, N.A. (the “Lenders”). The Credit Agreement is a $125.0 million revolving credit facility whereby the Lenders agreed to make loans on a revolving basis from time to time and to issue letters of credit for up to the $125.0 million committed amount. The termination date of the Credit Agreement is December 28, 2017.

 

The principal amount of any loans under the Credit Agreement will bear interest at either: (i) LIBOR plus an applicable margin as specified in the Credit Agreement (based on the Company’s senior debt to EBITDA ratio as that term is defined in the Credit Agreement), or (ii) the Base Rate (which is the greater of (a) the Federal Funds Rate plus 0.5% or (b) the prime rate as announced by the Administrative Agent). Quarterly non-use fees, letter of credit fees and administrative agent fees are payable at rates specified in the Credit Agreement.

 

The principal amount of any loan drawn under the Credit Agreement may be prepaid in whole or in part, with a minimum prepayment of $5.0 million, at any time, potentially subject to make-whole provisions.

 

The Credit Agreement includes customary restrictive covenants for facilities of this type, as discussed below.

 

17


 

Table of Contents 

Commercial letters of credit outstanding were $15.7 million at June 30, 2017 and $16.2 million at December 31, 2016.  Other than commercial letters of credit, there were no borrowings under this line of credit during the six months ended June 30, 2017, and available borrowing capacity at June 30, 2017 was $109.3 million.

 

Senior Secured Notes and Shelf Agreement

 

On December 28, 2012, the Company entered into a $50.0 million Senior Secured Notes purchase agreement (“Senior Notes”) and a $25.0 million private shelf agreement (the “Notes Agreement”) by and among the Company, The Prudential Investment Management, Inc. and certain Prudential affiliates (the “Noteholders”).  On June 3, 2015, the Notes Agreement was amended to provide for the issuance of additional notes of up to $75.0 million over the three year period ending June 3, 2018 ("Additional Senior Notes").

 

The Senior Notes amount was funded on December 28, 2012. The Senior Notes are due December 28, 2022 and bear interest at an annual rate of 3.65%, paid quarterly in arrears. Annual principal payments of $7.1 million are required from December 28, 2016 through December 28, 2021 with a final payment due on December 28, 2022. The principal amount may be prepaid, with a minimum prepayment of $5.0 million, at any time, subject to make-whole provisions.

 

On July 25, 2013, the Company drew $25.0 million available under the Notes Agreement.  The notes are due July 25, 2023 and bear interest at an annual rate of 3.85%, paid quarterly in arrears.  Seven annual principal payments of $3.6 million are required from July 25, 2017 with a final payment due on July 25, 2023.

 

On November 9, 2015, the Company drew $25.0 million available under the Additional Senior Notes Agreement. The notes are due November 9, 2025 and bear interest at an annual rate of 4.6%, paid quarterly in arrears. Seven annual principal payments of $3.6 million are required from November 9, 2019, with a final payment due on November 9, 2025.

 

Loans made under both the Credit Agreement and the Notes Agreement are secured by our assets, including, among others, our cash, inventory, goods, equipment (excluding equipment subject to permitted liens) and accounts receivable. All of our domestic subsidiaries have issued joint and several guaranties in favor of the Lenders and Noteholders for all amounts under the Credit Agreement and Notes Agreement.

 

Both the Credit Agreement and the Notes Agreement contain various restrictive and financial covenants including, among others, minimum tangible net worth, senior debt/EBITDA ratio, debt service coverage requirements and a minimum balance for unencumbered net book value for fixed assets. In addition, the agreements include restrictions on investments, change of control provisions and provisions in the event the Company disposes more than 20% of its total assets.

 

The Company was in compliance with the covenants for the Credit Agreement and Notes Agreement at June 30, 2017.

 

Canadian Credit Facility

 

The Company has a demand credit facility for $8.0 million in Canadian dollars with a Canadian bank for purposes of issuing commercial letters of credit in Canada.  The credit facility has an annual renewal and provides for the issuance of commercial letters of credit for a term of up to five years. The facility provides for an annual fee of 1.0% for any issued and outstanding commercial letters of credit. Letters of credit can be denominated in either Canadian or U.S. dollars. At December 31, 2016, there were no letters of credit outstanding.  Letters of credit outstanding was $0.5 million in Canadian dollars at June 30, 2017, and the available borrowing capacity was $7.5 million in Canadian dollars.  The credit facility contains a working capital restrictive covenant for OnQuest Canada, ULC.  At June 30, 2017, OnQuest Canada, ULC was in compliance with the covenant.

 

 

Note 11 — Noncontrolling Interests

 

The Company is currently involved in two joint ventures, each of which has been determined to be a variable interest entity (“VIE”) with the Company as the primary beneficiary as a result of its significant influence over the joint venture operations.

 

18


 

Table of Contents 

Each joint venture is a partnership, and consequently, no tax effect was recognized for the income.  The net assets of the joint ventures are restricted for use by the specific project and are not available for general operations of the Company.

 

Carlsbad Joint Venture

 

The Carlsbad joint venture operating activities began in 2015 and are included in the Company’s consolidated statements of income for the three and six months ended:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended June 30, 

 

Six Months Ended June 30, 

 

 

 

2017

    

2016

    

2017

    

2016

 

Revenues

 

$

26,203

 

$

3,150

 

$

37,003

 

$

6,668

 

Net income attributable to noncontrolling interests

 

 

12

 

 

131

 

 

380

 

 

286

 

 

The Carlsbad joint venture made no distributions to the partners, and the Company made no capital contributions to the Carlsbad joint venture during the six months ended June 30, 2017. The project is expected to be completed in 2018.

 

The carrying value of the assets and liabilities associated with the operations of the Carlsbad joint venture are included in the Company's consolidated balance sheets as follows:

 

jjjjjj

 

 

 

 

 

 

 

 

 

June 30, 

 

December 31, 

 

 

 

2017

 

2016

 

Cash

 

$

39,222

 

$

4,630

 

Accounts receivable

 

$

6,703

 

$

 —

 

Costs and estimated earnings in excess of billings

 

$

124

 

$

124

 

Billings in excess of costs and estimated earnings

 

$

33,452

 

$

3,426

 

Accounts payable

 

$

6,288

 

$

286

 

Due to Primoris

 

$

4,553

 

$

46

 

 

Wilmington Joint Venture

 

The Wilmington joint venture operating activities began in October 2015 and are included in the Company's consolidated statements of income for the three and six months ended:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended June 30, 

 

Six Months Ended June 30, 

 

 

 

2017

    

2016

    

2017

    

2016

 

Revenues

 

$

12,289

 

$

2,958

 

$

24,599

 

$

4,917

 

Net income attributable to noncontrolling interests

 

 

839

 

 

100

 

 

1,292

 

 

168

 

 

The Wilmington joint venture made no distributions to the partners, and the Company made no capital contributions to the Wilmington joint venture during the six months ended June 30, 2017. The project is expected to be completed in 2018.

 

The carrying value of the assets and liabilities associated with the operations of the Wilmington joint venture are included in the Company’s consolidated balance sheets as follows:

 

 

 

 

 

 

 

 

 

 

 

June 30, 

 

December 31, 

 

 

 

2017

 

2016

 

Cash

 

$

8,872

 

$

2,415

 

Accounts receivable

 

$

6,406

 

$

4,242

 

Billings in excess of costs and estimated earnings

 

$

2,334

 

$

2,572

 

Accounts payable

 

$

7,467

 

$

602

 

Due to Primoris

 

$

1,446

 

$

2,035

 

 

 

 

 

 

19


 

Table of Contents 

 

 

 

 

 

 

Summary – Joint Venture Balance Sheets

 

The following table summarizes the total balance sheet amounts for the two joint ventures, which are included in the Company’s condensed consolidated balance sheets:

 

 

 

 

 

 

 

 

 

 

 

Joint Venture

 

Consolidated

 

At June 30, 2017

 

Amounts

 

Amounts

 

Cash

 

$

48,094

 

$

111,676

 

Accounts receivable

 

$

13,109

 

$

355,231

 

Costs and estimated earnings in excess of billings

 

$

124

 

$

158,741

 

Accounts payable

 

$

13,755

 

$

134,091

 

Billings in excess of costs and estimated earnings

 

$

35,786

 

$

158,698

 

 

 

 

 

 

 

 

 

At December 31, 2016

 

 

 

 

 

 

 

Cash

 

$

7,045

 

$

135,823

 

Accounts receivable

 

$

4,242

 

$

388,000

 

Costs and estimated earnings in excess of billings

 

$

124

 

$

138,618

 

Accounts payable

 

$

888

 

$

168,110

 

Billings in excess of costs and estimated earnings

 

$

5,998

 

$

112,606

 

 

Note 12—Related Party Transactions

 

Primoris entered into leasing transactions with Stockdale Investment Group, Inc. (“SIGI”).  Our Chairman of the Board of Directors and our largest stockholder, Brian Pratt and his family, holds a majority interest of SIGI.  The leases were for three properties used by the Company in California, with various expiration dates.  In March 2017, the Company exercised a right of first refusal and purchased the SIGI properties.  The purchase was approved by the Company’s Board of Directors for $12.8 million.  The Company assumed three mortgage notes totaling $4.2 million with the remainder paid in cash.

 

During the three months ended June 30, 2017 and 2016, the Company paid $0 and $0.2 million, respectively, in lease payments to SIGI for the use of these properties.  During the six months ended June 30, 2017 and 2016, the Company paid $0.2 million and $0.4 million, respectively, in lease payments to SIGI for the use of these properties.

 

Primoris leases properties from other individuals that are current employees.  The amounts leased are not material and each arrangement was approved by the Board of Directors.

 

Note 13—Stock-Based Compensation

 

In July 2008, the shareholders approved and the Company adopted the Primoris Services Corporation 2008 Long-term Incentive Equity Plan, which was replaced by the Primoris Services Corporation 2013 Long-term Incentive Equity Plan (“Equity Plan”), after approval by the shareholders and adoption by the Company on May 3, 2013.

 

The Company’s Board of Directors has granted 259,065 Restricted Stock Units (“Units”) to executives under the Equity Plan.  The grants were documented in RSU Award Agreements, which provide for a vesting schedule and require continuing employment of the executive.  The Units are subject to earlier acceleration, termination, cancellation or forfeiture as provided in the underlying RSU Award Agreement. 

 

At June 30, 2017, a total of 173,650 Units were vested.  The vesting schedule for the remaining Units are as follows:

 

 

 

 

 

Number of Units

For the Years Ending December 31, 

 

to Vest

2017  (remaining six months)

 

 —

2018

 

28,471

2019

 

51,552

2020

 

5,392

 

 

85,415

 

20


 

Table of Contents 

Under guidance of ASC Topic 718 “Compensation — Stock Compensation”, stock-based compensation cost is measured at the date of grant, based on the calculated fair value of the stock-based award, and is recognized as expense over the employee’s requisite service period (generally the vesting period of the award).

 

The fair value of the Units was based on the closing market price of our common stock on the day prior to the date of the grant.  Stock compensation expense for the Units is being amortized using the straight-line method over the service period.  The Company recognized $0.2 million and $0.4 million in compensation expense for the three months ended June 30, 2017 and 2016, respectively, and $0.7 million in compensation expense for each of the six months ended June 30, 2017 and 2016.  At June 30, 2017, approximately $1.6 million of unrecognized compensation expense remained for the Units, which will be recognized over a weighted average period of 2.1 years.

 

Vested Units accrue “Dividend Equivalent Units” (as defined in the Equity Plan), which will be accrued as additional Units.  At June 30, 2017, a total of 2,378 Dividend Equivalent Units were accrued.

 

Note 14—Income Taxes

 

The Company determines its best current estimate of the annual effective tax rate using expected pre-tax earnings, statutory tax rates, and available tax planning opportunities. Certain significant or unusual items are separately recognized in the quarter in which they occur and can be a source of variability in the effective tax rate from quarter to quarter.  The Company recognizes interest and penalties related to uncertain tax positions, if any, as an income tax expense.

 

The effective tax rate on income including noncontrolling interests for the six months ended June 30, 2017 was 37.7%. The effective tax rate on income attributable to Primoris (excluding noncontrolling interests) was 39.0%.  The rates differ from the U.S. federal statutory rate of 35% primarily due to state income taxes, the Domestic Production Activity Deduction, and partially to nondeductible meals and incidental per diem expenses common to the construction industry.

 

The Company’s federal income tax returns are generally no longer subject to examination for tax years before 2013. The statutes of limitation of state and foreign jurisdictions generally vary between 3 to 5 years. Accordingly, the tax years 2011 through 2015 remain open to examination by the other taxing jurisdictions in which the Company operates.

 

Income taxes are accounted for under the asset and liability method. Deferred tax assets and liabilities are recognized for the future tax consequences of temporary differences between the financial reporting basis and tax basis of the Company’s assets and liabilities. Deferred tax assets and liabilities are measured using enacted tax rates expected to apply in the years in which those temporary differences are expected to reverse. The effects of remeasurement of deferred tax assets and liabilities resulting from changes in tax rates are recognized in income in the period of enactment.

 

Note 15—Dividends and Earnings Per Share

 

The Company has paid or declared cash dividends during 2016 and 2017 as follows:

 

 

 

 

 

 

 

 

 

 

Declaration Date

 

Record Date

    

Payable Date

    

Amount Per Share

 

February 22, 2016

 

March 31, 2016

 

April 15, 2016

 

$

0.055

 

May 2, 2016

 

June 30, 2016

 

July 15, 2016

 

$

0.055

 

August 3, 2016

 

September 30, 2016

 

October 14, 2016

 

$

0.055

 

November 2, 2016

 

December 31, 2016

 

January 16, 2017

 

$

0.055

 

March 21, 2017

 

March 31, 2017

 

April 15, 2017

 

$

0.055

 

May 5, 2017

 

June 30, 2017

 

July 14, 2017

 

$

0.055

 

 

The payment of future dividends is contingent upon our revenues and earnings, capital requirements and general financial condition of the Company, as well as contractual restrictions and other considerations deemed relevant by the Board of Directors.

 

21


 

Table of Contents 

The table below presents the computation of basic and diluted earnings per share for the three and six months ended June 30, 2017 and 2016.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended June 30, 

 

Six Months Ended June 30, 

 

 

2017

    

2016

    

2017

    

2016

Numerator:

 

 

 

 

 

 

 

 

 

 

 

 

Net income attributable to Primoris

 

$

21,545

 

$

5,056

 

$

29,236

 

$

7,749

 

 

 

 

 

 

 

 

 

 

 

 

 

Denominator (shares in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

Weighted average shares for computation of basic earnings per share

 

 

51,437

 

 

51,772

 

 

51,515

 

 

51,749

Dilutive effect of shares issued to independent directors

 

 

 —

 

 

 —

 

 

 3

 

 

 3

Dilutive effect of restricted stock units (1)

 

 

251

 

 

250

 

 

253

 

 

198

Weighted average shares for computation of diluted earnings per share

 

 

51,688

 

 

52,022

 

 

51,771

 

 

51,950

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per share attributable to Primoris:

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

$

0.42

 

$

0.10

 

$

0.57

 

$

0.15

Diluted

 

$

0.42

 

$

0.10

 

$

0.56

 

$

0.15


(1)

Represents the dilutive effect of a grant of 259,065 Units and 2,378 vested Dividend Equivalent Units.

 

 

Note 16—Stockholders’ Equity

 

Common stock —The Company issued 65,429 shares of common stock in February 2017 and 85,907 shares of common stock in February 2016 under the Company’s long-term retention plan (“LTR Plan”). The shares were purchased by the participants in the LTR Plan with payment made to the Company of $1.1 million in February 2017 and $1.4 million in February 2016. The Company’s LTR Plan for managers and executives allows participants to use a portion of their annual bonus amount to purchase Company common stock at a discount from the market price. The shares purchased in February 2017 were for bonus amounts earned in 2016, and the number of shares was calculated at 75% of the average closing market price of January 2017.

 

In February 2017 and 2016, the Company issued 11,784 shares and 10,450 shares of common stock, respectively, as part of the quarterly compensation of the non-employee members of the Board of Directors. 

 

As discussed in Note 13 — “Stock–Based Compensation”, as of June 30, 2017, the Board of Directors has granted a total of 259,065 shares of Units under the Equity Plan and these Units have accrued 2,378 Dividend Equivalent Units.

 

Share repurchase plan —In February 2017, the Company's Board of Directors authorized a $5.0 million share repurchase program under which the Company may, from time to time and depending on market conditions, share price and other factors, acquire shares of its common stock on the open market or in privately negotiated transactions up to an aggregate purchase price of $5.0 million. During the period from March 23, 2017 through March 28, 2017, the Company purchased and cancelled 216,350 shares of stock for $5.0 million at an average cost of $23.10 per share.

 

Note 17—Commitments and Contingencies

 

Leases  — The Company leases certain property and equipment under non-cancellable operating leases which expire at various dates through 2023. The leases require the Company to pay all taxes, insurance, maintenance and utilities and are classified as operating leases in accordance with ASC Topic 840 “Leases”.

 

Total lease expense during the three and six months ended June 30, 2017 was $5.9 million and $12.0 million, respectively, compared to $5.5 million and $10.8 million, respectively for the same periods in 2016.  The amounts for the three and six months ended June 30, 2017 included lease payments made to related parties of $0.1 million and $0.5 million, respectively compared to $0.4 million and $0.7 million, respectively, for the same periods in 2016. 

 

22


 

Table of Contents 

Letters of credit  — At June 30, 2017, the Company had letters of credit outstanding of $15.7 million, and at December 31, 2016, the Company had letters of credit outstanding of $16.2 million.  The outstanding amounts include the U.S. dollar equivalents for letters of credit issued in Canadian dollars.

 

Bonding — At June 30, 2017 and December 31, 2016, the Company had bid and completion bonds issued and outstanding totaling approximately $1.46 billion and $1.53 billion, respectively.

 

NTTA settlement — On February 7, 2012, the Company was sued in an action entitled North Texas Tollway Authority (“NTTA”), Plaintiff v. James Construction Group, LLC, and KBR, Inc., Defendants, v. Reinforced Earth Company, Third-Party Defendant (the “Lawsuit”). 

 

On February 25, 2015 the Lawsuit was settled for an expected cost to the Company of $9.0 million.  One of the defendants paid the Company $8.0 million to remove all of their liability. A second defendant agreed to provide up to $5.4 million to pay for the total expected remediation cost of approximately $22.4 million. The Company will use the $17.0 million to pay for a third-party contractor approved by the NTTA. At June 30, 2017, the remaining accrual balance was $14.5 million. In the event that the total remediation costs exceed the estimated amount, the second defendant would pay 20% of the excess amount and the Company would pay for 80% of the excess amount.

 

Legal proceedings —The Company has been engaged in dispute resolution to collect money it believes it is owed for one construction project completed  in 2014.  Because of uncertainties associated with the project, including uncertainty of the amounts that would be collected, the Company used a zero profit margin approach to recording revenues during the construction period for the project. 

 

For the project, a cost reimbursable contract, the Company recorded a receivable of $32.9 million with a reserve of approximately $17.8 million included in “billings in excess of costs and estimated earnings”.  At this time, the Company cannot predict the amount that it will collect nor the timing of any collection. The dispute resolution for the receivable initially required international arbitration; however, in the first half of 2016, the owner sought bankruptcy protection in U.S. bankruptcy court. The Company has initiated litigation against the sureties who have provided lien and stop payment release bonds for the total amount owed.  A trial date has been set for the fourth quarter of 2017.

 

The Company is subject to other claims and legal proceedings arising out of its business. The Company provides for costs related to contingencies when a loss from such claims is probable and the amount is reasonably determinable. In determining whether it is possible to provide an estimate of loss, or range of possible loss, the Company reviews and evaluates its litigation and regulatory matters on a quarterly basis in light of potentially relevant factual and legal developments. If we determine an unfavorable outcome is not probable or reasonably estimable, we do not accrue for a potential litigation loss. Management is unable to ascertain the ultimate outcome of other claims and legal proceedings; however, after review and consultation with counsel and taking into consideration relevant insurance coverage and related deductibles/self-insurance retention, management believes that it has meritorious defenses to the claims and believes that the reasonably possible outcome of such claims will not, individually or in the aggregate, have a materially adverse effect on the consolidated results of operations, financial condition or cash flows of the Company.

 

SEC Inquiry — The Company has been cooperating with an inquiry by the staff of the Securities and Exchange Commission, which appears to be focused on certain percentage-of-completion contract revenue recognition practices of the Company during the time period 2013 and 2014.  The Company is continuing to respond to the staff’s inquiries in connection with this matter.  At this stage, the Company is unable to predict when the staff’s inquiry will conclude or the outcome.

 

Withdrawal liability for multiemployer pension plan  — In November 2011, members of the Pipe Line Contractors Association (“PLCA”), including ARB, Rockford and Q3C (prior to the Company’s acquisition in 2012), withdrew from the Central States, Southeast and Southwest Areas Pension Fund multiemployer pension plan (“Plan”) in order to mitigate additional liability in connection with the significantly underfunded Plan.  During the first quarter of 2016, the Company received a final payment schedule for its withdrawal liability.  Based on this schedule, the liability recorded at June 30, 2017 was $5.1 million.  The Company has no plans to withdraw from any other agreements.

 

 

23


 

Table of Contents 

Note 18—Reportable Segments

 

Through the end of the year 2016, the Company segregated its business into three reportable segments: the Energy segment, the East Construction Services segment and the West Construction Services segment. In the first quarter 2017, the Company changed its reportable segments in connection with a realignment of the Company’s internal organization and management structure. The segment changes during the quarter reflect the focus of our CODM on the range of services we provide to our end user markets. Our CODM regularly reviews the operating and financial performance of our business units based on these segments.

 

The current reportable segments include the Power segment, the Pipeline segment, the Utilities segment, and the Civil segment.  Segment information for prior periods have been restated to conform to the new segment presentation.

 

The classification of our business unit revenues and gross profit for segment reporting purposes can at times require judgment on the part of management. Our business units may perform services across industries or perform joint services for customers in multiple industries. To determine reportable segment gross profit, certain allocations, including allocations of shared and indirect costs, such as facility costs, equipment costs and indirect operating expenses were made.

 

The following is a brief description of the reportable segments and their business units and operations.

 

The Power division of the Power segment includes ARB Industrial, Primoris Power, ARB Structures, and Primoris Renewable Energy. This division operates primarily in our California markets, with select projects performed nationwide. The Industrial division of this segment includes Primoris Industrial Constructors, Primoris Fabrication, and Primoris Mechanical Contractors. These groups are headquartered in and around Houston, TX and focus on the Southern region of the United States. The Engineering division of this segment includes OnQuest, with offices in California, OnQuest with offices in Calgary, and Primoris Design and Construction, located in Tyler, TX.

 

The Pipeline segment includes Rockford, Vadnais Trenchless, Primoris Field Services, Primoris Pipeline, and Primoris Coastal Field Services. Rockford operates throughout the United States. Vadnais Trenchless provides specialized trenchless solutions in California and other select areas. Presently, Primoris Field Services,  Primoris Pipeline and Primoris Coastal Field Services operate in Texas and surrounding states.

 

The Utilities segment is comprised of ARB Underground, Q3C, Primoris AV, and Primoris Distribution Services.  ARB Underground operates primarily in California, Q3C and Primoris AV are present throughout the Midwest region of the United States, and Primoris Distribution Services operates in Florida and the Southeast region of the United States.

 

The Civil segment includes Primoris Heavy Civil, Primoris I&M, and BW Primoris. These business units are located primarily in the Southeastern and Gulf Coast regions of the United States.

 

Each of the four segments specializes in a range of services that include engineering, designing, building/installing, replacing, repairing/rehabilitating, and providing management services for construction and construction-related projects. Our services include:

 

·

Providing installation of underground pipeline, cable, and conduits for entities in the petroleum, petrochemical, and water industries;

·

Providing maintenance services to utilities for installation and repair of gas distribution lines; 

·

Providing engineering, installation, and maintenance of industrial facilities for entities in the petroleum, petrochemical, water, and other industries; 

·

Providing installation of commercial and industrial cast-in-place structures; 

·

Providing construction of highways and bridges; and

·

Providing industrial and environmental construction.

 

All intersegment revenues and gross profit, which were immaterial, have been eliminated in the following tables. 

 

24


 

Table of Contents 

Segment Revenues

 

Revenue by segment for the three and six months ended June 30, 2017 and 2016 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

For the three months ended June 30, 

 

 

 

2017

 

2016

 

 

 

 

 

 

% of

 

 

 

 

% of

 

 

 

 

 

 

Total

 

 

 

 

Total

 

Segment

    

Revenue

    

Revenue

    

Revenue

    

Revenue

 

Power

 

$

157,773

 

25.0%

 

$

126,576

 

27.7%

 

Pipeline

 

 

134,623

 

21.3%

 

 

56,804

 

12.4%

 

Utilities

 

 

212,942

 

33.8%

 

 

157,119

 

34.4%

 

Civil

 

 

125,827

 

19.9%

 

 

116,312

 

25.5%

 

Total

 

$

631,165

 

100.0%

 

$

456,811

 

100.0%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

For the six months ended June 30, 

 

 

 

2017

 

2016

 

 

 

 

 

 

% of

 

 

 

 

% of

 

 

 

 

 

 

Total

 

 

 

 

Total

 

Segment

    

Revenue

    

Revenue

    

Revenue

    

Revenue

 

Power

 

$

289,013

 

24.2%

 

$

265,214

 

29.9%

 

Pipeline

 

 

318,068

 

26.7%

 

 

111,140

 

12.5%

 

Utilities

 

 

329,922

 

27.7%

 

 

260,873

 

29.4%

 

Civil

 

 

255,664

 

21.4%

 

 

250,030

 

28.2%

 

Total

 

$

1,192,667

 

100.0%

 

$

887,257

 

100.0%

 

 

Segment Gross Profit

 

Gross profit by segment for the three and six months ended June 30, 2017 and 2016 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

For the three months ended June 30, 

 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

Segment

 

Gross Profit

 

Revenue

 

Gross Profit

 

Revenue

 

Power

 

$

18,132

 

11.5%

 

$

14,092

 

11.1%

 

Pipeline

 

 

39,366

 

29.2%

 

 

6,469

 

11.4%

 

Utilities

 

 

32,347

 

15.2%

 

 

22,841

 

14.5%

 

Civil

 

 

(5,362)

 

(4.3%)

 

 

(117)

 

(0.1%)

 

Total

 

$

84,483

 

13.4%

 

$

43,285

 

9.5%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

For the six months ended June 30, 

 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

Segment

 

Gross Profit

 

Revenue

 

Gross Profit

 

Revenue

 

Power

 

$

33,656

 

11.6%

 

$

25,677

 

9.7%

 

Pipeline

 

 

67,491

 

21.2%

 

 

11,468

 

10.3%

 

Utilities

 

 

40,620

 

12.3%

 

 

34,726

 

13.3%

 

Civil

 

 

(2,231)

 

(0.9%)

 

 

10,691

 

4.3%

 

Total

 

$

139,536

 

11.7%

 

$

82,562

 

9.3%

 

 

25


 

Table of Contents 

Segment Goodwill

 

The amount of goodwill recorded by segment at June 30, 2017 and at December 31, 2016 is presented in Note 8 – “Goodwill and Intangible Assets”.  

 

Geographic Region — Revenues and Total Assets

 

The Company’s revenues are derived from customers primarily in the United States, with less than 1.0% generated from sources outside of the United States. At June 30, 2017, approximately 1.0% of total assets were located outside of the United States.

 

Note 19—Subsequent Events

 

Cash Dividend – On August 2, 2017, the Board of Directors declared a cash dividend of $0.055 per common share for stockholders of record as of September 29, 2017, payable on or about October 14, 2017.

26


 

Table of Contents 

 

 

PRIMORIS SERVICES CORPORATION

MANAGEMENT’S DISCUSSION AND ANALYSIS

 

Item 2.  Management’s Discussion and Analysis of Financial Condition and Results of Operations

 

Forward Looking Statements

 

This Quarterly Report on Form 10-Q for the quarterly period ended June 30, 2017 (“Second Quarter 2017 Report”) contains forward-looking statements within the meaning of Section 27A of the Securities Act of 1933, as amended (the “Securities Act”), and Section 21E of the Securities Exchange Act of 1934, as amended (the “Exchange Act”), which are subject to the “safe harbor” created by those sections. Forward-looking statements include information concerning our possible or assumed future results of operations, business strategies, financing plans, competitive position, industry environment, potential growth opportunities, the effects of regulation and the economy, generally. Forward-looking statements include all statements that are not historical facts and can be identified by terms such as “anticipates”, “believes”, “could”, “estimates”, “expects”, “intends”, “may”, “plans”, “potential”, “predicts”, “projects”, “should”, “will”, “would” or similar expressions.

 

Forward-looking statements involve known and unknown risks, uncertainties and other factors which may cause our actual results, performance or achievements to be materially different from any future results, performance or achievements expressed or implied by the forward-looking statements. We discuss many of these risks in detail in Part I, Item 1A “Risk Factors” of our Annual Report on Form 10-K for the year ended December 31, 2016 and our other filings with the Securities and Exchange Commission (“SEC”). You should read this Second Quarter 2017 Report, our Annual Report on Form 10-K for the year ended December 31, 2016 and our other filings with the SEC completely and with the understanding that our actual future results may be materially different from what we expect.

 

Given these uncertainties, you should not place undue reliance on these forward-looking statements. Also, forward-looking statements represent our management’s beliefs and assumptions only as of the date of this Second Quarter 2017 Report. We assume no obligation to update these forward-looking statements publicly, or to update the reasons actual results could differ materially from those anticipated in any forward-looking statements, even if new information becomes available.

 

The following discussion and analysis should be read in conjunction with the unaudited financial statements and the accompanying notes included in Part 1, Item 1 of this Second Quarter 2017 Report and our Annual Report on Form 10-K for the year ended December 31, 2016.

 

Introduction

 

Primoris is a holding company of various subsidiaries, which form one of the larger publicly traded specialty contractors and infrastructure companies in the United States. Serving diverse end-markets, we provide a wide range of construction, fabrication, maintenance, replacement, water and wastewater, and engineering services to major public utilities, petrochemical companies, energy companies, municipalities, state departments of transportation and other customers. We install, replace, repair and rehabilitate natural gas, refined product, water and wastewater pipeline systems; large diameter gas and liquid pipeline facilities; and heavy civil projects, earthwork and site development. We also construct mechanical facilities and other structures, including power plants, petrochemical facilities, refineries, water and wastewater treatment facilities and parking structures. Finally, we provide specialized process and product engineering services.

 

We have longstanding customer relationships with major utility, refining, petrochemical, power and engineering companies. We have completed major underground and industrial projects for a number of large natural gas transmission and petrochemical companies in the United States, as well as significant projects for our engineering customers. We enter into a large number of contracts each year, and the projects can vary in length from several weeks to as long as 48 months for completion on larger projects. Although we have not been dependent upon any one customer in any year, a small number of customers tend to constitute a substantial portion of our total revenues.

 

We recognize revenues and profitability on our contracts depending on the type of contract. For our fixed price, or lump sum, contracts, we record revenue as the work progresses on a percentage-of-completion basis, which means that we recognize revenue based on the percentage of costs incurred to date in proportion to the total estimated costs

27


 

Table of Contents 

expected to complete the contract. Fixed price contracts may include retainage provisions under which customers withhold a percentage of the contract price until the project is complete.  For our unit price, time and material, and cost-plus contracts, we recognize revenue as units are completed or services are performed.

 

Through the end of the year 2016, the Company segregated its business into three reportable segments: the Energy segment, the East Construction Services segment and the West Construction Services segment. In the first quarter 2017, the Company changed its reportable segments in connection with a realignment of the Company’s internal organization and management structure. The segment changes during the quarter reflect the focus of our chief operating decision maker (“CODM”) on the range of services we provide to our end user markets. The CODM regularly reviews the operating and financial performance of our business units based on these segments.

 

The current reportable segments include the Power, Industrial, and Engineering (“Power”) segment, the Pipeline and Underground (“Pipeline”) segment, the Utilities and Distribution (“Utilities”) segment, and the Civil segment.  See Note 18 – “Reportable Segments” for a brief description of the reportable segments and their operations.

 

The classification of our business unit revenues and gross profit for segment reporting purposes can at times require judgment on the part of management. Our business units may perform services across industries or perform joint services for customers in multiple industries. To determine reportable segment gross profit, certain allocations, including allocations of shared and indirect costs, such as facility costs, equipment costs and indirect operating expenses were made.

 

The following table lists the Company’s primary business units and their reportable segment:

 

 

 

 

 

 

 

Subsidiary

    

Reportable Segment

    

Prior Operating Segment

 

ARB Industrial (a division of ARB, Inc.)

 

Power

 

West

 

ARB Structures

 

Power

 

West

 

Primoris Power (formerly PES Saxon division)

 

Power

 

Energy

 

Primoris Renewable Energy (a division of Primoris Aevenia, Inc.)

 

Power

 

Energy

 

Primoris Industrial Constructors (formerly PES Industrial Division)

 

Power

 

Energy

 

Primoris Fabrication (a division of PES)

 

Power

 

Energy

 

Primoris Mechanical Contractors (a combination of a division of PES and Cardinal Contractors)

 

Power

 

Energy

 

OnQuest

 

Power

 

Energy

 

OnQuest Canada

 

Power

 

Energy

 

Primoris Design and Construction (“PD&C”); created 2017

 

Power

 

NA

 

Rockford Corporation (“Rockford”)

 

Pipeline

 

West

 

Vadnais Trenchless Services (“Vadnais Trenchless”)

 

Pipeline

 

West

 

Primoris Field Services (a division of PES Primoris Pipeline)

 

Pipeline

 

Energy

 

Primoris Pipeline (a division of PES Primoris Pipeline)

 

Pipeline

 

Energy

 

Primoris Coastal Field Services; created 2017

 

Pipeline

 

NA

 

ARB Underground (a division of ARB, Inc.)

 

Utilities

 

West

 

Q3 Contracting (“Q3C”)

 

Utilities

 

West

 

Primoris AV

 

Utilities

 

Energy

 

Primoris Distribution Services; created 2017

 

Utilities

 

NA

 

Primoris Heavy Civil (formerly JCG Heavy Civil Division)

 

Civil

 

East

 

Primoris I&M (formerly JCG Infrastructure & Maintenance Division)

 

Civil

 

East

 

BW Primoris

 

Civil

 

East

 

 

The Company owns a 50% interest in two separate joint ventures, both formed in 2015.  The Carlsbad Power Constructors joint venture (“Carlsbad”) is engineering and constructing a gas-fired power generation facility, and the “ARB Inc. & B&M Engineering Co.” joint venture (“Wilmington”) is also engineering and constructing a gas-fired power generation facility.  Both projects are located in the Southern California area.  The joint venture operations are included as part of the Power division of the Power segment.  As a result of determining that the Company is the primary beneficiary of the two variable interest entities (“VIEs”), the results of the Carlsbad and Wilmington joint ventures are consolidated in the Company’s financial statements.  Both project are expected to be completed in 2018.

 

28


 

Table of Contents 

On January 29, 2016, the Company acquired the net assets of Mueller Concrete Construction Company (“Mueller”) for $4.1 million, and on November 18, 2016, the Company acquired the net assets of Northern Energy & Power (“Northern”) for $6.8 million.  On May 26, 2017, the Company acquired the net assets of Florida Gas Contractors (“FGC”) for $37.7 million, on May 30, 2017 the PD&C acquired certain engineering assets for approximately $2.3 million, and on June 16, 2017, the Company acquired the net assets of Coastal Field Services (“Coastal”) for $27.5 million.  Both Mueller and FGC operations are included in the Utilities segment, Northern operations are included in the Power segment, and Coastal operations are included in the Pipeline segment.

 

Material trends and uncertainties

 

We generate our revenue from both large and small construction and engineering projects. The award of these contracts is dependent on many factors, most of which are not within our control. We depend in part on spending by companies in the energy and oil and gas industries, the gas utility industry, as well as municipal water and wastewater customers. Over the past several years, each segment has benefited from demand for more efficient and more environmentally friendly energy and power facilities, local highway and bridge needs and from the activity level in the oil and gas industry. However, periodically, each of these industries and government agencies are adversely affected by macroeconomic conditions. Economic factors outside of our control may affect the amount and size of contracts we are awarded in any particular period.

 

We closely monitor our customers to assess the effect that changes in economic, market and regulatory conditions may have on them. We have experienced reduced spending by some of our customers over the last several years, which we attribute to negative economic and market conditions, and we anticipate that these negative conditions may continue to affect demand for our services in the near-term.  Major fluctuations in market prices of oil, gas and other fuel sources have affected demand for our services.  The current price of oil, gas and liquid natural gas has created uncertainty with respect to demand for our oil and gas pipeline services in the near term, with additional uncertainty resulting over the length of time that prices will remain at current levels.  We believe that our upstream operations, such as the construction of gathering lines within the oil shale formations, will remain at lower levels for an extended period. While there was some stability in the price of oil in the first half of 2017, that stability has not resulted in a significant change in the contracting activities of our customers. We believe that over time, the need for pipeline infrastructure for mid-stream and gas utility companies will result in a continuing need for our services, but the impact of the low oil prices and the bankruptcy of some smaller oil and gas producers may delay midstream pipeline opportunities. The continuing changes in the regulatory environment also affect the demand for our services, either by increasing our work or delaying projects.  For example, the regulatory environment in California may result in delays for the construction of gas-fired power plants while regulators continue to search for significant renewable resources, but renewable resources may also create a demand for our construction services.  Finally, we believe that regulated utility customers will continue to invest in our maintenance and replacement services.

 

Seasonality, cyclicality and variability

 

Our results of operations are subject to quarterly variations. Some of the variation is the result of weather, particularly rain, ice and snow, which can impact our ability to perform construction services. While the majority of the Company’s work is in the southern half of the United States, these seasonal impacts affect revenues and profitability since gas and other utilities defer routine replacement and repair during their period of peak demand.  Any quarter can be affected either negatively or positively by atypical weather patterns in any part of the country.  In addition, demand for new projects tends to be lower during the early part of the year due to clients’ internal budget cycles.  As a result, the Company generally experiences higher revenues and earnings in the third and fourth quarters of the year as compared to the first two quarters.

 

The Company is also dependent on large construction projects which tend not to be seasonal, but can fluctuate from year to year based on general economic conditions.  Our business may be affected by declines or delays in new projects or by client project schedules.  Because of the seasonal and cyclical nature of our business, the financial results for any period may fluctuate from prior periods, and the Company’s financial condition and operating results may vary from quarter-to-quarter.  Results from one quarter may not be indicative of its financial condition or operating results for any other quarter or for an entire year.

 

29


 

Table of Contents 

Critical Accounting Policies and Estimates

 

The preparation of financial statements in conformity with accounting principles generally accepted in the United States requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and the disclosure of contingent assets and liabilities as of the date of the financial statements and that affect the amounts of revenues and expenses reported for each period. These estimates and assumptions must be made because certain information that is used in the preparation of our financial statements cannot be calculated with a high degree of precision from data available, is dependent on future events, or is not capable of being readily calculated based on generally accepted methodologies. Often, these estimates are particularly difficult to determine, and we must exercise significant judgment. We use estimates in our assessments of revenue recognition under percentage-of-completion accounting with estimated future job profitability, estimation of any loss provision, the allowance for doubtful accounts, useful lives of property and equipment, fair value assumptions in analyzing goodwill and long-lived asset impairments, self-insured claims liabilities and deferred income taxes. Actual results could differ significantly from our estimates, and our estimates could change if they were made under different assumptions or conditions.

 

As described in our Annual Report on Form 10-K for the year ended December 31, 2016, our critical accounting policies relate primarily to revenue recognition for fixed and unit price contracts, income taxes, goodwill, long-lived assets, reserves for uninsured risks and contingencies. There have been no material changes to our critical accounting policies since December 31, 2016.

 

Results of Operations

 

Consolidated Results

 

The following discussion compares the results of the three and six months ended June 30, 2017 to the three and six months ended June 30, 2016.

 

Revenues

 

Revenue for the three months ended June 30, 2017 was $631.2 million, an increase of $174.4 million, or 38.2%, compared to the same period in 2016 due to increases in revenues across all four segments. Pipeline segment revenue increased $77.8 million primarily from Rockford’s two large pipeline projects in Florida; Utilities segment revenue increased $55.8 million mainly due to increased utility work at both ARB Underground and Q3C;  Power segment revenue increased $31.2 million, primarily as a result of increases at ARB Industrial associated with joint venture projects in Southern California; and Civil segment revenue increased $9.5 million from increases at Primoris I&M from a methanol plant project in Louisiana and increased volume at Primoris Heavy Civil in Texas.

 

For the six months ended June 30, 2017, revenue increased by $305.4 million, or 34.4%, to $1,192.7 million compared to the same period in 2016.  Pipeline segment revenue increased $206.9 million primarily from Rockford’s two large pipeline projects in Florida; Utilities segment revenue increased $69.1 million mainly due to increases for utility customers at both ARB Underground and Q3C;  Power segment revenue increased $23.8 million, primarily as a result of increases at ARB Industrial associated with joint venture projects in Southern California; and Civil segment revenue increased $5.6 million from increases at Primoris I&M related  to a methanol plant in Louisiana.

 

30


 

Table of Contents 

Gross Profit

 

Gross profit was $84.5 million for the three months ended June 30, 2017, an increase of $41.2 million, or 95.2%, compared to the same period in 2016.  Pipeline segment gross profit increased $32.9 million primarily from Rockford’s two large pipeline projects in Florida; Utilities segment gross profit increased $9.5 million mainly due to increased volume for utility customers at ARB Underground;  Power segment gross profit increased $4.0 million as a result of increases associated with joint venture projects at ARB Industrial; and Civil segment gross profit decreased $5.2 million primarily from productivity issues at Primoris Heavy Civil.

 

For the six months ended June 30, 2017, gross profit increased by $57.0 million, or 69.0%, to $139.5 million compared to the same period in 2016. Pipeline segment gross profit increased $56.0 million primarily from Rockford’s two large pipeline projects in Florida; Utilities segment gross profit increased $5.9 million mainly due to increases with California utility customeres at ARB Underground;  Power segment gross profit increased $8.0 million as a result of increases on joint venture projects at ARB Industrial; and Civil segment gross profit decreased $12.9 million primarily from productivity issues at Primoris Heavy Civil.

 

Selling, general and administrative expenses

 

Selling, general and administrative (“SG&A”) expenses of $46.0 million during the three months ended June 30, 2017, increased by $13.5 million, or 41.5%, compared to the second quarter of 2016. Approximately $1.9 million of the increase in SG&A is related to acquired businesses. The primary reasons for the remaining increase was a $8.4 million increase in compensation related expenses, including incentive compensation accruals; a $1.6 million increase in legal costs; and $1.1 million increase in acquisition expenses.  SG&A expense as a percentage of revenue increased slightly to 7.3% compared to 7.1% for the corresponding period in 2016 due primarily to the two acquired businesses, which have slightly higher SG&A as a percent of revenue.

 

SG&A expense of $85.8 million increased $20.7 million, or 31.7%, for the six months ended June 30, 2017, compared to $65.1 million for the same period in 2016.  Approximately $1.9 million of the increase in SG&A is related to acquired businesses.  The remaining increase was primarily due to a $14.2 million increase in compensation related expenses, including incentive compensation accruals; a $1.8 million increase in legal costs; a $1.2 million increase in acquisition costs; and a $1.0 million benefit in the prior year from an adjustment to the pension withdrawal liability.  SG&A as a percentage of revenue for the six months ended June 30, 2017 decreased slightly to 7.2% compared to 7.3% for the corresponding period in 2016, as a result of the increase in revenue and the impact of the two acquired businesses.

 

Planned JCG Texas Heavy Civil division divestiture

 

In October 2016, the Company announced that it planned to divest its Texas heavy civil business unit, which operates as a division of JCG.   The Company planned to continue to operate the business unit until completion of a sale.  The Company engaged a financial advisor to assist in the sale and marketed the business unit.  In April 2017, the Board of Directors determined that based on the information available, the Company would attain the best long-term value by withdrawing from the sales process and continuing to operate the business unit.  Primoris will aggressively pursue claims that will be made for five Texas Department of Transportation projects that resulted in significant losses recorded in 2016.  However, there can be no assurance as to the final amounts collected.   

   

 

31


 

Table of Contents 

Other income and expense

 

Non-operating income and expense items for the three and six months ended June 30, 2017 and 2016 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended

 

Six Months Ended

 

 

 

June 30, 

 

June 30, 

 

 

    

2017

    

2016

    

2017

    

2016

 

 

 

(Thousands)

 

(Thousands)

 

Foreign exchange gain

 

$

109

 

$

21

 

$

132

 

$

380

 

Other expense

 

 

(13)

 

 

 —

 

 

(13)

 

 

 —

 

Interest income

 

 

114

 

 

52

 

 

183

 

 

91

 

Interest expense

 

 

(2,145)

 

 

(2,240)

 

 

(4,407)

 

 

(4,508)

 

Total other income (expense)

 

$

(1,935)

 

$

(2,167)

 

$

(4,105)

 

$

(4,037)

 

 

For the three and six months ended June 30, 2017, foreign exchange gains reflect currency exchange fluctuations of the United States dollar compared to the Canadian dollar.  Most of our Canadian subsidiary’s contracts are sold based on United States dollars, but a portion of the work is paid for with Canadian dollars creating a positive currency exchange difference when the value of the Canadian dollar is less than the US dollar.

 

Interest income is derived from interest earned on excess cash invested primarily in short term U.S. Treasury bills, which are backed by the federal government, and other investments that may not be backed by the federal government.

 

Interest expense for the three and six months ended June 30, 2017 remain relatively unchanged between periods due to relatively similar levels of long-term debt between the periods.

 

Provision for income taxes

 

The Company determines its best current estimate of the annual effective tax rate at each interim period using expected annual pre-tax earnings, statutory tax rates, and available tax planning opportunities. Certain significant or unusual items are separately recognized in the quarter in which they occur and can be a source of variability in the effective tax rate from quarter to quarter.

 

The effective tax rate on income attributable to Primoris (excluding noncontrolling interests) was 39.0% for the six months ended June 30, 2017.  The rate differs from the U.S. federal statutory rate of 35% primarily due to state income taxes, the Domestic Production Activity Deduction, and partially to nondeductible meals and incidental per diem expenses common to the construction industry.

 

The Company recorded income tax expense for the three months ended June 30, 2017 of $14.2 million compared to $3.3 million for the three months ended June 30, 2016.  The $10.9 million increase was primarily driven by a $27.3 million increase in pre-tax income (excluding noncontrolling interests).

 

The Company recorded income tax expense for the six months ended June 30, 2017 of $18.7 million compared to  $5.2 million for the six months ended June 30, 2016.  The $13.5 million increase was primarily driven by a $35.0 million increase in pre tax income (excluding noncontrolling interests), partially offset by a 1.0% decrease in effective tax rate from 40.0% to 39.0%.  The decrease in effective tax rate was primarily due to favorable provision-to-return adjustments from tax returns filed in the first quarter of 2017 and an increase in projected income for 2017.

 

32


 

Table of Contents 

Segment results

 

Power, Industrial and Engineering Segment

 

Revenue and gross profit for the Power segment for the three and six months ended June 30, 2017 and 2016 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended June 30, 

 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Thousands)

 

Revenue

 

(Thousands)

 

Revenue

 

Power Segment

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

157,773

 

 

 

$

126,576

 

 

 

Gross profit

 

$

18,132

 

11.5%

 

$

14,092

 

11.1%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Six Months Ended June 30, 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Thousands)

 

Revenue

 

(Thousands)

 

Revenue

 

Power Segment

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

289,013

 

 

 

$

265,214

 

 

 

Gross profit

 

$

33,656

 

11.6%

 

$

25,677

 

9.7%

 

 

 

Revenue increased by $31.2 million, or 24.6%, for the three months ended June 30, 2017, compared to the same period in 2016.  Revenue at ARB Industrial increased $26.1 million resulting from a $32.4 million increase in the division’s joint venture power plant projects in Southern California, partially offset by a $3.7 million reduction in revenue from the completion of a separate power project in Southern California in 2016.  In addition, Primoris Power realized a revenue increase of $9.6 million, primarily from a power plant construction project in the Mid-Atlantic region. Partially offsetting the increases is a $3.5 million decrease at Primoris Industrial Constructors as they continue work on a large petrochemical plant in Louisiana, and a $3.4 million decrease at ARB Structures due to the completion of a large parking structure in 2016.

 

Revenue increased by $23.8 million, or 9.0%, during the six months ended June 30, 2017, compared to the same period in 2016.  Revenue at ARB Industrial increased $36.2 million resulting from a $50.0 million increase in the division’s joint venture power plant projects in Southern California, partially offset by an $11.3 million reduction in revenue from the completion of a separate power project in Southern California in 2016.  In addition, Primoris Mechnical Contractors’ revenue increased by $6.2 million on higher volumes.  These increases are partially offset by a $14.9 million decrease at ARB Structures due to the completion of a large parking structure in 2016 and a $5.0 million decrease at Primoris Industrial Constructors as they are near completion of a large petrochemical plant in Louisiana.

 

Gross profit for the three months ended June 30, 2017, increased by $4.0 million or 28.7%, compared to the same period in 2016.  The increase is primarily due to the additional revenue provided by ARB Industrial’s joint venture projects in Southern California along with Primoris Power’s Mid-Atlantic power plant.    

 

Gross profit increased by $8.0 million, or 31.1%, during the six months ended June 30, 2017, compared to the same period in 2016.  The increase was primarily due to ARB Industrial’s $5.3 million increase in gross profit from the divison’s joint venture power plant projects and the completion of another power project. In addition, Primoris Mechanical Contractors increased $1.1 million due to higher volumes.

 

Gross profit as a percent of revenues increased to 11.5% and 11.6% during the three and six months ended June 30, 2017, respectively, from 11.1% and 9.7% in the same periods in 2016, primarily as a result of the progress of the power plant joint venture projects.

 

33


 

Table of Contents 

Pipeline and Underground Segment

 

Revenue and gross profit for the Pipeline segment for the three and six months ended June 30, 2017 and 2016 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended June 30, 

 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Thousands)

 

Revenue

 

(Thousands)

 

Revenue

 

Pipeline Segment

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

134,623

 

 

 

$

56,804

 

 

 

Gross profit

 

$

39,366

 

29.2%

 

$

6,469

 

11.4%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Six Months Ended June 30, 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Thousands)

 

Revenue

 

(Thousands)

 

Revenue

 

Pipeline Segment

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

318,068

 

 

 

$

111,140

 

 

 

Gross profit

 

$

67,491

 

21.2%

 

$

11,468

 

10.3%

 

 

Revenue increased by $77.8 million, or 137.0%, for the three months ended June 30, 2017, compared to the same period in 2016.  Rockford increased $62.2 million as a result of it’s two large pipeline jobs in Florida, which are substantially complete and experienced good weather conditions resulting in no weather delays and high productivity.  In addition, Primoris Field Services increased $6.4 million from a new pipeline job associated with a petrochemical plant in Lousiana and Vadnais Trenchless increased $3.9 million due to micro-tunneling project in Southern California.  

 

Revenue increased by $206.9 million, or 186.2%, for the six months ended June 30, 2017, compared to the same period in 2016.  The increase is primarily due to the strong results from Rockford’s two large pipeline jobs in Florida slightly offset by a $9.6 million reduction in revenues at Primoris Field Services after completion of two pipeline projects in 2016. 

 

Gross profit for the three months ended June 30, 2017 increased by $32.9 million, or 508.5%, compared to the same period in 2016.  The increase is primarily attributable to the two pipeline jobs in the Rockford division as well as the new pipeline and micro-tunneling jobs.

 

Gross profit for the six months ended June 30, 2017 increased by $56.0 million, or 488.6%, compared to the same period in 2016.  The increase is primarily attributable to the two pipeline jobs in the Rockford division.

 

Gross profit as a percent of revenues increased to 29.2% and 21.2% during the three and six months months ended June 30, 2017, respectively, from 11.4% and 10.3% in the same periods in 2016, primarily as a result of the good weather and higher productivity on the two large Rockford jobs.

 

34


 

Table of Contents 

Utilities and Distribution Segment

 

Revenue and gross profit for the Utilities segment for the three and six months ended June 30, 2017 and 2016 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended June 30, 

 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Thousands)

 

Revenue

 

(Thousands)

 

Revenue

 

Utilities Segment

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

212,942

 

 

 

$

157,119

 

 

 

Gross profit

 

$

32,347

 

15.2%

 

$

22,841

 

14.5%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Six Months Ended June 30, 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Thousands)

 

Revenue

 

(Thousands)

 

Revenue

 

Utilities Segment

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

329,922

 

 

 

$

260,873

 

 

 

Gross profit

 

$

40,620

 

12.3%

 

$

34,726

 

13.3%

 

 

 

Revenue increased by $55.8 million, or 35.5%, for the three months ended June 30, 2017, compared to the same period in 2016. Approximately $46.9 million of the increase is due to ARB Underground, primarily for two major utility customers as well as a new collaboration MSA arrangement for a major utility customer.  In addition, revenue at the Q3C division increased by $8.1 million on higher volumes and the addition of two new MSA customers.

 

Revenue for the six months ended June 30, 2017 increased by $69.0 million, or 26.5%, compared to the same period in 2016. Approximately $53.6 million of the increase is related to ARB Underground, primarily from an increase in work for three major utility customers in California as well as the new collaboration MSA arrangement.  In addition, revenue at the Q3C division increased by $11.9 million on higher volumes and the addition of two new MSA customers.

 

Gross profit for the three months ended June 30, 2017 increased by $9.5 million or 41.6%, compared to the same period in 2016.  The increase is primarily due to the growth in MSA revenue at ARB Underground and Q3C.

 

Gross profit for the six months ended June 30, 2017 increased $5.9 million, or 17.0%, compared to the same period in 2016 primarily due to the growth in MSA revenue at ARB Underground and Q3C.

 

Gross profit as a percent of revenues increased to 15.2% during the three months ended June 30, 2017, from 14.5% during the same period in 2016. The increase is primarily due to increased profitability in the ARB Underground division from the corresponding revenue growth.

 

Gross profit as a percent of revenues decreased slightly to 12.3% for the six months ended June 30, 2017, from 13.3% during the same period in 2016. The decrease was driven primarily by a few MSA agreements realizing lower margins as they approach the end of their term and will be renegotiated during renewal.

 

35


 

Table of Contents 

Civil Segment

 

Revenue and gross profit for the Civil segment for the three months ended June 30, 2017 and 2016 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Three Months Ended June 30, 

 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Thousands)

 

Revenue

 

(Thousands)

 

Revenue

 

Civil Segment

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

125,827

 

 

 

$

116,312

 

 

 

Gross profit

 

$

(5,362)

 

(4.3%)

 

$

(117)

 

(0.1%)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Six Months Ended June 30, 

 

 

2017

 

2016

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Thousands)

 

Revenue

 

(Thousands)

 

Revenue

 

Civil Segment

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

255,664

 

 

 

$

250,030

 

 

 

Gross profit

 

$

(2,231)

 

(0.9%)

 

$

10,691

 

4.3%

 

 

Revenue increased by $9.5 million, or 8.2%, for the three months ended June 30, 2017, compared to the same period in 2016.  Primoris Heavy Civil revenue increased by $9.3 million as increases of $20.0 million from TX DOT and $3.4 million from Arkansas DOT projects were partially offset by decreases of $11.0 million from LA DOT projects and a reduction in airport work as newly awarded airport work has yet to begin.  Revenue at Primoris I&M increased by $6.5 million primarily as a result of a $13.9 million increase from a methanol plant project in Louisiana, offset by lower revenue at a large petrochemical project in south Louisiana and decreases in maintenance projects in Florida.  

 

Revenue increased by $5.6 million, or 2.3%, for the six months ended June 30, 2017, compared to the same period in 2016.  Primoris Heavy Civil revenue increased by $1.7 million primarily due to increases of $20.1 million from TX DOT and $8.0 million from Arkansas DOT projects, partially offset by decreases of $18.8 million from LA DOT projects. Revenue at Primoris I&M increased by $3.9 million primarily as a result of a $24.8 million increase related to a methanol plant project in Louisiana, partially offset by lower revenue at a large petrochemical project in south Louisiana and decreases in Florida mine work. 

 

Gross profit decreased by $5.2 million for the three months ended June 30, 2017, compared to the same period in 2016.  The gross profit decrease was primarily a result of productivity issues on AR DOT and LA DOT projects, partially offset by lower write downs on TX DOT projects. Heavy Civil included $36.5 million of revenue for which no margin was recognized.

 

Gross profit decreased by $12.9 million for the six months ended June 30, 2017, compared to the same period in 2016.  The gross profit decrease was primarily a result of productivity issues on AR DOT and LA DOT projects, partially offset by lower write downs on TX DOT projects. Heavy Civil included $60.6 million of revenue for which no margin was recognized.

 

Gross profit as a percent of revenue decreased to (4.3%) and (0.9%) during the three and six months months ended June 30, 2017, respectively, from (0.1%) and 4.3% in the same periods in 2016 for the reasons noted above.

 

Geographic area financial information

 

The majority of the Company’s revenues are derived from customers in the United States with approximately 1% generated from sources outside of the United States.

 

36


 

Table of Contents 

Backlog

 

For companies in the construction industry, backlog can be an indicator of future revenue streams. We define backlog as a combination of: (1) anticipated revenue from the uncompleted portions of existing contracts for which we have known revenue amounts for fixed and unit price contracts (“Fixed Backlog”), and (2) the estimated revenues on MSA work for the next four quarters (“MSA Backlog”).  We normally do not include time-and-equipment, time-and-materials and cost reimbursable plus fee contracts in the calculation of backlog, since their final revenue amount is difficult to estimate in advance.  However, we will include these types of contracts in backlog if the customer specifies an anticipated revenue amount.

 

The two components of backlog, Fixed Backlog and MSA Backlog, are detailed below.

 

Fixed Backlog

 

Fixed Backlog by reportable segment as of December 31, 2016 and June 30, 2017 and the changes in Fixed Backlog for the six months ended June 30, 2017 (in millions) are as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

Beginning Fixed

    

 

 

    

 

 

    

Ending Fixed

    

Revenue

    

Total Revenue

 

 

 

Backlog at

 

Contract

 

Revenue

 

Backlog

 

Recognized from

 

for Six Months

 

 

 

December 31, 

 

Additions to

 

Recognized from

 

at June 30, 

 

Non-Fixed Backlog

 

ended June 30, 

 

Reportable Segment

 

2016

 

Fixed Backlog

 

Fixed Backlog

 

2017

 

Projects

 

2017

 

Power

 

$

469.6

 

$

240.4

 

$

261.2

 

$

448.8

 

$

27.8

 

$

289.0

 

Pipeline

 

 

1,019.4

 

 

132.7

 

 

303.7

 

 

848.4

 

 

14.4

 

 

318.1

 

Utilities

 

 

31.5

 

 

148.6

 

 

85.7

 

 

94.4

 

 

244.2

 

 

329.9

 

Civil

 

 

605.9

 

 

309.5

 

 

250.9

 

 

664.5

 

 

4.8

 

 

255.7

 

Total

 

$

2,126.4

 

$

831.2

 

$

901.5

 

$

2,056.1

 

$

291.2

 

$

1,192.7

 

 

Revenues recognized from non-Fixed Backlog projects shown above are generated by MSA projects and projects completed under time-and-equipment, time-and-materials and cost-reimbursable-plus-fee contracts or are revenue from the sale of construction materials, such as rock or asphalt to outside third parties or sales of water services in the case of BW Primoris.

 

At June 30, 2017, our total Fixed Backlog was $2.06 billion, representing a decrease of $70.3 million, or 3.3%, compared to $2.13 billion as of December 31, 2016. 

 

MSA Backlog

 

The following table outlines historical MSA revenues for the past six quarters ($ in millions):

 

 

 

 

 

 

 

 

Quarterly MSA Revenues

 

 

2016

 

2017

First Quarter

 

105.2

 

105.5

Second Quarter

 

142.2

 

181.0

Third Quarter

 

160.2

 

 

Fourth Quarter

 

168.6

 

 

 

MSA Backlog includes anticipated MSA revenues for the next twelve months. We estimate MSA revenues based on historical trends, anticipated seasonal impacts and estimates of customer demand based on information from our customers. The increase in MSA Backlog at June 30, 2017 is primarily due to the Coastal and FGC acquisitions, which added approximately $50.0 million and $30.0 million, respectively to the total

 

37


 

Table of Contents 

The following table shows our estimated MSA Backlog at June 30, 2017 by reportable segment (in millions):

 

 

 

 

 

 

MSA Backlog

 

 

at June 30, 

 

Reportable Segment:

2017

 

Power

$

42.5

 

Pipeline

 

79.1

 

Utilities

 

569.7

 

Civil

 

3.0

 

Total

$

694.3

 

 

Total Backlog

 

The following table shows total backlog (Fixed Backlog plus MSA Backlog), by reportable segment as of the quarter-end dates shown below (in millions):

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Reportable Segment:

 

June 30, 2016

    

September 30, 2016

    

December 31, 2016

    

March 31, 2017

    

June 30, 2017

 

Power

 

$

376.7

 

$

533.6

 

$

511.9

 

$

577.4

 

$

491.3

 

Pipeline

 

 

437.8

 

 

1,030.3

 

 

1,052.6

 

 

917.1

 

 

927.5

 

Utilities

 

 

490.5

 

 

519.0

 

 

606.5

 

 

672.3

 

 

664.1

 

Civil

 

 

607.9

 

 

612.1

 

 

626.9

 

 

631.7

 

 

667.5

 

Total

 

$

1,912.9

 

$

2,695.0

 

$

2,797.9

 

$

2,798.5

 

$

2,750.4

 

 

We expect that during the next four quarters, we will recognize as revenue approximately 68% of the total backlog at June 30, 2017, comprised of backlog of approximately: 82% of the Power segment; 38% of the Pipeline segment; 100% of the Utilities segment; and 66% of the Civil segment.

 

Backlog should not be considered a comprehensive indicator of future revenues, as a percentage of our revenues are derived from projects that are not part of a backlog calculation. The backlog estimates include amounts from estimated MSA revenues, but our customers are not contractually obligated to purchase an amount of services from us under the MSAs. Any of our contracts, MSA, fixed price or fixed unit price, may be terminated by our customers on relatively short notice. In the event of a project cancellation, we may be reimbursed for certain costs, but typically we have no contractual right to the total revenues reflected in backlog. Projects may remain in backlog for extended periods of time as a result of customer delays, regulatory requirements or project specific issues. Future revenues from projects completed under time-and-equipment, time-and-materials and cost-reimbursable-plus-fee contracts may not be included in our estimated backlog amount.

 

Liquidity and Capital Resources

 

Cash Needs

 

Liquidity represents our ability to pay our liabilities when they become due, fund business operations and meet our contractual obligations and execute our business plan.  Our primary sources of liquidity are our cash balances at the beginning of each period and our net cash flow.  If needed, we have availability under our lines of credit to augment liquidity needs.  In order to maintain sufficient liquidity, we evaluate our working capital requirements on a regular basis.  We may elect to raise additional capital by issuing common stock, convertible notes, term debt or increasing our credit facility, as necessary, to fund our operations or to fund the acquisition of new businesses.

 

Our cash and cash equivalents totaled $111.7 million at June 30, 2017 compared to $135.8 million at December 31, 2016. We anticipate that our cash and investments on hand, existing borrowing capacity under our credit facility and our future cash flows from operations will provide sufficient funds to enable us to meet our operating needs, our planned capital expenditures and our ability to grow for at least the next twelve months. In evaluating our liquidity needs, we consider cash and cash equivalents held by our consolidated VIEs. These amounts, which totaled $48.1 million and $7.0 million as of June 30, 2017 and December 31, 2016, respectively, were not available for general corporate purposes.

 

The construction industry is capital intensive, and we expect to continue to make capital expenditures to meet anticipated needs for our services. Historically, we have invested an amount that approximated the sum of depreciation and amortization expenses plus proceeds from equipment sales. During the six months ended June 30, 2017, capital expenditures were approximately $48.9 million, including assumption of mortgage debt of $4.2 million.  In addition, the

38


 

Table of Contents 

companies acquired during the period added $12.4 million to property, plant and equipment.  For the first six months of 2017, total construction equipment purchases were $23.1 million, while the amount of depreciation, amortization and equipment sales proceeds were approximately $36.4 million.  Capital expenditures for the remaining six months of 2017 are expected to total between $15.0 million and $20.0 million.

 

Cash Flows

 

Cash flows during the six months ended June 30, 2017 and 2016 are summarized as follows:

 

 

 

 

 

 

 

 

 

 

 

Six months ended

 

 

June 30, 

 

    

2017

    

2016

 

 

 

(Thousands)

 

(Thousands)

 

Change in cash:

 

 

 

 

 

 

 

Net cash provided by operating activities

 

$

116,289

 

$

5,498

 

Net cash used in investing activities

 

 

(106,238)

 

 

(40,525)

 

Net cash used in financing activities

 

 

(34,198)

 

 

(28,980)

 

Net change in cash and cash equivalents

 

$

(24,147)

 

$

(64,007)

 

 

Operating Activities

 

The source of our cash flow from operating activities for the six months ended June 30, 2017 and 2016 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Six months ended

 

 

 

 

 

 

June 30, 

 

 

 

 

 

    

2017

    

2016

    

Change

 

 

 

(Thousands)

 

 

 

Operating Activities:

 

 

 

 

 

 

 

 

 

 

Operating income

 

$

53,705

 

$

17,406

 

$

36,299

 

Depreciation and amortization

 

 

31,750

 

 

34,089

 

 

(2,339)

 

Stock-based compensation expense

 

 

690

 

 

710

 

 

(20)

 

Gain on sale of property and equipment

 

 

(3,208)

 

 

(2,293)

 

 

(915)

 

Impairment of intangibles

 

 

477

 

 

 —

 

 

477

 

Changes in assets and liabilities

 

 

55,672

 

 

(35,211)

 

 

90,883

 

Net other income (expense) and tax provision

 

 

(22,797)

 

 

(9,203)

 

 

(13,594)

 

Net cash provided by operating activities

 

$

116,289

 

$

5,498

 

$

110,791

 

 

The net change in assets and liabilities during the six months ended June 30, 2017 resulted in cash provided by the net change of $55.7 million, compared to a net use of cash of $35.2 million in the six months ended June 30, 2016, an improvement in cash flow of $90.9 million. The primary reason for the improvement was an improvement of $41.3 million in accounts receivable for the current year and an increase of $63.4 million in billings in excess of costs and estimated earnings, partially offset by a decrease in accounts payable of $26.0 million.

 

The more significant reasons for the $55.7 million of cash provided by the changes in assets and liabilities during the six months ended June 30, 2017 are outlined as follows:

 

·

Accounts receivable decreased by $43.8 million from December 31, 2016, reflecting successful collection efforts during the first half of 2017. For non-disputed receivables (excluding retainage), our days sales outstanding declined from 47 days at December 31, 2016 to 35 days at June 30, 2017.  In addition to maintaining an excellent collection history, we have certain lien rights that can provide additional security for collections. At June 30, 2017, accounts receivable represented 29.7% of our total assets compared to 33.1% at the end of 2016; 

 

·

Billings in excess of costs and estimated earnings increased by $45.8 million compared to December 31, 2016, primarily reflecting the addition work paid for in advance; 

 

·

Uninstalled inventory decreased by $6.9 million during the first half of 2017; 

 

39


 

Table of Contents 

·

Costs and estimated earnings in excess of billings (“CIE”) increased by $19.6 million compared to December 31, 2016. CIE results primarily from either time lags between revenue recognition and contractual billing terms or the billing lag at the end of each month. The increase during the six months ended June 30, 2017 was primarily due to a $9.5 million increase for Q3C and $8.3 million increase for Primoris Heavy Civil; and

 

·

Accounts payable decreased by $37.1 million and accrued expenses and other current liabilities increased by $8.2 million during the first half of 2017.

 

Investing activities

 

During the six months ended June 30, 2017, we purchased property and equipment for $44.7 million in cash (which is net of assumed mortgage notes of $4.2 million) compared to $42.1 million during the same period in the prior year.  We believe that ownership of equipment is generally preferable to renting equipment on a project-by-project basis, as ownership helps to ensure the equipment is available for our projects when needed. In the past, ownership has resulted in lower overall equipment costs.

 

We received proceeds from the sale of used equipment of $4.7 million during the six months ended June 30, 2017, compared to $5.7 million during the same period in 2016.

 

During the six months ended June 30, 2017, we used $66.2 million for acquisitions, primarily related to FGC and Coastal.  During the six months ended June 30, 2016, we used $4.1 million for the acquisition of Mueller.

 

Financing activities

 

Financing activities used cash of $34.2 million for the six months ended June 30, 2017, which was the net of several transactions, including:

 

·

$24.7 million in repayment of long-term debt and capital leases;

 

·

Dividend payments of $5.7 million to our stockholders;

 

·

Repurchase of $5.0 million of common stock; and

 

·

$1.1 million in proceeds from the issuance of 65,429 shares of common stock purchased by the participants in the Primoris Long-term Retention Plan.

 

Financing activities used cash of $29.0 million for the six months ended June 30, 2016, which was the net of several transactions, including:

 

·

$24.7 million in repayment of long-term debt and capital leases;

 

·

Dividend payments of $5.7 million to our stockholders;

 

·

$1.4 million in proceeds from the issuance of 85,907 shares of common stock purchased by the participants in the Primoris Long-term Retention Plan.

 

Debt Activities

 

For a description of our credit agreements, see Note 10 — “Credit Arrangements” in Item 1, Financial Statements of this Second Quarter 2017 Report.

 

Related party transactions

 

For a discussion of related party transactions, please see Note 12 — “Related Party Transactions” in Item 1, Financial Statements of this Second Quarter 2017 Report.

 

40


 

Table of Contents 

Common stock

 

For a discussion of items affecting our common stock, please see Note 16 — “Stockholders’ Equity” in Item 1, Financial Statements of this Second Quarter 2017 Report.

 

Contractual Obligations

 

As of June 30, 2017, we had $241.5 million of outstanding long-term debt and capital lease obligations and there were no short-term borrowings.

 

A summary of contractual obligations as of June 30, 2017 was as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

Total

    

1 Year

    

2 - 3 Years

    

4 - 5 Years

    

After 5 Years

 

 

 

(In Millions)

 

Long-term debt and capital lease obligations

 

$

241.5

 

$

58.2

 

$

101.1

 

$

45.0

 

$

37.2

 

Interest on long-term debt (1)

 

 

24.1

 

 

6.5

 

 

8.8

 

 

4.5

 

 

4.3

 

Pension plan withdrawal liability

 

 

5.1

 

 

1.1

 

 

2.2

 

 

1.8

 

 

 —

 

Equipment operating leases

 

 

33.1

 

 

11.8

 

 

17.0

 

 

4.3

 

 

 —

 

Contingent consideration obligations

 

 

1.2

 

 

1.2

 

 

 —

 

 

 —

 

 

 —

 

Real property leases

 

 

11.4

 

 

4.1

 

 

5.8

 

 

1.4

 

 

0.1

 

Real property leases—related parties

 

 

2.0

 

 

0.5

 

 

0.7

 

 

0.7

 

 

0.1

 

 

 

$

318.4

 

$

83.4

 

$

135.6

 

$

57.7

 

$

41.7

 

Letters of credit

 

$

15.7

 

$

15.7

 

$

 —

 

$

 —

 

$

 —

 


(1)

The interest amount represents interest payments for our fixed rate debt assuming that principal payments are made as originally scheduled.

 

The table does not include obligations under multi-employer pension plans in which some of our employees participate.  Our multi-employer pension plan contribution rates are generally specified in our collective bargaining agreements, and contributions are made to the plans based on employee payrolls. Our obligations for future periods cannot be determined because we cannot predict the number of employees that we will employ at any given time nor the plans in which they may participate.

 

We may also be required to make additional contributions to multi-employer pension plans if they become underfunded, and these contributions will be determined based on our union payroll. The Pension Protection Act of 2006 added special funding and operational rules for multi-employer plans that are classified as “endangered,” “seriously endangered” or “critical” status.  Plans in these classifications must adopt measures to improve their funded status through a funding improvement or rehabilitation plan, which may require additional contributions from employers.  The amount of additional funds that we may be obligated to contribute cannot be reasonably estimated and is not included in the table above.

 

In November 2011, members of the Pipe Line Contractors Association “PLCA”, including ARB, Rockford and Q3C (prior to the Company’s acquisition in 2012), withdrew from the Central States, Southeast and Southwest Areas Pension Fund multiemployer pension plan (“Plan”) in order to mitigate additional liability in connection with the significantly underfunded Plan.  During the first quarter of 2016, the Company received a final payment schedule for its withdrawal liability.  Based on this schedule, the liability recorded at June 30, 2017 was $5.1 million.  The Company has no plans to withdraw from any other agreements.

 

41


 

Table of Contents 

Off-balance sheet transactions

 

As is common in our industry, we enter into certain off-balance sheet arrangements in the ordinary course of business that result in risks not directly reflected on our balance sheet. We have no off-balance sheet financing arrangement with variable interest entities.  The following represents transactions, obligations or relationships that could be considered material off-balance sheet arrangements.

 

·

Letters of credit issued under our lines of credit. At June 30, 2017, we had letters of credit outstanding of $15.7 million, for international project engineering jobs in our Power segment and for providing security to our insurance carriers.  These letters of credit are used by some of our vendors to ensure reimbursement for amounts that they are disbursing on our behalf, such as beneficiaries under our self-funded insurance program.  In addition, from time to time, certain customers require us to post a letter of credit to ensure payments to our subcontractors or guarantee performance under our contracts. Letters of credit reduce our borrowing availability under our Credit Agreement and Canadian Credit Facility.  If these letters of credit were drawn on by the beneficiary, we would be required to reimburse the issuer of the letter of credit, and we may be required to record a charge to earnings for the reimbursement. As of the date of this Second Quarter 2017 Report, we do not believe that it is likely that any material claims will be made under a letter of credit;

 

·

We enter into non-cancellable operating leases for some of our facilities, equipment and vehicles, including leases with related parties. At June 30, 2017, equipment operating lease commitments were $33.1 million and facility rental commitments were $13.4 million.  Accounting treatment of operating leases will change in accordance with ASU 2016-02 “Leases (Topic 842)”, effective January 1, 2019;    

 

·

In the ordinary course of our business, we may be required by our customers to post surety bid or completion bonds in connection with services that we provide. At June 30, 2017, we had $1.46 billion in outstanding bonds.  As of the date of this Second Quarter 2017 Report, we do not anticipate that we would have to fund material claims under our surety arrangements;

 

·

Certain of our subsidiaries are parties to collective bargaining agreements with unions which may create future obligations not recorded on our balance sheet;

 

·

Other guarantees that we make from time to time, such as guaranteeing the obligations of our subsidiaries; and

 

·

Employment agreements with executive officers or with executives from acquired companies may create obligations at a future date.

 

Receivable Collection Actions

 

As do all construction contractors, we negotiate payments with our customers from time to time, and we may encounter delays in receiving payments from our customers.  The Company has been engaged in dispute resolution to collect money it believes it is owed for one construction project completed  in 2014.  Because of uncertainties associated with the project, including uncertainty of the amounts that would be collected, the Company used a zero profit margin approach to recording revenues during the construction period for the project. 

 

For the project, a cost reimbursable contract, the Company recorded a receivable of $32.9 million with a reserve of approximately $17.8 million included in “billings in excess of costs and estimated earnings”.  At this time, the Company cannot predict the amount that it will collect nor the timing of any collection. The dispute resolution for the receivable initially required international arbitration; however, in the first half of 2016, the owner sought bankruptcy protection in U.S. bankruptcy court. The Company has initiated litigation against the sureties who have provided lien and stop payment release bonds for the total amount owed.  A trial date has been set for the fourth quarter of 2017.

 

Effects of Inflation and Changing Prices

 

Our operations are affected by increases in prices, whether caused by inflation or other economic factors. We attempt to recover anticipated increases in the cost of labor, equipment, fuel and materials through price escalation provisions in certain major contracts or by considering the estimated effect of such increases when bidding or pricing new work or by entering into back-to-back contracts with suppliers and subcontractors.

 

42


 

Table of Contents 

Item 3.  Quantitative and Qualitative Disclosures About Market Risk

 

In the ordinary course of business, we are exposed to risks related to market conditions. These risks primarily include fluctuations in foreign currency exchange rates, interest rates and commodity prices. We may seek to manage these risks through the use of financial derivative instruments. These instruments may include foreign currency exchange contracts and interest rate swaps.

 

We do not execute transactions or use financial derivative instruments for trading or speculative purposes. We enter into transactions with counter parties that are generally financial institutions in a matter to limit significant exposure with any one party.

 

At June 30, 2017, we had no derivative financial instruments.

 

The carrying amounts for cash and cash equivalents, accounts receivable, short-term debt, accounts payable and accrued liabilities shown in the consolidated balance sheets approximate fair value at June 30, 2017 and December 31, 2016, due to the generally short maturities of these items. At June 30, 2017, we held no short term investments.

 

At June 30, 2017, all of our long-term debt was subject to fixed interest rates.

 

Item 4.  Controls and Procedures

 

Disclosure Controls and Procedures

 

As of June 30, 2017, we carried out an evaluation, under the supervision and with the participation of our management, including our Chief Executive Officer (“CEO”) and Chief Financial Officer (“CFO”), of the effectiveness of the design and operation of our “disclosure controls and procedures”, as such term is defined under Exchange Act Rules 13a-15(e) and 15d-15(e).

 

Based on this evaluation, our CEO and CFO concluded that, at June 30, 2017, the disclosure controls and procedures were effective at the reasonable assurance level to ensure that information required to be disclosed by us in the reports we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in the rules and forms of the SEC, and accumulated and communicated to our management, including our CEO and CFO, as appropriate to allow timely decisions regarding required disclosure.

 

In designing and evaluating the disclosure controls and procedures, our management recognized that any controls and procedures, no matter how well designed and operated, can provide only reasonable assurance of achieving the desired control objectives. In reaching a reasonable level of assurance, our management necessarily was required to apply its judgment in evaluating the cost-benefit relationship of possible controls and procedures.  The Company’s disclosure controls and procedures are designed to provide reasonable assurance of achieving their stated objectives. We anticipate continuing enhancement of our controls, especially as we complete the process of integrating our financial and operations information systems onto a common platform.

 

Changes in Internal Control Over Financial Reporting

 

During the quarter ended June 30, 2017, there were no changes to our internal control over financial reporting practices or processes that materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

 

43


 

Table of Contents 

Part II. Other Information

 

Item 1.  Legal Proceedings

 

The Company has been engaged in dispute resolution to collect money it believes it is owed for one construction project completed in 2014.  Because of uncertainties associated with the project, including uncertainty of the amounts that would be collected, the Company used a zero profit margin approach to recording revenues during the construction period for the project. 

 

For the project, a cost reimbursable contract, the Company recorded a receivable of $32.9 million with a reserve of approximately $17.8 million included in “billings in excess of costs and estimated earnings”.  At this time, the Company cannot predict the amount that it will collect nor the timing of any collection. The dispute resolution for the receivable initially required international arbitration; however, in the first half of 2016, the owner sought bankruptcy protection in U.S. bankruptcy court. The Company has initiated litigation against the sureties who have provided lien and stop payment release bonds for the total amount owed.  A trial date has been set for the fourth quarter of 2017.

 

The Company is subject to other claims and legal proceedings arising out of its business. The Company provides for costs related to contingencies when a loss from such claims is probable and the amount is reasonably determinable. In determining whether it is possible to provide an estimate of loss, or range of possible loss, the Company reviews and evaluates its litigation and regulatory matters on a quarterly basis in light of potentially relevant factual and legal developments. If we determine an unfavorable outcome is not probable or reasonably estimable, we do not accrue for a potential litigation loss. Management is unable to ascertain the ultimate outcome of other claims and legal proceedings; however, after review and consultation with counsel and taking into consideration relevant insurance coverage and related deductibles/self-insurance retention, management believes that it has meritorious defenses to the claims and believes that the reasonably possible outcome of such claims will not, individually or in the aggregate, have a materially adverse effect on the consolidated results of operations, financial condition or cash flows of the Company.

 

SEC Inquiry – The Company has been cooperating with an inquiry by the staff of the Securities and Exchange Commission, which appears to be focused on certain percentage-of-completion contract revenue recognition practices of the Company during the time period 2013 and 2014.  We are continuing to respond to the staff’s inquiries in connection with this matter.  At this stage, the Company is unable to predict when the staff’s inquiry will conclude or the outcome.

 

 

Item 1A.  Risk Factors.

 

In addition to the information set forth in this Report, you should carefully consider the factors discussed in the section entitled “Risk Factors” in our Annual Report on Form 10-K for the year ended December 31, 2016, which to our knowledge have not materially changed. Those risks, which could materially affect our business, financial condition or future results, are not the only risks we face. Additional risks and uncertainties not currently known to us or that we currently deem to be immaterial also may materially adversely affect our business, financial condition and/or operating results.

 

Item 2.  Unregistered Sales of Equity Securities and Use of Proceeds.

 

None

 

Item 3.  Defaults Upon Senior Securities.

 

None.

 

Item 4.  (Removed and Reserved).

 

Item 5.  Other Information.

 

None.

44


 

Table of Contents 

Item 6.  Exhibits.

 

The following exhibits are filed as part of this Quarterly Report on Form 10-Q.

 

Exhibit
Number

    

Description

31.1

 

Rule 13a-14(a)/15d-14(a) Certification by the Registrant’s Chief Executive Officer (*)

31.2

 

Rule 13a-14(a)/15d-14(a) Certification by the Registrant’s Chief Financial Officer (*)

32.1

 

Section 1350 Certification by the Registrant’s Chief Executive Officer (*)

32.2

 

Section 1350 Certification by the Registrant’s Chief Financial Officer (*)

101 INS

 

XBRL Instance Document (*)

101 SCH

 

XBRL Taxonomy Extension Schema Document (*)

101 CAL

 

XBRL Taxonomy Extension Calculation Linkbase Document (*)

101 LAB

 

XBRL Taxonomy Extension Label Linkbase Document (*)

101 PRE

 

XBRL Taxonomy Extension Presentation Linkbase Document (*)

101 DEF

 

XBRL Taxonomy Extension Definition Linkbase Document (*)


(*)Filed herewith

 

45


 

Table of Contents 

SIGNATURES

 

Pursuant to the requirements of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

 

 

PRIMORIS SERVICES CORPORATION

 

 

Date:  August 7, 2017

/s/ PETER J. MOERBEEK

 

Peter J. Moerbeek

 

Executive Vice President, Chief Financial Officer (Principal Financial and Accounting Officer)

 

 

46


 

Table of Contents 

EXHIBITS ATTACHED TO THIS QUARTERLY REPORT ON FORM 10-Q

 

Exhibit
Number

    

Description

31.1

 

Rule 13a-14(a)/15d-14(a) Certification by the Registrant’s Chief Executive Officer (*)

31.2

 

Rule 13a-14(a)/15d-14(a) Certification by the Registrant’s Chief Financial Officer (*)

32.1

 

Section 1350 Certification by the Registrant’s Chief Executive Officer (*)

32.2

 

Section 1350 Certification by the Registrant’s Chief Financial Officer (*)

101 INS

 

XBRL Instance Document (*)

101 SCH

 

XBRL Taxonomy Extension Schema Document (*)

101 CAL

 

XBRL Taxonomy Extension Calculation Linkbase Document (*)

101 LAB

 

XBRL Taxonomy Extension Label Linkbase Document (*)

101 PRE

 

XBRL Taxonomy Extension Presentation Linkbase Document (*)

101 DEF

 

XBRL Taxonomy Extension Definition Linkbase Document (*)


(*)Filed herewith

 

47