Annual Statements Open main menu

GOLDEN ENTERTAINMENT, INC. - Quarter Report: 2005 October (Form 10-Q)

e10vq
Table of Contents

 
 
UNITED STATES SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
 
Form 10-Q
     
(Mark One)    
þ
  QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
 
    For the quarterly period ended October 2, 2005
 
OR
 
o
  TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
 
    For the transition period from           to
Commission File No. 0-24993
LAKES ENTERTAINMENT, INC.
(Exact name of registrant as specified in its charter)
     
Minnesota   41-1913991
(State or other jurisdiction
of incorporation or organization)
  (I.R.S. Employer
Identification No.)
 
130 Cheshire Lane
Minnetonka, Minnesota
(Address of principal executive offices)
  55305
(Zip Code)
(952) 449-9092
(Registrant’s telephone number, including area code)
     Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.     Yes o          No þ
      Indicate by check mark whether the registrant is an accelerated filer (as defined in Rule 12b-2 of the Exchange Act).     Yes þ          No o
      Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).     Yes o          No þ
      As of December 9, 2005, there were 22,299,909 shares of Common Stock, $0.01 par value per share, outstanding.
 
 


 

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
INDEX
                 
        Page of
        Form 10-Q
         
PART I. FINANCIAL INFORMATION
  ITEM 1.     FINANCIAL STATEMENTS        
         Condensed Consolidated Balance Sheets as of October 2, 2005 (unaudited) and January 2, 2005     3  
         Unaudited Condensed Consolidated Statements of Loss for the three months ended October 2, 2005 and October 3, 2004 (restated)     4  
         Unaudited Condensed Consolidated Statements of Comprehensive Loss for the three months ended October 2, 2005 and October 3, 2004 (restated)     5  
         Unaudited Condensed Consolidated Statements of Loss for the nine months ended October 2, 2005 and October 3, 2004 (restated)     6  
         Unaudited Condensed Consolidated Statements of Comprehensive Loss for the nine months ended October 2, 2005 and October 3, 2004 (restated)     7  
         Unaudited Condensed Consolidated Statements of Cash Flows for the nine months ended October 2, 2005 and October 3, 2004 (restated)     8  
         Notes to Unaudited Condensed Consolidated Financial Statements     9  
 ITEM 2.    MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS     21  
 ITEM 3.    QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK     57  
 ITEM 4.    CONTROLS AND PROCEDURES     58  
 PART II. OTHER INFORMATION
 ITEM 1.    LEGAL PROCEEDINGS     58  
 ITEM 6.    EXHIBITS     61  
 Certification of CEO Pursuant to Section 302
 Certification of CFO Pursuant to Section 302
 Certification of CEO & CFO Pursuant to Section 302

2


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Consolidated Balance Sheets
October 2, 2005 and January 2, 2005
                   
    October 2,   January 2,
    2005   2005
         
    (Unaudited)
    (In thousands)
ASSETS
Current assets:
               
 
Cash and cash equivalents (balance includes $3.0 million and $4.5 million of WPT Enterprises, Inc. cash)
  $ 16,723     $ 28,717  
 
Short-term investments (balance includes $27.5 million and $27.8 million of WPT Enterprises, Inc. short-term investments)
    27,471       28,930  
 
Accounts receivable, net of allowance of $0.1 million and $0
    1,509       2,038  
 
Deferred tax asset
    95       137  
 
Prepaids
    1,025       1,233  
 
Other current assets
    1,842       1,159  
             
Total current assets
    48,665       62,214  
             
Property and equipment, net of accumulated depreciation
    12,555       6,795  
             
Long-term assets related to Indian casino projects
               
 
Notes receivable, Indian Tribes
    77,789       67,066  
 
Land held for development
    16,164       15,433  
 
Intangible asset related to acquisition of management contracts
    44,290       41,096  
 
Other
    4,247       2,024  
             
Total long-term assets related to Indian casino projects
    142,490       125,619  
             
 
Investments
    260       6,093  
 
Deferred tax asset
    4,278       4,278  
 
Other
    4,586       4,090  
             
Total assets
  $ 212,834     $ 209,089  
             
 
LIABILITIES AND SHAREHOLDERS’ EQUITY
Current liabilities:
               
 
Accounts payable
  $ 12,970     $ 780  
 
Income taxes payable
    10,619       5,457  
 
Accrued payroll and related costs
    941       891  
 
Deferred revenue
    4,764       3,280  
 
Other accrued expenses
    3,611       3,449  
             
Total liabilities
    32,905       13,857  
             
Commitments and contingencies
               
Common shares issued by subsidiary subject to repurchase
          618  
Minority interest
    11,000       11,222  
Shareholders’ equity:
               
 
Capital stock, $.01 par value; authorized 200,000 shares; 22,300 and 22,253 common shares issued and outstanding at October 2, 2005 and January 2, 2005, respectively
    223       223  
 
Additional paid-in capital
    158,316       157,895  
 
Retained earnings
    10,469       25,280  
 
Accumulated other comprehensive loss
    (79 )     (6 )
             
Total shareholders’ equity
    168,929       183,392  
             
Total liabilities and shareholders’ equity
  $ 212,834     $ 209,089  
             
The accompanying notes are an integral part of these consolidated financial statements.

3


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Consolidated Statements of Loss
                     
    Three Months Ended
     
    October 2,   October 3,
    2005   2004
         
        (Restated)
    (Unaudited)
    (In thousands, except
    loss per share)
Revenues:
               
 
License fee income
  $ 1,766     $ 2,854  
 
Host fees, sponsorship and other
    365       119  
             
   
Total revenues
    2,131       2,973  
             
Costs and expenses:
               
 
Selling, general and administrative
    6,936       3,697  
 
Production costs
    561       1,942  
 
Net impairment losses
    94        
 
Depreciation
    133       163  
             
   
Total costs and expenses
    7,724       5,802  
 
Net unrealized gain (loss) on notes receivable
    (2,120 )     790  
             
Loss from operations
    (7,713 )     (2,039 )
             
Other income:
               
 
Interest income
    443       104  
 
Other
          1  
             
   
Total other income
    443       105  
             
Loss before income taxes, equity in earnings (loss) of investments and minority interest
    (7,270 )     (1,934 )
Income tax provision (benefit)
    354       (791 )
             
Loss before equity in earnings (loss) of investments and minority interest
    (7,624 )     (1,143 )
Equity in earnings (loss) of investments, net of tax
    1       (19 )
             
Loss before minority interest
    (7,623 )     (1,162 )
Minority interest in net (income) loss of subsidiary
    581       (53 )
             
Net loss
  $ (7,042 )   $ (1,215 )
             
Loss per share, basic and diluted
  $ (0.32 )   $ (0.05 )
             
Weighted average common shares outstanding
    22,300       22,232  
             
The accompanying notes are an integral part of these consolidated financial statements.

4


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Consolidated Statements of Comprehensive Loss
                   
    Three Months Ended
     
    October 2,   October 3,
    2005   2004
         
        (Restated)
    (Unaudited)
    (In thousands)
Net loss
  $ (7,042 )   $ (1,215 )
Other comprehensive loss, net of tax:
               
 
Unrealized gain (loss) on securities
    (37 )     3  
             
Comprehensive loss
  $ (7,079 )   $ (1,212 )
             
The accompanying notes are an integral part of these consolidated financial statements.

5


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Consolidated Statements of Loss
                     
    Nine Months Ended
     
    October 2,   October 3,
    2005   2004
         
        (Restated)
    (Unaudited)
    (In thousands, except
    loss per share)
Revenues:
               
 
License fee income
  $ 10,568     $ 10,266  
 
Host fees, sponsorship and other
    2,266       1,565  
             
   
Total revenues
    12,834       11,831  
             
Costs and expenses:
               
 
Selling, general and administrative
    20,368       10,088  
 
Production costs
    8,125       7,059  
 
Net impairment losses
    94       5,833  
 
Depreciation
    337       456  
             
   
Total costs and expenses
    28,924       23,436  
 
Net unrealized gain (loss) on notes receivable
    (241 )     1,318  
             
Loss from operations
    (16,331 )     (10,287 )
             
Other income:
               
 
Interest income
    1,256       195  
 
Other
          42  
             
   
Total other income
    1,256       237  
             
Loss before income taxes, equity in earnings of investments and minority interest
    (15,075 )     (10,050 )
Income tax provision (benefit)
    1,061       (1,667 )
             
Loss before equity in earnings of investments and minority interest
    (16,136 )     (8,383 )
Equity in earnings of investments, net of tax
    7       227  
             
Loss before minority interest
    (16,129 )     (8,156 )
Minority interest in net (income) loss of subsidiary
    1,317       (53 )
             
Net loss
  $ (14,812 )   $ (8,209 )
             
Loss per share, basic and diluted
  $ (0.66 )   $ (0.37 )
             
Weighted average common shares outstanding
    22,296       22,063  
             
The accompanying notes are an integral part of these consolidated financial statements.

6


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Consolidated Statements of Comprehensive Loss
                   
    Nine Months Ended
     
    October 2,   October 3,
    2005   2004
         
        (Restated)
    (Unaudited)
    (In thousands)
Net loss
  $ (14,812 )   $ (8,209 )
Other comprehensive loss, net of tax:
               
 
Unrealized gain (loss) on securities
    (73 )     3  
             
Comprehensive loss
  $ (14,885 )   $ (8,206 )
             
The accompanying notes are an integral part of these consolidated financial statements.

7


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Condensed Consolidated Statements of Cash Flows
                     
    Nine Months Ended
     
    October 2,   October 3,
    2005   2004
         
        (Restated)
    (Unaudited)
    (In thousands)
OPERATING ACTIVITIES:
               
 
Net loss
  $ (14,812 )   $ (8,209 )
 
Adjustments to reconcile net loss to net cash used in operating activities:
               
   
Depreciation
    337       456  
   
Production depreciation
    191        
   
Stock-based compensation expense
    772       545  
   
Equity in earnings of investments
    (7 )     (227 )
   
Deferred income taxes
    42       (1,509 )
   
Net impairment losses
    94       5,833  
   
Net unrealized losses (gains) on notes receivable
    241       (1,318 )
   
Minority interest
    (1,317 )     53  
 
Changes in operating assets and liabilities:
               
   
Accounts receivable
    529       456  
   
Prepaid expenses
    208        
   
Other current assets
    (683 )     767  
   
Income taxes
    5,162       (928 )
   
Accounts payable
    (421 )     (1,279 )
   
Deferred revenue
    1,484       3,562  
   
Accrued expenses
    212       67  
             
Net cash used in operating activities
    (7,968 )     (1,731 )
             
INVESTING ACTIVITIES:
               
 
Short-term investment securities
    1,387       (7,188 )
 
Payments for land held under contract for sale
          (327 )
 
Proceeds from land held under contract for sale
    5,000        
 
Advances on long-term assets related to Indian casino projects
    (9,284 )     (10,987 )
 
Payments to unconsolidated affiliates
    (10 )     (257 )
 
Proceeds from unconsolidated affiliates
    850       1,683  
 
Payments for other long-term assets
    (693 )     (936 )
 
Decrease in other long-term assets
    197        
 
Purchase of property and equipment
    (1,599 )     (605 )
             
Net cash used in investing activities
    (4,152 )     (18,617 )
             
FINANCING ACTIVITIES:
               
 
Proceeds from sale of common stock
    126       3,905  
 
Net proceeds from issuance of common stock by subsidiary
          32,458  
             
Net cash provided by financing activities
    126       36,363  
             
Net (decrease) increase in cash and cash equivalents
    (11,994 )     16,015  
Cash and cash equivalents — beginning of period
    28,717       25,340  
             
Cash and cash equivalents — end of period
  $ 16,723     $ 41,355  
             
SUPPLEMENTAL DISCLOSURES OF CASH FLOW INFORMATION:
               
 
Cash paid during the period for:
               
   
Income taxes
  $ 50     $ 165  
 
Noncash operating activities:
               
   
Capitalized television costs related to unit options issued to consultants
  $     $ 202  
   
Acquisition of long-term assets and advances related to Indian casino projects
  $ 2,887     $ 801  
   
Acquisitions of property and equipment financed with accounts payable
  $ 4,689     $  
The accompanying notes are an integral part of these condensed consolidated financial statements.

8


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements
1. BUSINESS OVERVIEW AND ACCOUNTING POLICIES
Business Overview
      Lakes Entertainment, Inc. and Subsidiaries, a Minnesota corporation (“Lakes” or the “Company”), has development agreements for various Indian-owned casino properties and intends to manage such casinos when applicable regulatory approvals have been received and other contingencies have been satisfied. Lakes is also involved in other businesses, including development of a Company-owned casino and the purchase/license or development of new table game concepts for licensing to other casinos. In addition, as of October 2, 2005, Lakes owned approximately 62% of WPT Enterprises, Inc. (“WPTE”), a separate publicly held media and entertainment company principally engaged in the development, production and marketing of poker-themed televised programming, the licensing and sale of branded products and the sale of corporate sponsorships. Lakes’ unaudited condensed consolidated financial statements include the results of operations of WPTE, and in recent periods, all of Lakes’ revenues have been derived from WPTE’s business.
      Lakes, through various subsidiaries, has entered into the following contracts for the development, and management of new casino operations, all of which are subject to various regulatory approvals and in some cases resolution of legal proceedings:
  •  Lakes has contracts to develop and manage The Foothill Oaks Casino, to be built on the Rancheria of the Shingle Springs Band of Miwok Indians (“Shingle Springs Tribe”) in El Dorado County, California, adjacent to U.S. Highway 50, approximately 30 miles east of Sacramento, California (the “Shingle Springs Casino”).
 
  •  Lakes has contracts to develop and manage the Four Winds Casino resort to be built on land to be placed into trust for the Pokagon Band of Potawatomi Indians (“Pokagon Band”) in New Buffalo Township, Michigan near Interstate 94. The casino location will be near the first Interstate 94 exit in southwestern Michigan and approximately 75 miles east of Chicago (the “Pokagon Casino”).
 
  •  Lakes has contracts to develop and manage a casino to be built on the Rancheria of the Jamul Indian Village (“Jamul Tribe”) located on State Highway 94, approximately 20 miles east of San Diego, California (the “Jamul Casino”).
 
  •  Lakes has consulting agreements and management contracts with three wholly-owned subsidiaries of the Pawnee Tribal Development Corporation (“Pawnee TDC” referred to collectively as the “Pawnee Nation”) in connection with assisting the Pawnee Nation in developing, equipping and managing three separate casino destinations.
 
  •  Lakes has consulting agreements and management contracts with the Iowa Tribe of Oklahoma (the “Iowa Tribe”) in connection with developing, equipping and managing a new casino and the Tribe’s existing Cimarron casino.
      Lakes entered into consulting agreements and management contracts with the Kickapoo Traditional Tribe of Texas (the “Kickapoo Tribe”) effective as of January 2005 to improve the performance of the Kickapoo Tribe’s existing Lucky Eagle Casino in Eagle Pass, Texas, located approximately 140 miles southwest of San Antonio. During the third quarter of fiscal 2005 the Company’s relationship with the Kickapoo Tribe deteriorated and in November 2005, Lakes and the Kickapoo Tribe terminated their business relationship (Note 10).
Basis of Presentation
      The unaudited condensed consolidated financial statements of the Company have been prepared pursuant to the rules and regulations of the Securities and Exchange Commission (“SEC”) applicable to interim

9


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
financial information. Accordingly, certain information normally included in the annual financial statements prepared in accordance with accounting principles generally accepted in the United States has been condensed or omitted. For further information, please refer to the annual audited consolidated financial statements of the Company, and the related notes, as restated (Note 2) included within the Company’s Annual Report on Form 10-K for the year ended January 2, 2005, previously filed with the SEC on December 2, 2005, from which the balance sheet information as of that date is derived.
      In the opinion of management, all adjustments considered necessary for a fair presentation have been included, consisting only of normal recurring adjustments. The results for the current interim period are not necessarily indicative of the results to be expected for the full year.
      In addition to the restatements discussed in Note 3, certain amounts, as previously reported, have been reclassified to conform to the current period presentation.
2. MANAGEMENT’S FINANCIAL PLANS
      As of December 9, 2005, Lakes’ unaudited cash balance, excluding WPTE cash, was approximately $5.5 million. Lakes’ future quarterly corporate costs are expected to approximate $3.5 million and future quarterly development project-related costs are expected to approximate $3.5 million, however, a portion of these costs are discretionary and could be deferred if necessary. It is anticipated that Lakes will require additional capital through either public or private financings to fund operating expenses and development project-related costs during the remainder of 2005 and 2006 and the Company is currently considering various financing alternatives. The Company believes that its assets provide sufficient collateral to obtain the necessary financing. The assets of Lakes include common shares of WPTE that have an estimated fair value of $82.6 million as of December 9, 2005, based on the public trading price, on that date, which may not be indicative of what Lakes could realize in a sale of its WPTE shares. The Company believes the shares of WPTE could be the source or part of the collateral for the additional financing. In addition, the Company continues to pursue engaging an investment banking firm to explore strategic alternatives for the Company’s shares of common stock of WPTE which may include the sale of part or all of such shares to fund Lakes’ operational and development needs. See Note 11 — subsequent events regarding Financing Facility.
3. RESTATEMENT
      During 2005, as a result of discussions with the staff of the SEC, the Company re-evaluated its accounting methodology surrounding its contractual relationships with Indian tribes and determined that it should have separately recognized the separate elements of its development and management agreements with the Indian tribes. Historically the Company recorded its advances to Indian tribes as notes receivable and deferred recognition of interest income due to the contingent repayment terms of the notes. The Company has now determined that as advances are made to the tribe pursuant to the development relationship it should have given separate recognition to the contractual notes receivable established and the related interests in management contracts that are acquired in conjunction with the development agreements. As a result the accompanying unaudited condensed consolidated financial statements for the three and nine months ended as of October 3, 2004 have been restated from amounts previously reported to reflect these accounting changes

10


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
retroactively. A summary of the effects of the restatement on the results of operations for the quarterly period and nine month period ended October 3, 2004, follows (in thousands, except per share data):
                                 
    For the       For the    
    Three Months   For the   Nine Months   For the
    Ended   Three Months   Ended   Nine Months
    October 3, 2004,   Ended   October 3, 2004,   Ended
    As Previously   October 3, 2004,   As Previously   October 3, 2004,
Consolidated Statement of Earnings (Loss)   Reported   Restated   Reported   Restated
                 
Net impairment losses
  $     $     $     $ 5,833  
Total costs and expenses
    5,815       5,802       24,047       23,436  
Net unrealized gains on notes receivable
          790             1,318  
Loss from operations
    (2,841 )     (2,039 )     (12,215 )     (10,287 )
Income tax benefit
    (1,101 )     (791 )     (2,028 )     (1,667 )
Net loss
  $ (1,718 )   $ (1,215 )   $ (9,636 )   $ (8,209 )
Basic loss per share
  $ (0.08 )   $ (0.05 )   $ (0.44 )   $ (0.37 )
Diluted loss per share
  $ (0.08 )   $ (0.05 )   $ (0.44 )   $ (0.37 )
The following table illustrates the effect of the restatement on retained earnings:
         
    October 3, 2004
     
Retained earnings, as previously reported
  $ 15,282  
Restatement adjustment
    5,830  
       
Retained earnings, as restated
  $ 21,112  
       
4. INVESTMENTS
Membership Interest in Metroflag Polo, LLC
      On July 15, 2005, the Company received a $5.0 million payment from Metroflag Polo, LLC (“Metroflag”), in full satisfaction of the Company’s membership interest in Metroflag, which approximated the carrying value of the asset on the unaudited condensed consolidated balance sheet. Accordingly, no gain or loss will be recorded in future periods related to this transaction.
5. STOCK BASED COMPENSATION
      The Company accounts for its employee stock option plans under the recognition and measurement principles of Accounting Principles Board Opinion No. 25, Accounting for Stock Issued to Employees, and related Interpretations.
      The following table illustrates the effect on net loss and loss per share if the Company had applied the fair value recognition provisions of Statement of Financial Accounting Standards No. 123, Accounting for Stock-

11


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
Based Compensation (SFAS No. 123), to stock-based employee compensation (in thousands, except per share data).
                                   
    Three Months Ended   Nine Months Ended
         
    October 2,   October 3,   October 2,   October 3,
    2005   2004   2005   2004
                 
        Restated       Restated
Net loss:
  $ (7,042 )   $ (1,215 )   $ (14,812 )   $ (8,209 )
As reported
                               
 
Less: Total stock-based compensation expense determined under the fair value method, net of related tax effects
    (1,132 )     (686 )     (3,176 )     (1,405 )
Pro forma
  $ (8,174 )   $ (1,901 )   $ (17,988 )   $ (9,614 )
Net loss per share, basic and diluted:
                               
 
As reported
  $ (0.32 )   $ (0.05 )   $ (0.66 )   $ (0.37 )
 
Pro forma
  $ (0.37 )   $ (0.09 )   $ (0.81 )   $ (0.44 )
6. LOSS PER SHARE
      For all periods, basic loss per share, is calculated by dividing the loss by the weighted average number of common shares outstanding. The effects of stock options and warrants have not been included in diluted loss per share for the three months ended or nine months ended October 2, 2005 and October 3, 2004 as the effect would have been anti-dilutive as a result of losses.
7. INCOME TAXES
      In accordance with SFAS No. 109, Lakes evaluated the ability to utilize deferred tax assets arising from net operating loss carry forwards, deferred tax assets and other ordinary items and determined that a valuation allowance was appropriate at October 2, and January 2, 2005. Lakes evaluated all evidence and determined net losses generated over the past three years outweighed the current positive evidence that the Company believes exists surrounding its ability to generate significant income from its long-term assets related to Indian casino projects. Therefore, the Company recorded a 100% valuation allowance against these items at October 2, and January 2, 2005. However, the Company has recognized a deferred tax asset related to capital losses during 2001 to 2004. The realization of these benefits is dependant on the generation of capital gains. The Company believes it will have sufficient capital gains in the foreseeable future to utilize these benefits due to significant appreciation in its investment in WPTE, which has a minimal cost basis. The Company owns approximately 12.5 million shares of WPTE common stock valued at approximately $82.6 million as of December 9, 2005 based upon the closing stock price as reported by Nasdaq on December 9, 2005 of $6.62.
      The Company is currently under examination for income and franchise tax matters. See Note 8 regarding the IRS Tax Audit and the Louisiana Department of Revenue Litigation Tax Matter.

12


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
8. COMMITMENTS AND CONTINGENCIES:
Tribal Commitments
      The Company’s development agreements with its tribal partners require the Company to provide financial support related to project development, in the form of loans.
                         
    Tribal Casino Development Advances/Commitments
    As of October 2, 2005
     
    Pre-Construction   Land Held for   Remaining
    Advances   Development   Commitment
             
    (In thousands)
Jamul Tribe
  $ 15,885     $ 6,612     $ 7,503  
Shingle Springs Tribe
    36,410       8,810       4,780  
Pokagon Band
    45,813             27,187  
Kickapoo Tribe*
    947       667       386  
Pawnee Nation
    2,059              
Iowa Tribe
    167       76       757  
 
Refer to Note 10 for further information regarding the Kickapoo Tribe project.
      For the Pokagon Casino project, the Company has agreed to provide additional financing from its own funds if financing to the Pokagon Band at an interest rate not to exceed 13% is not available from third parties. If this occurs and Lakes is required to provide all financing, this would be an additional commitment of up to approximately $54 million. Based on discussions with prospective lenders, management presently believes that third-party financing will be available for this project. However, there can be no assurance that third-party financing will be available at the time the project begins construction.
      Once the Pokagon Casino is open and Lakes is the manager of the casino, the Company will be obligated to pay an amount to an unrelated third party related to a settlement and release agreement associated with Lakes obtaining the management contract with the Pokagon Band. The obligation is payable quarterly for five years so long as Lakes is the manager of the casino, and the maximum liability over the five-year period is approximately $11 million.
      Lakes may be required to provide a guarantee of tribal debt financing or otherwise provide support for the tribal obligations related to any of the projects. Any guarantees by Lakes will be recorded as a liability on the Company’s consolidated financial statements at the fair value of the guarantee at its inception.
Common Shares Subject to Repurchase
      WPTE violated certain securities laws in connection with its initial public offering by sending out written email communications to individuals that did not contain all of the information required to be in a prospectus and were not preceded or accompanied by a prospectus meeting the requirements for a prospectus. These violations could require WPTE to repurchase shares sold in the offering to direct recipients of the email communications for a period of up to one year at the offering price plus interest. WPTE sold 75,200 shares in the offering that were subject to such repurchase rights, and these shares were classified as common shares subject to repurchase as of January 2, 2005. As of August 9, 2005, the one-year anniversary of WPTE’s initial public offering, WPTE’s repurchase obligation with respect to such shares expired, and these shares were reclassified as equity as of October 2, 2005.

13


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
IRS Tax Audit
      The Company’s federal income tax returns are under audit by the Internal Revenue Service (“IRS”) for the fiscal years ended 2001 and 2000 related to the treatment of income categorized as a capital gain. If the Company is unsuccessful in sustaining its position the Company may be required to pay up to approximately $3.2 million plus interest and penalties related to tax on ordinary income, but this would be offset by re-establishing capital losses that would then be available to offset future capital gains, if any. The Company believes it will have sufficient capital gains in the foreseeable future to utilize these benefits due to significant appreciation in its investment in WPTE. The Company owns approximately 12.5 million shares of WPTE common stock valued at approximately $82.6 million as of December 9, 2005 based upon the closing stock price as reported by Nasdaq on December 9, 2005 of $6.62. Lakes’ basis in the WPTE common stock is minimal.
Leases
      The Company leases certain property and equipment, including an airplane, under non-cancelable operating leases. The Company’s airplane lease contained a residual value guarantee of $7.5 million. Rent expense, under non-cancelable operating leases, exclusive of real estate taxes, insurance, and maintenance expense was $0.2 million and $0.1 million for the three month period ended October 2, 2005 and October 3, 2004, respectively and $1.3 million and $0.3 million for the nine month period ended October 2, 2005 and October 3, 2004, respectively. During 2004, the Company determined that the value of the aircraft had decreased to $6.1 million. Therefore, the Company began accruing the expected deficiency over the remaining term of the lease. This resulted in additional expense of $0.6 million in the fourth quarter of fiscal 2004 and $0.8 million in fiscal 2005. At the end of the lease term in April 2005 a determination of the actual deficiency was made and based on that determination a payment of $1.4 million was made during August 2005.
      The airplane lease was amended on May 1, 2005, which allows for a base term of one year and two one-year renewal terms. Total future minimum lease payments due under this lease are approximately $1.7 million payable ratably over the three-year lease term. Under the lease agreement, the Company has the option of renewing the lease, purchasing the airplane at amounts which range from approximately $5.2 million to $5.8 million or facilitating the sale of the aircraft at the end of each term included in the up to three year lease term; however at the conclusion of the lease, the Company is required to purchase the airplane or facilitate the sale of the airplane. The Company’s airplane lease contains a residual value guarantee of $5.2 million at the end of the three year lease term.
Legal Proceedings
Slot Machine Litigation
      In 1994, William H. Poulos filed a class-action lawsuit in the United States District Court for the Middle District of Florida against various parties, including Lakes’ predecessor Grand Casinos and numerous other parties alleged to be casino operators or slot machine manufacturers. This lawsuit was followed by several additional lawsuits of the same nature against the same, as well as additional defendants, all of which were subsequently consolidated into a single class-action pending in the United States District Court for the District of Nevada. Following a court order dismissing all pending pleadings and allowing the plaintiffs to re-file a single complaint, a complaint has been filed containing substantially identical claims, alleging that the defendants fraudulently marketed and operated casino video poker machines and electronic slot machines, and asserting common law fraud and deceit, unjust enrichment and negligent misrepresentation and claims under the federal Racketeering-Influenced and Corrupt Organizations Act. Various motions were filed by the defendants seeking to have this new complaint dismissed or otherwise limited. In December 1997, the Court, in general, ruled on all motions in favor of the plaintiffs. The plaintiffs then filed a motion seeking class certification and the defendants opposed it. In June 2002, the Court entered an order denying class

14


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
certification. On August 10, 2004, the Ninth Circuit Court of Appeals affirmed the District Court’s denial of class certification. On September 14, 2005, the United States District Court for the District of Nevada granted the defendants’ motions for summary judgment, and judgment was entered against the plaintiffs on that same day. The defendants have also filed motions seeking the payment of costs and attorney fees and defendants have until December 28, 2005 to complete their briefing on the motions.
      The Company has not recorded any liability for this matter as currently an estimate of any possible loss cannot be made. Management currently believes that the final outcome of this matter is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
Willard Eugene Smith Litigation
      On October 24, 2003, Lakes announced that it had been named as one of a number of defendants in a counterclaim filed in state court in Harris County, Texas by Willard Eugene Smith involving Kean Argovitz Resorts, LLC (KAR) and related persons and entities. In the counterclaim, Smith asserted that, under an alleged oral agreement with Kevin Kean, he is entitled to a percentage of fees to be received by the KAR Entities or their principals relating to the Shingle Springs and Jamul Casinos that Lakes’ subsidiaries are developing in California. Smith also sought recovery of damages through the remedy of either attachment of the management fees generated from the projects or avoidance of buyout agreements between Lakes and KAR based on their conduct with respect to the alleged agreement. Trial for the above litigation commenced in April 2005. In May 2005, the jury in the state court case reached a verdict in favor of Lakes and the other defendants. The jury in the case found that there was no agreement with Smith relating to the ongoing monthly payments for the percentage of management fees. The jury also found that Smith was not entitled to damages. As a result of the verdict against Smith, a second phase of the trial, which would have sought to recover from Lakes any damages awarded, will not be necessary. Smith filed a Motion for a Partial Retrial on the issue of damages which was denied automatically by operation of law. Smith failed to timely file an appeal to the Texas Court of Appeals, so the judgment has become final.
El Dorado County, California Litigation
      On January 3, 2003, El Dorado County filed an action in the Superior Court of the State of California, seeking to prevent the construction of a highway interchange that was approved by a California state agency. The action, which was consolidated with a similar action brought by Voices for Rural Living and others, does not seek relief directly against Lakes. However, the interchange is necessary to permit the construction of a casino to be developed and managed by Lakes through a joint venture.
      The casino will be owned by the Shingle Springs Tribe. The matter was tried to the court on August 22, 2003. On January 2, 2004, Judge Lloyd G. Connelly, Judge of the Superior Court for the State of California, issued his ruling on the matter denying the petition in all respects except one. As to the one exception, the court sought clarification as to whether the transportation conformity determination used to determine the significance of the air quality impact of the interchange operations considered the impact on attainment of the state ambient air quality standard for ozone. The California Department of Transportation (CalTrans) prepared and filed the clarification addendum sought by the court. Prior to the court’s determination of the adequacy of the clarification, El Dorado County and Voices for Rural Living appealed Judge Connelly’s ruling to the California Court of Appeals on all of the remaining issues.
      A ruling with respect to the addendum was issued June 21, 2004 by the Superior Court of California, County of Sacramento. The ruling indicated that the addendum provided to the court by CalTrans did not provide a quantitative showing to satisfy the court’s earlier request for a clarification on meeting the state ambient ozone standard. The court recognized that the information provided by CalTrans does qualitatively show that the project may comply with the state standard, but concluded that a quantitative analysis is necessary even though the court recognized that the methodology for that analysis “is not readily apparent”.

15


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
In addition, the ruling specifically stated, “Moreover such methodology appears necessary for the California Environmental Quality Act analysis of transportation projects throughout the state, including transportation projects for which respondents (i.e. CalTrans) have approval authority.” CalTrans, the Shingle Springs Tribe and Lakes responded to the court with a revised submission in August 2004. Representatives of the California Air Resources Board and the Sacramento Area Council of Governments filed declarations supporting the revised submission to the court. Opposition to that revised submission was filed, a hearing on the revised submission took place on August 20, 2004, and the court again found the revised submission of CalTrans, the Shingle Springs Tribe and Lakes to be inadequate. That ruling was separately appealed to the California Court of Appeals (the “Court”) and an oral argument for these appeals and the appeals of El Dorado County and Voices of Rural Living was held before the Court on August 29, 2005. The Court issued its decision on these appeals on November 8, 2005. The Court ruled in favor of CalTrans’ appeal, rejecting the El Dorado County’s argument that the transportation conformity analysis did not conform to state standards. The Court also rejected all but two of the legal claims asserted in the appeal by El Dorado County and Voices for Rural Living against the environmental impact report (“EIR”) prepared by CalTrans for the interchange that will connect Highway 50 to the Shingle Springs Rancheria. For the remaining two issues, the Court held that CalTrans must supplement its environmental analysis by adding some discussion to the air quality chapter to further explain the project’s contribution to overall vehicular emissions in the region, and that CalTrans also must evaluate whether a smaller casino and hotel would reduce environmental impacts. The Court acknowledged CalTrans lacks jurisdiction to require the Tribe to develop a smaller casino, but nevertheless required some discussion of this alternative in the interchange EIR.
      The Company has not recorded any liability for this matter as management believes the Courts’ rulings will ultimately allow the project to commence. However there can be no assurance that the final outcome of this matter is not likely to have a material adverse effect upon the Company’s unaudited condensed consolidated financial statements.
Grand Casinos, Inc. Litigation
      In connection with the establishment of Lakes as a public corporation on December 31, 1998, via a distribution of its common stock to the shareholders of Grand Casinos, the Company and Grand Casinos entered into an agreement governing the sharing or allocation of tax benefits accruing to Grand Casinos and certain affiliated companies of Grand Casinos. Lakes asserted claims against Grand Casinos for amounts to which Lakes believed it was entitled under the tax sharing agreement. On December 1, 2004, Lakes entered into a settlement agreement with Grand Casinos and its parent company, Park Place Entertainment Corporation (now known as Caesars Entertainment, Inc.), pursuant to which Lakes received $11.3 million in December 2004 in satisfaction of its prior claim and its future rights to the tax benefits that were the subject of the dispute. Lakes will be required to provide reimbursement for its share of the disallowed benefits, if any.. This settlement income has been recorded as other income in the consolidated statement of loss for the year ended January 2, 2005. Lakes has not recorded any tax related to the settlement payment of $11.3 million, as Lakes believes this settlement is not taxable to Lakes.
Louisiana Department of Revenue Litigation Tax Matter
      The Louisiana Department of Revenue maintains a position that Lakes owes additional Louisiana corporation income tax for the period ended January 3, 1999 and the tax years ended December 31, 1999 through December 31, 2001 and additional Louisiana corporation franchise tax for the tax years ended December 31, 2000 through December 31, 2002. This determination is the result of an audit of Louisiana tax returns filed by Lakes for the tax periods at issue and relates to the reporting of income earned by Lakes in connection with the managing of two Louisiana-based casinos. On December 20, 2004, the Secretary of the Department of Revenue of the State of Louisiana filed a petition to collect taxes against Lakes in the 19th Judicial District Court, East Baton Rouge Parish, Louisiana, Docket No. 527596, Section 23. In the

16


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
petition to collect taxes the Department of Revenue of the State of Louisiana asserts that additional corporation income tax and corporation franchise tax in the amount of $8.6 million, excluding interest, are due by Lakes for the taxable periods set forth above. Lakes maintains that it has remitted the proper Louisiana corporation income tax and Louisiana corporation franchise tax for the taxable periods at issue. On February 14, 2005, Lakes filed an answer to the petition to collect taxes asserting all proper defenses and maintaining that no additional taxes are owed and that the petition to collect taxes should be dismissed. Management intends to vigorously contest this action by the Louisiana Department of Revenue. However, Lakes may be required to pay up to the $8.6 million assessment plus interest if Lakes is not successful in this matter. The Company has recorded a reserve related to this examination which is reflected as part of income taxes payable on the Company’s consolidated balance sheets.
WPTE Lawsuit With the Travel Channel
      On September 19, 2005, WPTE filed suit in the California Superior Court seeking to keep the Travel Channel, LLC from interfering with WPTE’s prospective contractual relationship with third party networks in connection with the sale of the broadcast rights to the Professional Poker Tour (“PPT”), and to clarify and enforce WPTE’s rights with respect to the World Poker television episodes. Under WPTE’s existing agreement with TRV for the World Poker Tour program (the “WPT Agreements”), TRV is afforded the right to negotiate exclusively with WPTE with respect to certain types of programming developed by WPTE during a 60 day period. Pursuant to the WPT Agreements, WPTE submitted the PPT to TRV and began negotiations but failed to reach an agreement with TRV within the allotted negotiation window. Consequently, WPTE began discussions with other networks. While WPTE later revived its attempts to reach a deal with TRV after TRV’s exclusive bargaining window had ended, WPTE ultimately received an offer from ESPN. WPTE submitted this offer to TRV pursuant to TRV’s contractual last right to match the deal as specified under the WPT Agreements. Thereafter, TRV sent letters to WPTE and ESPN asserting, among other things, that WPTE was not entitled to complete a deal for the PPT with a third party. Following TRV’s letters, WPTE filed suit on September 19, 2005, alleging that TRV breached the WPT Agreements and interfered with WPTE’s prospective contractual relationship with ESPN, and seeking a judicial declaration of WPTE’s rights under the WPT Agreements to produce non-World Poker Tour branded programs covering poker tournaments. Subsequent to WPTE filing, ESPN withdrew its offer to WPTE to acquire the broadcast rights to the PPT. On September 22, 2005, TRV and Discovery Communications, Inc. filed an answer and cross-complaint and subsequently filed a motion for judgment on the pleadings and an “anti-SLAPP” motion, both of which were denied on November 10, 2005. Despite WPTE’s dispute with TRV, WPTE remains committed to fulfilling its obligations to TRV in connection with the World Poker Tour series.
Other Litigation
      Lakes is involved in various other inquiries, administrative proceedings, and litigation relating to contracts and other matters arising in the normal course of business. While any proceeding or litigation has an element of uncertainty, management currently believes that the final outcome of these matters is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
9. SEGMENT INFORMATION
      Lakes’ principal business is the development and management of gaming related properties. Additionally, the Company is the majority owner of WPTE, owning approximately 62% of WPTE’s outstanding common stock. Substantially, all operations of the Company and WPTE are conducted in the United States. Episodes of the World Poker Tour television series produced by WPTE are distributed internationally by a third party distributor. The segments reported below (in millions) are the segments of the Company for which separate financial information is available and for which operating results are evaluated by the chief operating decision-maker in deciding how to allocate resources and in assessing performance. The amounts in the Corporate and

17


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
Eliminations column below have not been allocated to the other segments because these costs are not easily allocable and to do so would not be practical.
                                 
    Industry Segments
     
    Indian Casino   WPT   Corporate &   Total
    Projects   Enterprises, Inc.   Eliminations   Consolidated
                 
Total assets as of October 2, 2005
  $ 145.1     $ 36.2     $ 31.5     $ 212.8  
Total assets as of January 2, 2005
    127.2       37.1       44.8       209.1  
For the Three Months Ended October 2, 2005
                               
Revenue
  $     $ 2.1     $     $ 2.1  
Net earnings (loss)
    (2.3 )     (1.6 )     (3.1 )     (7.0 )
Depreciation expense
          0.1             0.1  
For the Nine Months Ended October 2, 2005
                               
Revenue
  $     $ 12.8     $     $ 12.8  
Net earnings (loss)
    (1.5 )     (3.6 )     (9.7 )     (14.8 )
Depreciation expense
          0.1       0.2       0.3  
For the Three Months Ended October 3, 2004, restated
                               
Revenue
  $     $ 3.0     $     $ 3.0  
Net earnings (loss)
    0.2       (0.5 )     (0.9 )     (1.2 )
Depreciation expense
          0.1       0.1       0.2  
For the Nine Months Ended October 3, 2004, restated
                               
Revenue
  $     $ 11.8     $     $ 11.8  
Net earnings (loss)
    (4.7 )     1.2       (4.7 )     (8.2 )
Depreciation expense
          0.1       0.4       0.5  
10. IMPAIRMENT CHARGES
Nipmuc Nation project
      During the second quarter of 2004, the BIA issued its final determination denying the application of the Nipmuc Nation of Massachusetts (“Nipmuc Nation”) for federal recognition. Although the Nipmuc Nation is appealing the determination with the BIA, Lakes made a decision to discontinue funding the project. Lakes recorded an unrealized loss on notes receivable of $0.8 million related to the fair value of the note receivable from the Nipmuc Nation. Lakes also recorded an impairment charge of $5.8 million related to other long-term assets related to the Nipmuc Nation Indian casino project.
Kickapoo Project
      Lakes entered into consulting agreements and management contracts with the Kickapoo Tribe effective January 2005 to improve the performance of the gaming operations conducted at the Kickapoo Tribe’s existing Lucky Eagle Casino in Eagle Pass, Texas, located approximately 140 miles southwest of San Antonio. During the third quarter of fiscal 2005 the Company’s relationship with the Kickapoo Tribe deteriorated and in November 2005, Lakes and the Kickapoo Tribe terminated their business relationship. Lakes recognized an impairment charge of $0.1 million related to the intangible asset related to the acquisition of the management contract during the three months ended October 2, 2005. In addition during the three months ended

18


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
October 2, 2005, the Company recorded an unrealized loss on notes receivable of $4.1 million related to the Kickapoo project. Included in the $4.1 million are unrealized losses of approximately $3.8 million related to project costs incurred that Lakes may be required to pay as a result of the terminated relationship, and approximately $0.3 million related to advances made by Lakes on the note receivable from the Kickapoo Tribe. During the nine months ended October 2, 2005, the Company recognized unrealized losses on notes receivable of approximately $5.9 million. Included in the $5.9 million are unrealized losses of approximately $5.0 million related to project costs incurred that Lakes may be required to pay as a result of the terminated relationship, and approximately $0.9 million related to advances made by Lakes on the note receivable from the Kickapoo Tribe. As of October 2, 2005, Lakes owns approximately 18 acres of land near the Kickapoo site with a cost basis of approximately $0.7 million.
      The Company is negotiating with the Kickapoo Tribe to resolve all of the financial terms of the contracts including repayment of the advances, payment of unpaid project costs incurred, a possible sale of the land owned by Lakes to the Kickapoo Tribe, and to formally terminate the gaming operations consulting agreement, management contract, and related ancillary agreements relating to the project.
11. SUBSEQUENT EVENTS
Financing Facility
      On December 16, 2005, Lakes closed on a $20 million financing facility with the Lyle Berman Family Partnership (the “Partnership”). An initial draw of $10 million was made under the facility on December 16, 2005, and the remaining $10 million can be drawn in $5 million increments over time as needed. Any funds drawn under the facility bear interest at the rate of 12% per annum and are due and payable on the third anniversary of the first advance drawn. No commitment fees, closing fees or loan servicing fees were assessed or paid in connection with the facility. Lakes may prepay the facility in whole or in part without penalty. Lyle Berman, Lakes’ Chairman and Chief Executive Officer, does not have an ownership or other beneficial interest in the Partnership. Neil Sell, a Director of Lakes, is one of the trustees of the irrevocable trusts that are the partners in the Partnership.
      The financing facility is secured by substantially all of the personal property of Lakes and its subsidiaries other than WPTE, including all fees or rights to cash flow from Lakes’ casino projects, as well as by its real property located at 130 Cheshire Lane, Minnetonka, Minnesota (which is the location of the Company’s principal offices), its real estate mortgage from the Pokagon Band and its shares of WPTE. The financing facility is also guaranteed by certain of the Company’s subsidiaries other than WPTE. The facility permits Lakes to separately sell up to 3.5 million WPTE shares without application of the proceeds from such sale to pay down draws under the financing facility so long as the per share price of WPTE shares does not fall below $3.00 per share, in which case the pro rata portion of the proceeds shall be applied to the financing facility based upon the difference between the share price and the minimum share price of $3.00. The sale of WPTE shares above 3.5 million shares will trigger mandatory prepayment of the financing facility.
      In consideration for the financing facility, Lakes issued to the Partnership warrants for the purchase of up to 2 million shares of its common stock at a purchase price of $7.88 per share that expire in December 2012. The warrants contain customary demand and piggyback registration rights for the shares of common stock underlying the warrants. The warrants will not become exercisable if Lakes’ borrowings under the facility do not exceed $10 million in the aggregate and all amounts owed under the facility are repaid in full on or before February 28, 2006. In addition, Lakes agreed to use its best efforts to cause WPTE to file a registration statement by no later than April 15, 2006 thus allowing for the possible resale of all WPTE shares pledged by Lakes to the Partnership. If Lakes were to sell more than the 3.5 million shares of WPTE, such proceeds would first be used to pay down the financing facility. Lakes has agreed to pay substantially all of the costs incurred in the preparation and filing of such registration statement.

19


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
WPTE Investment in PokerTek
      At October 2, 2005, WPTE had a nominal investment, consisting of a 15% ownership interest in (carried at cost), and a loan receivable from PokerTek, a company that offers an electronic poker table called the PokerPro system that provides a fully automated poker room environment to tribal and commercial casinos and card clubs. On October 14, 2005, PokerTek announced a public offering of 2,000,000 shares of common stock at a price of $11 per share. Concurrently with the public offering, WPTE’s ownership interest was diluted to 11.7% (1,080,000 shares), and PokerTek repaid WPTE the outstanding loan amount at its maturity value of $185,000. WPTE’s shares in PokerTek are restricted, thus prohibiting any sale of such shares in the market for six months. Nevertheless, in accordance with Statement of Financial Accounting Standards (SFAS) No. 115, Accounting for Certain Investments in Debt and Equity Securities, WPTE will adjust its investment to fair market value and classify it as “available for sale” in the fourth quarter of 2005, since WPTE does not expect to have any cash needs or plans to sell these shares in the foreseeable future. Accordingly, WPTE will record net unrealized gains and losses from this investment in a separate component of shareholder’s equity (i.e. within the “accumulated other comprehensive earnings” line item in the stockholders’ equity section of the balance sheet) beginning in the fourth quarter of 2005.

20


Table of Contents

ITEM 2. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS
      The following Management’s Discussion and Analysis of Financial Condition and Results of Operations reflect the adjustments relating to the restatement described in Note 3 in the unaudited condensed consolidated financial statements.
Overview
      Lakes develops Indian-owned casino properties and intends to manage such casinos when applicable regulatory approvals have been received and we have satisfied other contingencies. Lakes currently has development and management agreements with five separate tribes for one new casino operation in Michigan, two in California, and with two tribes in Oklahoma for five various casino projects. Lakes is also involved in other businesses, including development of a non-Indian casino and the development of new table games for licensing to casinos. In addition, as of October 2, 2005, Lakes owned approximately 62% of WPTE, a separate publicly held media and entertainment company principally engaged in the development, production and marketing of gaming themed televised programming, the licensing and sale of branded products and the sale of corporate sponsorships. Lakes’ consolidated financial statements include the results of operations of WPTE, and in recent periods, all of Lakes’ revenues have been derived from WPTE’s business.
Financial Overview
      In the three and nine months ended of the fiscal year ended January 1, 2006 (“fiscal 2005”) and the three and nine months ended of the fiscal year ended January 2, 2005 (“fiscal 2004”), all of Lakes’ consolidated revenues have been derived from the WPTE business, mainly from license fees for domestic telecast of World Poker Tour television episodes (“WPT”) and product licensing fees associated with the World Poker Tour brand and logo. There were minimal product licensing revenues in fiscal 2004. License fees have depended on the number of episodes delivered to The Travel Channel (“TRV”) in a particular period. Revenues from other parts of the WPTE business are relatively small but continue to grow.
Results of Operations
Nine Months Ended October 2, 2005 Compared to the Nine Months Ended October 3, 2004
Revenues
      All revenues in fiscal 2005 and 2004 were related to WPTE business. Total revenues increased by $1.0 million for the nine months ended October 2, 2005, compared to the same period in the prior year. Domestic television license revenues decreased by $3.6 million in the first nine months of fiscal 2005 compared to the first nine months of fiscal 2004. The reduction in domestic television license revenue reported in the first nine months of fiscal 2005 reflected the delivery of only thirteen episodes of Season Three and one episode of Season Four compared to 24 Season Two episodes that were delivered during the fiscal 2004 period. International television licensing revenues increased by $0.9 million for the nine months ended October 2, 2005, compared to the nine months ended October 3, 2004, as we increased distribution to more territories in the current period. Revenues for the nine months ended October 2, 2005, also included $2.9 million more in product licensing revenues than the nine months ended October 3, 2004 as WPTE licensees had substantially more product in the marketplace in fiscal 2005.
      TRV exercised its option for Seasons Three and Four in May 2004 and March 2005, respectively, and has additional options for the following three seasons (Seasons Five through Seven) under which WPTE would receive fixed license fees for each episode WPTE produces. For each season covered by an option exercised by TRV, TRV will have exclusive rights to exhibit the programs in that season an unlimited number of times on its television network (or any other television network owned by the Discovery Channel) in the U.S. for four years.

21


Table of Contents

Costs and expenses
      Production costs are associated with WPTE costs of producing television series. WPTE cost of revenues increased by $1.1 million in the first nine months of fiscal 2005 as compared to the first nine months of fiscal 2004, and accordingly, overall gross margins were 36.7% in the first nine months of fiscal 2005 compared to 40.3% in the first nine months of fiscal 2004. Cost of revenues for the first nine months of fiscal 2005 included approximately $3.2 million related to the premiere season of the PPT, as well as $3.9 million and $0.2 million in production costs for Season Three and Season Four episodes, respectively, of the WPT. PPT production costs were expensed in this period rather than being capitalized because WPTE does not capitalize television production costs until a licensing agreement has been executed or WPTE has a firm commitment of revenue for the series. For the first nine months of fiscal 2004, cost of revenues of $7.1 million were related primarily to the production of Season Two episodes of the WPT. There were no PPT production costs incurred during the first nine months of fiscal 2004. Additionally, cost of revenues in the first nine months of fiscal 2005 included approximately $0.8 million of non-cash compensation expense related to consultant stock options compared to $0.5 million in the first nine months of fiscal 2004. Excluding the non-cash compensation expenses and PPT production costs expensed during the first nine months of fiscal 2005, gross margin for the first nine months of fiscal 2005 would have been 67.9% compared to 44.6% for the corresponding period in 2004, with the higher margin in fiscal 2005 due to increased revenues from product licensing, international licensing and sponsorship.
      Selling, general and administrative expenses increased by $10.3 million to $20.4 million for the nine months ended October 2, 2005 from $10.1 million for the nine months ended October 3, 2004. WPTE selling, general and administrative costs increased by $5.4 million for the nine months ended October 2, 2005, compared to the nine months ended October 3, 2004. This increase is primarily due to additional headcount costs, product licensing commissions, marketing expenses associated with online gaming and legal and audit fees incurred during the 2005 period associated with business development, increased product licensing revenues, online gaming launch, growth and regulatory compliance costs related to being an independent public company following WPTE’s initial public offering in the third quarter of fiscal 2004. Lakes’ selling, general and administrative costs were $11.5 million for the nine months ended October 2, 2005 and $6.6 million for the nine months ended October 3, 2004. This increase of $4.9 million is due to $1.0 million in additional rent expense primarily related to a deficiency in the guaranteed residual value of the aircraft the Company leases, $2.0 million related to increased head count and related costs due to the casino projects in Texas and Oklahoma, $1.4 million in professional service fees related to the casino projects in Texas and Oklahoma as well as regulatory compliance costs and $0.5 million in development costs associated with an “Automated System For Playing Live Casino Table Games.”
      Impairment losses were $0.1 million and $5.8 million during the nine months ended October 2, 2005 and October 3, 2004, respectively. The Company recognized a $0.1 million impairment charge related to the intangible asset related to the acquisition of the management contract during the three months ended October 2, 2005 related to the Kickapoo casino project. During the third quarter of fiscal 2005 the Company’s relationship with the Kickapoo Tribe deteriorated and in November 2005, Lakes and the Kickapoo Tribe terminated their business relationship. During the nine months ended October 3, 2004, the Company recognized a $5.8 million impairment charge related to long-term assets related to the Nipmuc Nation project. Lakes also recorded an unrealized loss on notes receivable of $0.8 million related to the fair value of the note receivable from the Nipmuc Nation. In June 2004, the BIA issued its final determination denying the Nipmuc Nation’s application for federal recognition. Although the Nipmuc Nation is appealing the determination with the BIA, Lakes made a decision to discontinue funding the project in the second quarter of 2004. At that time, Lakes recorded the impairment charge and an unrealized loss on notes receivable. Should the Nipmuc Nation become federally recognized and successfully open a casino operation (with or without Lakes’ assistance) Lakes is entitled to receive payment in full of its advances and deferred interest.
Net unrealized gain on notes receivable
      Net unrealized gains (losses) on notes receivable were ($0.2) million and $1.3 million for the nine months ended October 2, 2005 and October 3, 2004, respectively, related to the adjustment to fair value of the

22


Table of Contents

Company’s notes receivable from Indian Tribes. These fair value calculations are determined based on current assumptions related to the projects as discussed below under “Accounting for long-term assets related to Indian casino projects”. Included in net unrealized losses on notes receivable of ($0.2) million for the nine months ended October 2, 2005 are unrealized losses of $5.9 million related to the Kickapoo project as a result of the termination of the business relationship between the Kickapoo Tribe and Lakes. The unrealized loss is partially offset by unrealized gains primarily related to an increase in probability associated with the Pokagon Casino project.
Other
      Other income increased $1.1 million. Interest income was $1.3 million for the nine months ended October 2, 2005 compared to $0.2 million for the same period in the prior year. This increase is primarily due to an increase in cash and equivalents and short-term investments related to WPTE raising proceeds and becoming a public entity in August 2004 and cash settlements and cash proceeds from real estate sales received by Lakes in fiscal 2004.
Taxes
      The Company recorded a tax provision of $1.1 million for the nine-month period ended October 2, 2005 compared to a tax benefit of $1.7 million for the nine-month period ended October 3, 2004. The loss before income taxes, equity in earnings (loss) of investments and minority interest was $15.1 million for the nine months ended October 2, 2005 compared to a loss of $10.1 million for the nine months ended October 3, 2004. In accordance with Statement of Financial Accounting Standards No. 109, Accounting for Income Taxes (SFAS No. 109), Lakes evaluated the ability to utilize deferred tax assets relating to net operating loss carry forwards, deferred interest on advances made to Indian tribes and other ordinary items and determined that a valuation allowance was appropriate. Lakes evaluated all evidence and determined the net losses generated over the past three years outweighed the current positive evidence that the Company believes exists surrounding its ability to generate significant income from its long-term assets related to Indian casino projects and its investments in its non-Indian casino business. The Company recorded a 100% valuation allowance against these items at October 2, 2005 and January 2, 2005. In addition, the Company recognized a deferred tax asset for capital losses related to asset impairment charges. The realization of these benefits is dependent on the generation of capital gains. The Company believes it will have sufficient capital gains in the future to utilize these benefits.
Losses per common share and net losses
      For the nine months ended October 2, 2005, basic and diluted losses per common share were $0.66, compared to basic and diluted losses of $0.37 per common share, for the same period in the prior year. Net loss for the nine months ended October 2, 2005 was $14.8 million compared to $8.2 million for the nine months ended October 3, 2004. This increase is primarily due to the loss from operations increasing $6.0 million primarily due to WPTE’s production costs associated with the introduction of PPT production costs in 2005, with no associated revenues, and an increase in selling and administrative expenses, principally as a result of WPTE’s marketing and operating costs of launching WPTE’s online gaming initiative, and overall growth of compliance expenses resulting from being an independent public company. Lakes’ selling general and administrative expenses increased $4.9 million but were offset by an impairment loss of $5.8 million recognized in the prior year.
Three Months Ended October 2, 2005 Compared to the Three Months Ended October 3, 2004
Revenues
      All revenues in fiscal 2005 and fiscal 2004 were related to WPTE business. Total revenues decreased by $0.8 million for the three months ended October 2, 2005 as compared the same period in the prior year. Domestic television license revenues decreased by $1.9 million in the three months ended October 2, 2005 compared to the three months ended October 3, 2004. The reduction in domestic television license revenue

23


Table of Contents

reported in the third quarter of fiscal 2005 reflected the delivery of one Season Four episode compared to six Season Two episodes delivered during the third quarter of fiscal 2004. International television licensing revenues increased by $0.1 million for the three months ended October 2, 2005 compared to the three months ended October 3, 2004 as WPTE increased distribution to more territories in the current period. Revenues for the three months ended October 2, 2005 also included $0.8 million more in product licensing revenues than the three months ended October 3, 2004 as WPTE licensees had substantially more product in the marketplace in fiscal 2005.
Costs and Expenses
      Production costs are associated with WPTE costs of producing television series. WPTE cost of revenues decreased by $1.4 million in the third quarter of 2005 as compared to the third quarter of fiscal 2004, and accordingly, overall gross margins were 73.7% in the third quarter of fiscal 2005 compared to 34.7% in the third quarter of fiscal 2004. Cost of revenues for the third quarter of fiscal 2005 included approximately $0.2 million related to the premiere season of the PPT, as well as $0.2 million in production costs relating to the delivery of WPT episodes. PPT production costs were expensed in this period rather than being capitalized because WPTE does not capitalize television production costs until a licensing agreement has been executed or WPTE has a firm commitment of revenue for the series. For the third quarter of fiscal 2004, cost of revenues of $1.9 million was related primarily to the production of Season Two episodes of the WPT. There were no PPT production costs incurred during the third quarter of fiscal 2004.
      Selling and administrative expenses increased by $3.2 million for the three months ended October 2, 2005, compared to the three months ended October 3, 2004. WPTE’s selling general and administrative expenses increased by $1.8 million for the three months ended October 2, 2005, compared to the three months ended October 3, 2004. This increase is primarily due to additional headcount costs, product licensing commissions, marketing expenses associated with online gaming and legal and audit fees incurred during the 2005 period associated with business development, increased product licensing revenues, online gaming launch, growth and regulatory compliance costs related to being an independent public company following our initial public offering in the third quarter of 2004. Lakes’ selling general and administrative expenses increased by $1.4 million for the three months ended October 2, 2005, compared to the three months ended October 3, 2004 primarily due to $0.8 million related to increased head count and related costs due to the casino projects in Texas and Oklahoma, $0.1 million in professional service fees related to the casino projects in Texas and Oklahoma as well as regulatory compliance costs, $0.3 million in increased maintenance costs associated with the Company’s airplane it leases as well as its information technology system, and $0.2 million in development costs associated with an “Automated System For Playing Live Casino Table Games”.
Net unrealized gain (loss) on notes receivable
      Net unrealized gain (loss) on notes receivable was ($2.1) million and $0.8 million for the three months ended October 2, 2005 and October 3, 2004, respectively, related to the adjustment to fair value of the Company’s notes receivable from Indian Tribes. These fair value calculations are determined based on current assumptions related to the projects as discussed below under “Accounting for long-term assets related to Indian casino projects”. The unrealized loss for the three months ended October 2, 2005 is primarily due to an unrealized loss of $4.1 million related to amounts advanced or costs incurred on behalf of the Kickapoo Tribe during the three months ended October 2, 2005 as a result of the termination of the business relationship between the Kickapoo Tribe and Lakes. The unrealized loss is partially offset by unrealized gains of $2.0 million on the Company’s other Indian casino projects.
Taxes
      The Company recorded a tax provision of $0.4 million during the three months ended October 2, 2005 compared to a tax benefit of $0.8 million during the three months ended October 3, 2004. The loss before income taxes, equity in earnings (loss) of investments and minority interest was $7.3 million for the three months ended October 2, 2005 compared to a loss of $1.9 million for the three months ended October 3, 2004. In accordance with Statement of Financial Accounting Standards No. 109, Accounting for Income Taxes

24


Table of Contents

(SFAS No. 109), Lakes evaluated the ability to utilize deferred tax assets relating to net operating loss carry forwards, deferred interest on advances made to Indian tribes and other ordinary items and determined that a valuation allowance was appropriate. Lakes evaluated all evidence and determined the net losses generated over the past three years outweighed the current positive evidence that the Company believes exists surrounding its ability to generate significant income from its long-term assets related to Indian casino projects and its investments in its non-Indian casino business. The Company recorded a 100% valuation allowance against these items at October 2, 2005 and January 2, 2005. In addition, the Company recognized a deferred tax asset for capital losses related to asset impairment charges. The realization of these benefits is dependent on the generation of capital gains. The Company believes it will have sufficient capital gains in the future to utilize these benefits.
Losses Per Common Share and Net Losses
      For the three months ended October 2, 2005, basic and diluted losses per common share were $0.32, compared to basic and diluted losses of $0.05 per common share, for the same period in the prior year. Net loss for the three months ended October 2, 2005 was $7.0 million compared to $1.2 million for the three months ended October 3, 2004. The increase in net loss is primarily due an increase in loss from operations of $5.7 million primarily due to increased selling general and administrative expenses related to both WPTE and Lakes as well as an increase in the net unrealized loss on notes receivable of $2.9 million related to the adjustment to fair value of the Company’s notes receivable from Indian Tribes.
Liquidity and Capital Resources
      At October 2, 2005, Lakes’ unaudited condensed consolidated balance sheet included unrestricted cash and cash equivalents and short-term investment balances of $44.2 million. Included in this amount was Lakes’ cash of $13.7 million. Also included were WPTE cash of $3.0 million and WPTE short-term investments of $27.5 million. WPTE cash and investments will not be used in Lakes’ business. As of October 2, 2005, Lakes’ has had no operating revenues from casino operations since the expiration of the management contract with the Coushatta Tribe in January 2002.
      In August and September 2004, WPTE raised a total of approximately $32.4 million in cash proceeds from its initial public offering, net of underwriting discounts and estimated offering expenses. WPTE’s cash resources are expected to be used for WPTE’s business and will not be available for Lakes’ casino projects or other non-WPTE businesses. The initial public offering resulted in the termination of Lakes’ obligation to fund WPTE operations under a limited revolving note receivable. As of October 2, 2005, Lakes holds approximately 12.5 million shares or approximately 62% of WPTE’s common stock. Lakes’ will be subject to Rule 144 regarding volume limitations for sales of WPTE common stock.
      The Company’s primary source of cash for its development of casino projects during fiscal 2004 and during the nine months ended October 2, 2005 has been from the planned sale of assets. During fiscal 2004, the 2022 Ranch land, which was owned by Lakes and its joint venture partner Land Baron West, LLC, was sold. Lakes received cash in the amount of approximately $2.5 million related to the sale of the land as well as through the settlement of a title dispute. Lakes received proceeds of $5.9 million in fiscal 2004 in connection with the sale of the Polo Plaza and adjacent Travelodge property and an additional $5.0 million received during 2005, pursuant to an option agreement with Metroflag. We expect that proceeds from the sale of assets will decrease in future periods. Additionally in December 2004, Lakes received $11.3 million in settlement of a tax sharing agreement with Grand Casinos. For a discussion of Lakes’ current efforts to secure financing for its operational and development needs see Note 11.
      Our management contracts with our tribal partners require that we provide financial support for project development in the form of loans. These loans are interest bearing; however, the loans and related interest are not due until the casino is built and has established profitable operations. In the event that the casinos are not built, our only recourse is to attempt to liquidate assets of the development, if any, excluding any land in trust. A portion of the advances due from the Pokagon Band in the approximate amount of $24.1 million resulted

25


Table of Contents

from funds advanced by the Company for the Pokagon Band’s purchase of the land. The Company has a first deed of trust against this property, which will be relinquished when the BIA places the land into trust.
      We currently believe that our existing casino development projects included in the table below (except for the project with the Kickapoo Tribe — see Note 10) will be constructed and achieve profitable operations; however, no assurance can be made that this will occur. If this does not occur, it is likely that Lakes would incur substantial or complete losses on its notes receivable from Indian tribes and related intangible assets associated with the acquisition of the management contracts. In addition, if Lakes’ current casino development projects are not completed or, upon completion, fail to successfully compete in the highly competitive market for gaming activities, Lakes may lack the funds to compete for and develop future gaming or other business opportunities and Lakes’ business could be adversely affected to the extent that it may be forced to cease its operations entirely.
      Following is a table summarizing remaining contractual obligations as of October 2, 2005 (in millions):
                                           
    Payment Due by Period
     
        Less Than       More Than
Contractual Obligations   Total   1 Year   1-3 Years   3-5 Years   5 Years
                     
Remaining casino development commitment(1)(3)
                                       
 
Jamul
  $ 7.5     $ 1.6     $ 5.9     $     $  
 
Shingle Springs
    4.8       1.7       3.1              
 
Pokagon(2)
    27.2       1.4       15.0       10.8        
 
Kickapoo Traditional Tribe of Texas(8)
    0.4       0.4                          
 
Iowa Tribe of Oklahoma
    0.8       0.8                          
Operating leases(4)
    1.7       0.1       1.3       0.3        
WPTE operating leases(5)
    2.9       0.5       1.0       1.0       0.4  
WPTE purchase obligations(6)
    1.1       0.5       0.6              
WPTE employee obligations(7)
    0.8       0.7       0.1              
                               
    $ 47.2     $ 7.7     $ 27.0     $ 12.1     $ 0.4  
                               
 
(1)  Lakes anticipates that it will require additional capital through public or private financings or the sale of some or all of Lakes’ shares of WPTE to meet the remaining casino development commitments. See table below detailing tribal casino development commitments.
 
(2)  For the Pokagon Casino project, the Company has agreed to provide additional financing from its own funds if financing at an interest rate not to exceed 13% is not available from third parties. If this occurs and Lakes is required to provide all financing, this would be an additional commitment of up to approximately $54 million. Currently, it appears that third party financing will be available for this project. However, there can be no assurance that third party financing will be available and that Lakes will not be required to provide this additional financing. The Company will be obligated to pay an amount to an unrelated third party once the Pokagon Casino is open and Lakes is the manager of the casino. The amount is payable quarterly for five years and is only payable if Lakes is the manager of the casino. The payment is part of a settlement and release agreement associated with Lakes obtaining the management contract with the Pokagon Band. The maximum liability over the five-year period is approximately $11 million.
 
(3)  Lakes may be required to provide a guarantee of tribal debt financing or otherwise provide support for the tribal obligations related to any of the projects. Any guarantees by Lakes or similar off-balance sheet liabilities will increase Lakes’ potential exposure in the event of a default by any of these tribes. No such guarantees or similar off-balance sheet liabilities existed at October 2, 2005.
 
(4)  The Company leases an airplane, under a non-cancelable operating lease which was amended on May 1, 2005. The new term is for a period of up to three years.

26


Table of Contents

(5)  Operating lease obligations include rent payments on WPTE’s corporate office space. Monthly lease payments began at approximately $38,000 and escalate to approximately $45,000 over the six-year lease term. The amount set forth in the table above assumes monthly lease payments through May 2011.
 
(6)  Purchase obligations include contractual obligations of $1.1 million related to the establishment of WPTE’s internet gaming site.
 
(7)  Employee obligations include the base salaries payable to Steven Lipscomb, Audrey Kania and Robyn Moder under their respective employment agreements.
 
(8)  Lakes entered into consulting agreements and management contracts with the Kickapoo Tribe effective January 2005 to improve the performance of the gaming operations conducted at the Kickapoo Tribe’s existing Lucky Eagle Casino in Eagle Pass, Texas, located approximately 140 miles southwest of San Antonio. During the third quarter of fiscal 2005 the Company’s relationship with the Kickapoo Tribe deteriorated and in November 2005, Lakes and the Kickapoo Tribe terminated their business relationship.
Casino Development Advances/ Commitments
As of October 2, 2005
                                                         
                            Commitments
                            in Excess of
                        Lakes’ Cash   Available
        Land Held       Total   Remaining   and   Cash and
    Pre-Construction   for   Total   Funding   Funding   Short-Term   Short-Term
    Advances   Development   Funded   Commitment   Commitment   Investments   Investments
                             
    (In millions)
Jamul Tribe(a)
  $ 15.9     $ 6.6     $ 22.5     $ 30.0     $ 7.5                  
Shingle Springs Tribe(b)
    36.4       8.8       45.2       50.0       4.8                  
Pokagon Band(c)
    45.8             45.8       73.0       27.2                  
Kickapoo Tribe(d)
    0.9       0.7       1.6       2.0       0.4                  
Iowa Tribe(e)
    0.2       0.1       0.3       1.0       0.7                  
Pawnee Nation(f)
    2.1             2.1       1.1                        
                                           
    $ 101.3     $ 16.2     $ 117.5     $ 157.1     $ 40.6     $ 13.7     $ 26.9  
                                           
 
(a) Lakes plans to continue making advances on the remaining commitment to the Jamul Tribe on a monthly basis until the casino opens. Lakes plans to make advances of $0.6 million and $6.9 million during the fourth quarter of fiscal 2005 and during fiscal 2006, respectively, to fulfill its remaining commitment to the Jamul Tribe.
 
(b) Lakes plans to continue making advances on the remaining commitment to the Shingle Springs Tribe on a monthly basis until the casino opens. Lakes plans to make advances of $0.6 million and $4.2 million during the fourth quarter of fiscal 2005 and during fiscal 2006, respectively, to fulfill its remaining commitment to the Shingle Springs Tribe.
 
(c) Lakes plans to continue making advances on the remaining commitment to the Pokagon Band on a monthly basis until the casino opens. Lakes plans to make advances of $0.5 million, $15.9 million and $10.8 million during the fourth quarter of 2005, during fiscal 2006 and during fiscal 2007, respectively, to fulfill its remaining commitment to the Pokagon Band.
 
(d) Lakes entered into consulting agreements and management contracts with the Kickapoo Tribe effective January 2005 to improve the performance of the gaming operations conducted at the Kickapoo Tribe’s existing Lucky Eagle Casino in Eagle Pass, Texas, located approximately 140 miles southwest of San Antonio. In November 2005, Lakes and the Kickapoo Tribe terminated their business relationship. Lakes recognized an impairment charge of $0.1 million related to the intangible asset related to the acquisition of the management contract during the three months ended October 2, 2005. In addition during the three months ended October 2, 2005, the Company recorded an unrealized loss on notes receivable of $4.1 million related to the Kickapoo project. Included in the $4.1 million are unrealized

27


Table of Contents

losses of approximately $3.8 million related to project costs incurred that Lakes may be required to pay as a result of the terminated relationship, and approximately $0.3 million related to advances made by Lakes on the note receivable from the Kickapoo Tribe. During the nine months ended October 2, 2005, the Company recognized unrealized losses on notes receivable of approximately $5.9 million. Included in the $5.9 million are unrealized losses of approximately $5.0 million related to project costs incurred that Lakes may be required to pay as a result of the terminated relationship, and approximately $0.9 million related to advances made by Lakes on the note receivable from the Kickapoo Tribe. As of October 2, 2005, Lakes owns approximately 18 acres of land near the Kickapoo site with a cost basis of approximately $0.7 million. As a result of the terminated business relationship with the Kickapoo Tribe, Lakes intends to negotiate with the Kickapoo Tribe to reach an agreement to resolve all of the financial terms of the contracts including repayment of the advances, payment of unpaid project costs incurred, possible sale of the land owned by Lakes to the Kickapoo Tribe, and to formally terminate the gaming operations consulting agreement, management contract, and related ancillary agreements relating to the project.
 
(e) Lakes plans to advance the $1.0 million it has committed to the Iowa Tribe during 2005. In December 2005 the Iowa Tribe closed on third party financing related to the Cimarron Casino and repaid Lakes all amounts advanced related to that project. Additional amounts have and will be advanced to the Iowa Tribe for the new casino project based upon an approved budget yet to be finalized.
 
(f) During the third quarter of 2005, Lakes made a commitment of $1.1 million to the Pawnee Nation related to the Trading Post project based upon an approved budget. Additional amounts will continue to be advanced to the Pawnee Nation for the new casino project and Travel Plaza project based upon an approved budget yet to be finalized.
      During the three months ended October 2, 2005, the Company incurred development costs of approximately $5.0 million relating to the non-Indian casino it is developing in Vicksburg, Mississippi. The Company is working toward obtaining all necessary approvals to move forward with this project.
      During 2005, Lakes’ corporate costs, excluding WPTE, which is not expected to require additional capital from Lakes, will approximate $12.5 million. Development project-related costs are expected to approximate $24.0 million during 2005. Lakes’ unaudited cash balance, excluding WPTE cash was approximately $5.5 million as of December 9, 2005. Lakes’ on-going quarterly corporate costs are expected to approximate $3.5 million and on-going quarterly development project-related costs are expected to approximate $3.5 million, however a portion of these costs are discretionary and could be deferred if necessary. Additionally, the Company may be required to pay taxes, ranging from $0 to approximately $12 million plus interest and penalties, in 2006 related to two tax matters. It is anticipated that Lakes will require additional capital through public or private financings or the sale of some or all of the Company’s shares of WPTE to meet operating expenses and development project-related costs during the remainder of 2005 and 2006 and the Company is currently considering various financing alternatives. In December 2005, Lakes obtained a $20 million financing facility from the Lyle Berman Family Partnership and received a $10 million draw on this facility on December 16, 2005 (see Note 11). Lakes plans to continue pursuing other financing alternatives, and the Company believes the assets of Lakes provide sufficient collateral to obtain the necessary financing. The assets of Lakes include common shares of WPTE that have an estimated fair value of $82.6 million as of December 9, 2005, based on the public trading price, on that date, which may not be indicative of what Lakes could realize in a sale of its shares. The Company believes the shares of WPTE could be the source or part of the collateral for the additional financing.
      Our major use of cash over the past three years has been pre-construction financing provided to our tribal partners. Lakes also anticipates that it may incur additional pre-construction costs which would require the Company to obtain additional sources of financing. These development costs do not include construction-related costs that would be incurred if any of the projects were to begin construction during the next twelve months. Management anticipates that it will be necessary to raise additional capital when any of the projects begin construction and believes such financing will be available based on preliminary discussions with prospective lenders. However, such financings may not be available when needed on terms acceptable to Lakes or at all. Moreover, any additional equity financings may be dilutive to Lakes’ shareholders, and any

28


Table of Contents

debt financing may involve additional restrictive covenants. An inability to raise such funds when needed might require Lakes to delay, scale back or eliminate some of its expansion and development goals.
      In addition, the construction of the Company’s Indian casino projects may depend on the ability of the tribes to obtain financing for the projects. If such financing cannot be obtained on acceptable terms, it may not be possible to complete these projects, which could have a material adverse effect on Lakes’ results of operations and financial condition. In order to assist the tribes, Lakes may be required to guarantee the tribes’ debt financing or otherwise provide support for the tribes’ obligations. Any guarantees by Lakes, if any, will increase Lakes’ potential exposure in the event of a default by any of these tribes.
      For the Pokagon Casino project, the Company has agreed to finance all phases of the project entirely from its own funds if financing at an interest rate of 13% or less is not available from the capital markets. If this occurs and Lakes is required to provide all financing, this would be an additional commitment of up to approximately $54 million. Currently, management believes that third-party financing will be available for this project. However, there can be no assurance third-party financing will be available and that Lakes will not be required to provide this additional financing.
      As a part of the transaction establishing Lakes as a separate public company on December 31, 1998, the Company agreed to indemnify Grand Casinos through December 28, 2004 against all costs, expenses and liabilities incurred in connection with or arising out of certain pending and threatened claims and legal proceedings against Grand Casinos and to pay all related settlements and judgments. The indemnification period expired on December 28, 2004 and Lakes does not have any further obligations. Lakes incurred no costs related to this matter in 2004.
Critical Accounting Policies and Estimates
      Our consolidated unaudited financial statements and accompanying notes are prepared in accordance with U.S. GAAP. Preparing financial statements requires management to make estimates and assumptions that affect the reported amounts of assets, liabilities, revenue, and expenses. These estimates and assumptions are affected by management’s application of accounting policies. The significant accounting policies that Lakes believes are the most critical to aid in fully understanding and evaluating its reported financial results include the following: revenue recognition, long-term assets related to Indian casino projects and income taxes.
      Revenue recognition: Revenue from the management of Indian-owned casino gaming facilities is recognized in accordance with our policy described below under the caption “Accounting for long-term assets related to Indian casino projects.”
      Revenue from the domestic and international distribution of WPTE’s television series is recognized as earned under the following criteria established by the American Institute of Certified Public Accountants Statement of Position (SOP) No. 00-2, Accounting by Producers or Distributors of Films:
  •  Persuasive evidence of an arrangement exists;
 
  •  The show/episode is complete, and in accordance with the terms of the arrangement, has been delivered or is available for immediate and unconditional delivery;
 
  •  The license period has begun and the customer can begin its exploitation, exhibition or sale;
 
  •  The seller’s price to the buyer is fixed and determinable; and
 
  •  Collectibility is reasonably assured.
      In accordance with the terms of the TRV agreement, WPTE recognizes domestic television license revenues upon the receipt and acceptance of completed episodes. However, due to restrictions and practical limitations applicable to WPTE’s operating relationships with foreign networks, WPTE currently does not consider collectibility of international television license revenues to be reasonably assured, and accordingly, WPTE does not recognize such revenue until the distributor has received payment. Additionally, WPTE presents international distribution license fee revenues net of the distributor’s fees, as the distributor is the primary obligor in the transaction with the ultimate customer pursuant to the Financial Accounting Standards

29


Table of Contents

Board (FASB) Emerging Issues Task Force (EITF) 99-19, Reporting Revenue Gross as a Principal versus Net as an Agent.
      Product licensing revenues are recognized when the underlying royalties from the sales of the related products are earned. WPTE recognizes minimum revenue guarantees ratably over the term of the license or as earned royalties based on actual sales of the related products, if greater. WPTE presents product licensing fees gross of licensing commissions, which are recorded as selling and administrative expenses as WPTE is the primary obligor in the transaction with the ultimate customer pursuant to EITF 99-19.
      Online gaming revenues are recognized monthly based on detailed statements received from WagerWorks, WPTE’s online gaming partner, for online poker and casino activity throughout the previous month. In accordance with EITF 99-19, WPTE presents online gaming revenues gross of WagerWorks costs, including WagerWorks management fee, royalties, credit card processing and chargebacks that are recorded as cost of revenues, since WPTE has the ability to adjust price and specifications of the online gaming site, WPTE bears the majority of the credit risk and WPTE is responsible for the sales and marketing of the gaming site.
      Event hosting fees are paid by host casinos for the privilege of hosting the events and are recognized as the episodes that feature the host casino are aired, and sponsorship revenues are recognized as the episodes that feature the sponsor are aired. Licensing advances and guaranteed payments collected, but not yet earned, by WPTE, as well as casino host fees and sponsorship receipts collected prior to the airing of episodes, are classified as deferred revenue in the accompanying balance sheets.
      Deferred television costs: WPTE accounts for deferred television costs in accordance to SOP No. 00-2. Deferred television costs include capitalizable direct costs, production overhead and development costs and are stated at the lower of cost or net realizable value based on anticipated revenue. WPTE has not currently anticipated any revenues in excess of those subject to existing contractual relationships, since WPTE has insufficient operating history to enable such anticipation. Accordingly, television costs related to the new PPT series will continue to be expensed as incurred until a licensing agreement has been executed or WPTE has a firm commitment of revenue for the series. Marketing, distribution and general and administrative costs are expensed as incurred. Capitalized television production costs for each episode are expensed as revenues are recognized upon delivery and acceptance by the Travel Channel of the completed episode. Management of WPTE currently estimates that 44% of capitalized deferred television costs at October 2, 2005, are expected to be expensed in connection with episode deliveries by the end of fiscal 2005.
Accounting for long-term assets related to Indian casino projects:
Notes Receivable:
      Lakes is involved as the exclusive developer and manager of Indian-owned casino projects. The Company has formal procedures governing its evaluation of opportunities for potential development projects that it follows before entering into agreements to provide financial support for the development of these properties. Lakes determines that there is probable future economic benefit prior to recording any asset related to the Indian casino project. No asset related to an Indian casino project is recognized unless it is considered probable that the project will be built and result in an economic benefit to Lakes sufficient to recover the asset. Lakes initially evaluates the following six factors involving critical milestones that affect the probability of developing and operating a casino:
  •  Has the U.S. Government’s Bureau of Indian Affairs federally recognized the tribe as a tribe?
 
  •  Does the tribe hold or have the right to acquire land to be used for the casino site?
 
  •  Has the Department of the Interior put the land into trust for purposes of being used as a casino site?
 
  •  Has the tribe entered into a gaming agreement with the state in which the land is located, if required by the state?

30


Table of Contents

  •  Has the tribe obtained approval by the National Indian Gaming Commission of the management agreement?
 
  •  Do other legal and political obstacles exist that could block development of the project and, if so, what is the likelihood of the tribe successfully prevailing?
      In addition to the above factors, Lakes also considers economic and qualitative factors affecting Lakes’ future economic benefits from the project, including the following:
  •  An evaluation by Company management of the financial projections of the project given the project’s geographic location and the feasibility of the project’s success given such location;
 
  •  The structure and stability of the tribal government;
 
  •  The scope of the proposed project, including the physical scope of the contemplated facility and the expected financial scope of the related development;
 
  •  An evaluation of the proposed project’s ability to be built as contemplated and the likelihood that financing will be available; and
 
  •  The nature of the business opportunity to Lakes, including whether the project would be a financing, development and/or management opportunity.
      The development phase of each relationship commences with the signing of the respective contracts and continues until the casinos open for business; thereafter, the management phase of the relationship, governed by the management contract, continues for a period of up to seven years. Lakes, as developer and manager, has the exclusive right and obligation to develop, manage, operate and maintain the casino and to train tribal members and others in the operation and maintenance of the casino during the term of the contract. The Company also makes advances to the tribes to fund certain portions of the projects, which bear interest generally at prime plus 1% or 2%. Repayment of the advances and accrued interest is only required if the casino is successfully opened and distributable profits are available from the casino operations. Under the management contract Lakes typically earns a management fee calculated as a percentage of the net income of the operations. In addition, repayment of the loans and the manager’s fees under the management contracts are subordinated to certain other financial obligations of the respective operations. Generally, the order of priority of payments from the casinos’ cash flows is as follows: a certain minimum monthly priority payment to the tribe, repayment of various senior debt associated with construction and equipping of the casino with interest accrued thereon, repayment of various debt with interest accrued thereon due to Lakes, management fee to Lakes, and other obligations, with the remaining funds distributed to the tribe.
      The Company accounts for its advances to the tribes and its management contracts as separate elements. The advances made to the tribes are accounted for as structured notes in accordance with the guidance contained in Emerging Issues Task Force Consensus No. 96-12 Recognition of Interest Income and Balance Sheet Classification of Structured Notes (EITF No. 96-12). Because repayment of the notes is required only if a casino is successfully opened, Lakes’ advances may be at risk to not be repaid for reasons other than failure of the borrower to pay the contractual amounts due because if the casinos are not built the notes will not become contractually due. Accordingly, pursuant to the guidance in EITF No. 96-12, Lakes records its advances to tribes at estimated fair value. Because the stated rate of the notes receivable alone is not commensurate with the risk inherent in these projects, the estimated fair value of the notes receivable is generally less than the amount advanced. At the date of each advance, the difference between the estimated fair value of the note receivable and the actual amount advanced is recorded as an intangible asset related to the acquisition of the management contract. Subsequent to the initial recording, the two assets are accounted for separately.
      Subsequent to its initial recording at estimated fair value, the note receivable portion of the advance is adjusted to its current fair value at each balance sheet date based on current assumptions related to the projects. The notes receivable are not adjusted to an amount in excess of the face value of the note plus accrued interest. Changes in estimated fair value are recorded as unrealized gains or losses on notes receivable in the Company’s statement of operations.

31


Table of Contents

      The determination of estimated fair value requires that assumptions be made and judgments be applied regarding casino opening dates, interest rates, discount rates and probabilities of the projects opening based on a review of critical milestones. If casino opening dates, interest rates, discount rates or the probabilities of the projects opening change significantly, the estimated fair value of the related note receivable is adjusted accordingly and the Company could experience unrealized gains or losses that could be material.
      Upon opening of the casino Lakes may conclude that it is no longer reasonably possible that the advances to Indian tribes would be at risk to not be repaid for reasons other than failure of the borrower to pay the contractual amounts due. In such situations, the notes receivable will be accounted for under the effective interest method upon opening of the casino and will no longer be adjusted to fair value at each balance sheet date. Any difference between the then fair value of the advances and the amount contractually due under the notes will be amortized into income using the effective interest method over the remaining term of the note. Such notes would then be evaluated for impairment pursuant to Statement of Financial Accounting Standards No. 114 “Accounting by Creditors for Impairment of a Loan.”
Intangible Assets Related to Acquisition of Management Contracts:
      Intangible assets related to the acquisition of the management contracts are accounted for using the guidance in Statement of Financial Accounting Standards No. 142 Goodwill and Other Intangible Assets (FASB No. 142). Pursuant to that guidance, the assets are periodically evaluated for impairment based on the estimated cash flows from the management contract on an undiscounted basis. In the event the carrying value of the intangible assets, in combination with the carrying value of land held for development and other assets associated with the Indian casino projects described below, were to exceed the undiscounted cash flow, an impairment would be recorded. Such an impairment would be measured based on the difference between the fair value and carrying value of the assets. Lakes, in accordance with FASB No. 142, will amortize the intangible assets related to the acquisition of the management contracts under the straight-line method over the lives of the contracts which will commence when the related casinos open. In addition to the intangible asset associated with the cash advances to tribes described above, these assets include actual costs incurred to acquire Lakes’ interest in the projects from third parties.
Land Held for Development
      Included in land held for development is land held for possible transfer to Indian tribes for use in certain of the future casino resort projects. In the event that this land is not transferred to the tribes, the Company can sell it. Lakes evaluates these assets for impairment in combination with intangible assets related to acquisition of management contracts and other assets related to the Indian casino projects as discussed above.
Other
      Included in this category are costs incurred related to the Indian casino projects, which have not yet been included as part of the notes receivable because of timing of the payment of these costs. These amounts will ultimately be allocated between notes receivable and intangible assets related to the acquisition of management contracts and will be evaluated for changes in fair value or impairment, respectively, as described above. These amounts vary from period to period due to timing of payment of these costs.
      In addition, Lakes incurs certain costs related to the projects that are not included in notes receivable, which are expensed as incurred. These costs include salaries, travel and certain legal costs.

32


Table of Contents

      The consolidated balance sheets as of October 2, 2005 (unaudited) and January 2, 2005 include long-term assets related to Indian casino projects of $142.5 million and $125.6 million, respectively, primarily related to three separate projects. The amounts are summarized by project (in thousands) as follows:
                                         
    October 2, 2005
     
        Shingle    
    Pokagon   Springs   Jamul    
    Band   Tribe   Tribe   Other   Total
                     
    (Unaudited)
Notes receivable, at fair value
  $ 41,182     $ 23,979     $ 10,897     $ 1,731     $ 77,789  
Intangible assets related to acquisition of management contracts
    18,116       18,125       7,449       600       44,290  
Land held for development
          8,810       6,612       742       16,164  
Other
    75       1,471       881       1,820       4,247  
                               
Total long-term assets related to the Indian casino project
  $ 59,373     $ 52,385     $ 25,839     $ 4,893     $ 142,490  
                               
                                         
    January 2, 2005
     
        Shingle    
    Pokagon   Springs   Jamul    
    Band   Tribe   Tribe   Other   Total
                     
Notes receivable, at fair value
  $ 35,931     $ 21,775     $ 9,345     $ 15     $ 67,066  
Intangible assets related to acquisition of management contracts
    17,604       16,698       6,789       5       41,096  
Land held for development
          8,772       6,661             15,433  
Other
    71       1,315       638             2,024  
                               
Total long-term assets related to the Indian casino project
  $ 53,606     $ 48,560     $ 23,433     $ 20     $ 125,619  
                               
      The key assumptions used to estimate the fair value of the notes receivable are estimated casino opening date, projected interest rates, discount rates and probability of projects opening. The estimated casino opening date used in the valuation reflects the weighted average of three scenarios: a base case (which is based on the Company’s forecasted casino opening date) and one and two years out from the base case. The projected interest rates are based upon the one year U.S Treasury Bill spot yield curve per Bloomberg and the specific assumptions on contract term, stated interest rate and casino opening date. The discount rate for the projects is based on the yields available on certain financial instruments at the valuation date, the risk level of equity investments in general, and the specific operating risks associated with open and operating gaming enterprises similar to each of the projects. In estimating this discount rate, market data of other public gaming related companies was considered. The probability applied to each project is based upon a weighting of four different scenarios with the fourth scenario assuming the casino never opens. The first three scenarios assume the casino opens but applies different opening dates as discussed above. The probability weighting applied to each scenario captures the element of risk in these projects and is based upon the status of each project, review of the critical milestones and likelihood of achieving the milestones.

33


Table of Contents

      The following table provides the key assumptions used to estimate the fair value of the notes receivable (dollars in thousands):
      Pokagon Band:
         
    As of October 2, 2005   As of January 2, 2005
         
Face value of note (principal and interest)
  $59,987 ($45,814 principal and $14,173 interest)   $55,747 ($44,550 principal and $11,197 interest)
Estimated months until casino opens (weighted average of three scenarios)
  33 months   33 months
Projected interest rate until casino opens
  7.9%   6.8%
Projected interest rate during the loan repayment term
  8.0%   8.2%
Discount rate
  15%   15%
Repayment terms of note
  60 months   60 months
Probability rate of casino opening (weighting of four scenarios)
  85%   75%
      A portion of the notes due from the Pokagon Band include funds advanced of approximately $24.1 million by the Company for the Pokagon Band’s purchase of land. The Company has a first deed of trust against substantially all of this property, which will be relinquished when the Bureau of Indian Affairs (“BIA”) places the land into trust.
      The estimated probability rate was increased from 75% to 85% during the three months ended April 3, 2005, due to an evaluation of all critical milestones and due to the favorable federal judge ruling issued in March 2005 that will allow the land to be taken into trust by the Federal Government. Subsequently the Taxpayers of Michigan Against Casinos (“TOMAC”) filed for an appeal. The appeal hearing date was held on December 8, 2005 and a decision is pending. Due to the delay related to this litigation the weighted average estimated casino opening date was extended from April 2008 to July 2008 during the three-month period ended October 2, 2005.
      TOMAC commenced the litigation against the Federal Government in 2001 after the U.S. Department of Interior issued a finding of no significant impact and recommended that land be taken into trust on behalf of the Pokagon Band. The land in trust issue has been the most significant critical milestone delaying the opening of the casino.
      See further discussion included below under “Description of each Indian casino project and evaluation of critical milestones — Pokagon Band.”

34


Table of Contents

      Shingle Springs Tribe:
         
    As of October 2, 2005   As of January 2, 2005
         
Face value of note (principal and interest)
  $43,944 ($36,409 principal and $7,535 interest)   $38,156 ($33,076 principal and $5,080 interest)
Estimated months until casino opens (weighted average of three scenarios)
  37 months   36 months
Projected interest rate until casino opens
  8.9%   7.9%
Projected interest rate during the loan repayment term
  8.9%   8.7%
Discount rate
  15%   15%
Projected repayment terms of note*
  24 months   24 months
Probability rate of casino opening (weighting of four scenarios)
  70%   70%
 
Payable in varying monthly installments based on contract terms subsequent to the casino opening.
      As a result of delays related to litigation surrounding access to the reservation via an interchange, the weighted average estimated casino opening date was extended from July 2008 to November 2008 during the three-month period ended October 2, 2005 (see further discussion below included under the caption “Description of each Indian casino project and evaluation of critical milestones — Shingle Springs”).
      Jamul Tribe:
         
    As of October 2, 2005   As of January 2, 2005
         
Face value of note (principal and interest)
  $19,817 ($15,885 principal and $3,932 interest)   $17,306 ($14,467 principal and $2,839 interest)
Estimated months until casino opens (weighted average of three scenarios)
  37 months   36 months
Projected interest rate until casino opens
  8.9%   7.9%
Projected interest rate during the loan repayment term
  9.1%   8.7%
Discount rate
  15%   15%
Repayment terms of note
  84 months   84 months
Probability rate of casino opening (weighting of four scenarios)
  75%   75%
      As a result of delays related to getting land contiguous to the reservation placed into trust, the weighted average estimated casino opening date was extended from July 2008 to November 2008 during the three-month period ended October 2, 2005. Because of the slow process, during August of 2005, the Jamul Tribe and Lakes formally announced plans to build the casino on the approximate six acres of reservation land held by the Jamul Tribe. Reservation land qualifies for gaming without going through a land in trust process (see further discussion below included under the caption “Description of each Indian casino project and evaluation of critical milestones — Jamul Tribe”).
      The fair value estimation requires that assumptions be made and judgments be applied regarding estimated casino opening dates, projected interest rates, discount rates and probabilities of the projects opening. If the assumptions used in the fair value calculation change significantly the Company could be exposed to unrealized gains or losses that could be material.

35


Table of Contents

      The following table represents a sensitivity analysis prepared by the Company of the notes receivable from the Jamul Tribe, Pokagon Band and Shingle Springs Tribe, based upon a change in the probability rate of the casino opening by five percentage points and the estimated casino opening date by one year:
                                                         
        Sensitivity Analysis
    October 2, 2005    
    Fair Value   5% Less       5% Increased   One Year    
    Notes Receivable   Probable   One Year Delay   Both   Probability   Sooner   Both
                             
Pokagon
  $ 41,181,729     $ 39,003,097     $ 38,882,230     $ 36,838,863     $ 43,360,361     $ 43,633,447     $ 45,956,298  
Shingle Springs
  $ 23,978,695     $ 22,181,860     $ 22,635,600     $ 20,934,700     $ 25,775,531     $ 25,397,545     $ 27,295,727  
Jamul
  $ 10,896,989     $ 10,185,157     $ 10,326,904     $ 9,653,077     $ 11,608,822     $ 11,499,229     $ 12,251,211  
                                           
    $ 76,057,414     $ 71,370,114     $ 71,844,735     $ 67,426,640     $ 80,744,714     $ 80,530,221     $ 85,503,236  
                                           
                                                         
        Sensitivity Analysis
    January 2, 2005    
    Fair Value   5% Less       5% Increased   One Year    
    Notes Receivable   Probable   One Year Delay   Both   Probability   Sooner   Both
                             
Pokagon
  $ 35,931,000     $ 33,957,913     $ 33,825,802     $ 29,583,071     $ 37,904,088     $ 38,197,409     $ 40,321,591  
Shingle Springs
  $ 21,775,000     $ 20,252,095     $ 20,453,118     $ 19,024,633     $ 23,297,905     $ 23,184,255     $ 24,807,821  
Jamul
  $ 9,345,000     $ 8,734,015     $ 8,776,784     $ 8,203,679     $ 9,955,986     $ 9,950,775     $ 10,602,146  
                                           
    $ 67,051,001     $ 62,944,022     $ 63,055,704     $ 56,811,384     $ 71,157,979     $ 71,332,440     $ 75,731,558  
                                           
      The assumption changes used in the sensitivity analysis above are hypothetical. The effect of the variation in the probability assumption and estimated opening date on the estimated fair value of the notes receivable from Indian tribes was calculated without changing any other assumptions; in reality, changes in these factors may result in changes in another. For example, the change in probability could be associated with a change in discount rate, which might magnify or counteract the sensitivities.
      The following represents the nature of the advances to the tribes. The table represents the total amount of advances, which represent the principal amount of the notes receivable, as of October 2, 2005 and January 2, 2005. The notes receivable are carried on the consolidated balance sheets at October 2, 2005 (unaudited) and January 2, 2005 at their estimated fair values of $77.8 million and $67.1 million, respectively.
                                         
    Balance at
    October 2, 2005
     
        Shingle    
Advances Principal Balance   Pokagon   Springs   Jamul   Other   Total
                     
Note receivable, pre-construction(a)
  $ 21,713     $ 36,409     $ 14,935     $     $ 73,057  
Note receivable, non — gaming land(b)
    13,176                         13,176  
Note receivable, land(b)
    10,925             950             11,875  
Note receivable, other
                      2,256       2,256  
                               
    $ 45,814     $ 36,409     $ 15,885     $ 2,256     $ 100,364  
                               
                                         
    Balance at
    January 2, 2005
     
        Shingle    
Advances Principal Balance   Pokagon   Springs   Jamul   Other   Total
                     
Note receivable, pre-construction(a)
  $ 20,449     $ 33,076     $ 13,517     $     $ 67,042  
Note receivable, non — gaming land(b)
    13,176                         13,176  
Note receivable, land(b)
    10,925             950             11,875  
Note receivable, other
                      20       20  
                               
    $ 44,550     $ 33,076     $ 14,467     $ 20     $ 92,113  
                               

36


Table of Contents

 
(a) Lakes advances funds to the tribes, which are related to certain costs incurred to develop the casino project. These costs relate to construction costs, legal fees in connection with various regulatory approvals and litigation, environmental costs and design consulting, and Lakes, in order to obtain the development agreement and management contract, agrees to advance a monthly amount used by the tribe for a variety of tribal expenses.
 
(b) Lakes purchased land to be used and transferred to the tribe in connection with the casino project. At Pokagon, a portion of the land will be used by the tribe separate from the casino project land.
      The notes receivable for pre-construction advances consist of the following principal amounts advanced to the tribes at October 2, 2005 and January 2, 2005 (in thousands):
                   
Pokagon   October 2, 2005   January 2, 2005
         
Monthly stipend
  $ 9,250     $ 8,125  
Construction
    2,633       2,580  
Legal
    1,384       1,379  
Environmental
    650       645  
Design
    7,796       7,720  
             
 
Total principal amount of pre-construction advances
  $ 21,713     $ 20,449  
             
                   
Shingle Springs   October 2, 2005   January 2, 2005
         
Monthly stipend
  $ 6,090     $ 4,980  
Construction
    1,622       1,605  
Legal
    11,495       10,290  
Environmental
    1,586       1,577  
Design
    9,267       9,120  
Gaming license
    3,376       3,226  
Lobbyist
    2,973       2,278  
             
 
Total principal amount of pre-construction advances
  $ 36,409     $ 33,076  
             
                   
Jamul   October 2, 2005   January 2, 2005
         
Monthly stipend
  $ 3,746     $ 3,319  
Construction
    159       159  
Legal
    3,123       2,606  
Environmental
    1,659       1,628  
Design
    3,830       3,640  
Gaming license
    496       429  
Lobbyist
    1,922       1,736  
             
 
Total principal amount of pre-construction advances
  $ 14,935     $ 13,517  
             
Lakes’ evaluation of impairment related to long-term assets related to Indian casino projects, excluding the notes receivable, which are valued at estimated fair value:
      Management periodically evaluates the intangible assets, land held for development and other costs associated with each of the projects for impairment. The assets are periodically evaluated for impairment based on the estimated cash flows from the management contract on an undiscounted basis. In the event the carrying value of the intangible assets, in combination with the carrying value of land held for development and other assets associated with the Indian casino projects were to exceed the undiscounted cash flow, an

37


Table of Contents

impairment would be recorded. Such impairment would be measured based on the difference between the fair value and carrying value of the assets.
      The financial models prepared by management for each project are based upon the scope of each of the projects, which are supported by a feasibility study as well as a market analysis where the casino will be built. Lakes’ (as its predecessor Grand Casinos Inc.) began developing Indian casino projects in 1990 and demonstrated success from the day the first Indian casino opened in 1991 through the expiration of its Coushatta management contract in 2002. This success legitimizes many of the key assumptions supporting the financial models. Projections for each applicable casino development were developed based on analysis of published information pertaining to the particular markets in which the Company’s Indian casinos will be located. In addition, Lakes has many years of casino operations experience within the Company, which provides a basis for its revenue expectations. The projections were prepared by Lakes not for purposes of the valuation at hand but rather for purposes of Lakes’ and the tribes’ business planning.
      The primary assumptions included within management’s financial model for each Indian casino project is as follows:
Pokagon Band
         
    October 2, 2005   January 2, 2005
         
No. of class III slot machines
  3,000   3,000
No. of table games
  100   100
No. of poker tables
  20   20
Win/class III slot machine/day — 1st year
  $275   $275
Win/table game/day — 1st year
  $1,300   $1,300
Win/poker game/day — 1st year
  $1,000   $1,000
Expected increase (decrease) in management fee cash flows
  Year 2 - (6.4%) (Decrease due to repayment of senior debt)
Year 3 - 1.9%
Year 4 - 3.6%
Year 5 - 2.8%
  Year 2 - (6.4%) (Decrease due to
repayment of senior debt)
Year 3 - 1.9%
Year 4 - 3.6%
Year 5 - 2.8%
      With regard to the Pokagon Casino project in southwest Michigan, the competitive market consists primarily of five Northern Indiana riverboats. The State of Indiana publicly reports certain results from these riverboat casinos, which supports the underlying assumptions in our projections. Specifically, the Northern Indiana trailing twelve months market average for slot machine revenue has consistently been above $300 win per unit per day or greater than $105,000 per machine per year which exceeds the $275 win per unit per day that we used in our Pokagon Casino projections. Of the five casinos in the market, two locations produced a win per unit less than our projections with three casinos producing win per unit revenue amounts greater than our forecast. The closest casino to our location consistently produces approximately $330 win per unit per day.

38


Table of Contents

Jamul Tribe
         
    October 2, 2005   January 2, 2005
         
No. of class III slot machines
  349   349
No. of class II slot machines
  1,651   1,651
No. of table games
  65   65
No. of Poker tables
  10   10
Win/class III slot machine/day — 1st year
  $285   $285
Win/class II slot machine/day —1st year
  $200   $200
Win/table game/day — 1st year
  $1,100   $1,100
Win/poker table/day — 1st year
  $650   $650
Expected increase (decrease) in management fee cash flows
  Year 2 - (8.8%) (Decrease due to repayment of senior debt)
Year 3 - 2.8%
Year 4 - 2.9%
Year 5 - 1.9%
Year 6 - 2.8%
Year 7 - 1.5%
  Year 2 - (8.8%) (Decrease due to repayment of senior debt)
Year 3 - 2.8%
Year 4 - 2.9%
Year 5 - 1.9%
Year 6 - 2.8%
Year 7 - 1.5%
      The San Diego market contains other Indian-owned casinos in the surrounding area, each of which is self-managed. Because of the proprietary nature of those operations no public information is readily attainable. However, based on the apparent successful nature of their operations (large casinos which continually expand, new hotel developments, new golf courses, etc.) coupled with our knowledge of their operations, we feel that our forecast of operations is within the revenue metrics of the market.
Shingle Springs Tribe
         
    October 2, 2005   January 2, 2005
         
No. of class III slot machines
  349   349
No. of class II slot machines
  1,651   1,651
No. of table games
  100   100
No. of poker tables
  20   20
Win/class III slot machine/day — 1st year
  $350   $350
Win/class II slot machine/day —1st year
  $250   $250
Win/table game/day — 1st year
  $1,275   $1,275
Win/poker table/day — 1st year
  $624   $624
Expected increase (decrease) in management fee cash flows
  Year 2 - (8.9%) (Decrease due to repayment of senior debt)
Year 3 - 3.6%
Year 4 - 3%
Year 5 - 5.1%
Year 6 - (17%) (Management fees were reduced in years six and seven)
Year 7 - 10.8%
  Year 2 - (8.9%) (Decrease due to repayment of senior debt)
Year 3 - 3.6%
Year 4 - 3%
Year 5 - 5.1%
Year 6 - (17%) (Management fees were reduced in years six and seven)
Year 7 - 10.8%
      In the Shingle Springs Sacramento market, there is one other Indian casino that is managed by another public company. Management took into consideration available information related to this other Indian casino when projecting management fees from the Shingle Springs Casino. Based on the apparent successful nature

39


Table of Contents

of their operations coupled with our knowledge of their operations, we feel that our forecast of operations is within the revenue metrics of the market.
      As of October 2, 2005 and January 2, 2005, no impairment was recognized on the Pokagon, Shingle Springs or Jamul projects.
Description of each Indian casino project and evaluation of critical milestones:
Pokagon Band
Business arrangement:
      Lakes, in July 1999, entered into a development agreement and management contract with the Pokagon Band, a federally recognized tribe with a compact with the State of Michigan, to develop and manage a casino on approximately 675 acres in southwest Michigan. The first phase of the casino is planned to include approximately 3,000 slot machines, 100 table games, various restaurant and bar venues, enclosed parking, a childcare facility and arcade, and various other resort amenities.
      The development agreement provides for Lakes to advance up to approximately $73.0 million for purchase of land and for the initial development phase of the project. The development agreement for the Pokagon project also provides that to the extent the Pokagon Band is unable to raise additional funding from third parties at an interest rate not to exceed 13%, Lakes will be required to provide additional financing of up to approximately $54.0 million. Based on extensive discussions with prospective lenders, it appears that third party financing will be available for this project; however, there can be no assurance that third party financing will be available at the time construction for the project begins. Lakes is not required to fund these amounts; however, if Lakes discontinued the funding prior to fulfilling the obligation, Lakes would forfeit the rights under the management contract.
      Lakes will receive approximately 24% of net income up to a certain level and 19% of the net income over that level, as a management fee. The term of the management contract is currently planned for five years beginning when the casino opens to the public and may extend for a total of seven years under certain circumstances. Payment of Lakes’ management fee will be subordinated to senior indebtedness of the Pokagon casino. The Pokagon Band may terminate the management contract after five years from the opening of the casino if any of certain required elements of the project have not been developed or certain financial commitments to the Pokagon Band have not been met. The Pokagon Band may also buy out the management contract provisions after two years from the opening date. The buyout amount is calculated based upon the previous 12 months of management fees earned multiplied by the remaining number of years under the management contract, discounted back to the present value at the time the buyout occurs. The management fee and length of contract are subject to regulatory approval. If the land were taken into trust in 2006 then the casino could open as early as late 2007.
      The Company will be obligated to pay an amount to an unrelated third party once the Pokagon Casino is open and Lakes is the manager of the casino. The amount is payable quarterly for five years and is only payable if Lakes is the manager of the casino. The payment is part of a settlement and release agreement associated with Lakes obtaining the management contract with the Pokagon Band. The maximum liability over the five-year period is approximately $11 million.

40


Table of Contents

Lakes’ evaluation of critical milestones:
      The following table outlines the status of each of the following primary milestones necessary to complete the Pokagon project as of the end of fiscal year 2003 and 2004 and as of October 2, 2005. Both the positive and negative evidence was reviewed during Lakes’ evaluation of the critical milestones.
             
Critical Milestone   December 28, 2003   January 2, 2005   October 2, 2005
             
Federal recognition of the tribe
  Yes   Yes   Yes
Possession of usable land corresponding with needs based on the Company’s project plan
  Yes   Yes   Yes
Usable land placed in trust by Federal government
  No — The Pokagon Band and Lakes continued to provide support for the case and in January 2003 the federal judge dismissed all issues except for the final issue and requested additional information from the BIA.   No — The additional information was submitted by the BIA in August 2004 and the lawsuit was still pending resolution as of January 2, 2005.   No — The additional information was submitted by the BIA in August 2004 and the lawsuit was still pending resolution as of January 2, 2005. Subsequently in March 2005 the federal judge dismissed the last remaining issue filed by Taxpayers of Michigan Against Casinos (TOMAC) and ruled in favor of the Pokagon Band allowing the land to be placed into trust by the BIA. During the required 60 day waiting period, TOMAC filed for an appeal. An agreement has been reached between the Department of Justice and TOMAC to not take the land into trust during the appeal process in exchange for TOMAC agreeing to a “fast track” hearing process. The appeal hearing date was held on December 8, 2005 and a decision is pending.
Usable county agreement, if applicable
  Yes   Yes   Yes

41


Table of Contents

             
Critical Milestone   December 28, 2003   January 2, 2005   October 2, 2005
             
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan
  Yes   Yes   Yes
NIGC approval of management contract in current and desired form
  No, submitted to the NIGC for review in 2000.   No, submitted to the NIGC for review in 2000 and approval is expected at approximately the same time the land is being placed into trust by the BIA.   No, submitted to the NIGC for review in 2000 and approval is expected at approximately the same time the land is being placed into trust by the BIA.
Resolution of all litigation and legal obstacles
  No, pending litigation regarding land in trust — see below.   No, pending litigation regarding land in trust — see below.   No, pending litigation regarding land in trust — see below.
Financing for construction
  No, however the Tribe engaged an investment banker to assist with obtaining financing.   No, however the Tribe engaged an investment banker to assist with obtaining financing.   No, however the Tribe engaged an investment banker to assist with obtaining financing.
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned
  No others known at this time by Lakes.   No others known at this time by Lakes.   No others known at this time by Lakes.
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      The Pokagon Band became a federally recognized tribe through an act of Congress prior to them entering into any agreements with Lakes. As part of this congressional action the Federal Government mandated that the Pokagon Band “shall” have land taken into trust on their behalf.
      In 1999, Lakes entered into a development agreement and management contract with the Pokagon Band. At that time the Pokagon Band was federally recognized and they had a compact with the State of Michigan. During 1999 and 2000, Lakes purchased land on behalf of the Pokagon Band.
      In January 2001, the U.S. Department of Interior issued a finding of no significant impact and recommended that land be taken into trust on behalf of the Pokagon Band. During the required 30-day waiting period a lawsuit was filed by the TOMAC against the federal government to stop the land in trust process. Lakes and the Pokagon Band continued to provide support for this case and believed it would be resolved in favor of the Band. The first hearing before the federal judge took place on December 2001. In March 2002, the judge eliminated several of TOMAC’s assertions and continued to review the remaining issues. In January 2003, the Judge dismissed all remaining issues except for one and requested additional information from the federal government (“BIA”) to support their conclusions on that one issue. Due to the fact that all issues except for one had been dismissed, Lakes continued to believe that it was probable that the land would be taken into trust and that the casino would open. The BIA submitted the additional information in August 2004; and in March 2005, the federal judge dismissed the last remaining issue filed by TOMAC making it possible for the land to be taken into trust for the gaming project. During the required 60-day waiting period, TOMAC filed for an appeal. An agreement has been reached between the Department of Justice and

42


Table of Contents

TOMAC to not take the land into trust during the appeal process in exchange for TOMAC agreeing to a “fast track” hearing process. The appeal hearing date was held on December 8, 2005 and a decision is pending. The federal lawsuit has been the most significant item delaying the opening of the casino. Lakes believes the outcome of this appeal will be favorable because of the sequence of events that have occurred in favor of the project to date, the existing state of the law and most recently, the March 2005 dismissal of the last remaining item in the lawsuit by the federal judge. The federal judge dismissed claims that the BIA had not completed a sufficient environmental assessment of the proposed casino site. Lakes believes this decision will be upheld during the appeal process because the evidence provided to the federal judge (including legal arguments), which was the federal judge’s basis for his favorable decision as to the sufficiency of the environmental assessment as it relates to the Pokagon project, has been reviewed by third-party advisors of both the Pokagon Band and Lakes, and we and our advisors continue to believe the environmental assessment that has been performed meets all necessary requirements for the land to be taken into trust. We expect approval of the management contract by the NIGC at approximately the same time the land is taken into trust by the BIA. Once the land is taken into trust, Lakes will help the Pokagon Band build and manage their casino development. Construction of the project could begin in late 2006 with an expected opening date twelve months following the start of construction.
Shingle Springs
Business arrangement:
      Plans for the Shingle Springs Casino project include an approximately 238,000 square-foot facility (including approximately 80,000 square feet of casino space) to be located adjacent to the planned Shingle Springs Rancheria exit, approximately 35 miles east of downtown Sacramento, on U.S. Highway 50. The Shingle Springs Casino is currently planned to feature approximately 2,000 gaming devices and approximately 100 table games, as well as restaurants, enclosed parking and other facilities.
      Lakes acquired its initial interest in the development and management contracts for the Shingle Springs Casino from Kean Argovitz Resorts- Shingle Springs, LLC (“KAR — Shingle Springs”) in 1999 and formed a joint venture, in which the contracts were held, between Lakes and KAR — Shingle Springs. On January 30, 2003, Lakes purchased the remaining KAR — Shingle Springs’ partnership interest in the joint venture. In connection with the purchase transaction, Lakes entered into separate agreements with the two individual owners of KAR — Shingle Springs (Kevin M. Kean and Jerry A. Argovitz). Under the agreement with Mr. Kean, Mr. Kean may elect to serve as a consultant to Lakes during the term of the casino management contract if he is found suitable by relevant gaming regulatory authorities. In such event, Mr. Kean will be entitled to receive annual consulting fees equal to 15% of the management fees received by Lakes from the Shingle Springs Casino operations, less certain costs of these operations. If Mr. Kean is not found suitable by relevant gaming regulatory authorities or otherwise elects not to serve as a consultant, he will be entitled to receive annual payments of $1 million from the Shingle Springs Casino project during the term of the respective casino management contract (but not during any renewal term of such management contract).
      Under the agreement with Mr. Argovitz, if he is found suitable by relevant gaming regulatory authorities he may elect to re-purchase his respective original equity interest in the Lakes’ subsidiary and then be entitled to obtain a 15% equity interest in Lakes’ management contract with the Shingle Springs Casino. If he is not found suitable or does not elect to purchase equity interests in the Lakes’ subsidiary, Mr. Argovitz would receive annual payments of $1 million from the Shingle Springs Casino project from the date of election through the term of the respective casino management contract (but not during any renewal term of such management contract).
      The development agreement provides for Lakes to make certain pre-construction advances to the Shingle Springs Tribe in the form of a transition loan and land loan up to a maximum amount of $50.0 million. Lakes is not required to fund these amounts; however, if Lakes discontinued the funding prior to fulfilling the obligation, Lakes would forfeit the rights under the management contract.
      The agreement provides for Lakes to arrange for financing or, in its discretion, loan to the Shingle Springs Tribe in the form of a facility loan, funds for the costs of construction and initial costs of operation up to a

43


Table of Contents

maximum currently of $300 million. In addition, Lakes will assist in the design, development and construction of the facility as well as manage the pre-opening, opening and continued operations of the casino and related amenities for a period of seven years. As compensation for its management services, Lakes will receive a management fee between 21% and 30% of net income of the operations annually for the first five years, with a declining percentage in years six and seven, as that term is defined by the management contract. Payment of Lakes’ management fee will be subordinated to senior indebtedness of the Shingle Springs Casino and minimum priority payment to the Shingle Springs Tribe. The Shingle Springs Tribe may terminate the agreement after five years from the opening of the casino if any of certain required elements of the project have not been developed. The management contract includes provisions that allow the Shingle Springs Tribe to buy out the management contract after four years from the opening date. The buyout amount is calculated based upon the previous twelve months of management fees earned multiplied by the remaining number of years under the contract, discounted back to the present value at the time the buyout occurs.
Lakes’ Evaluation of the Critical Milestones:
      The following table outlines the status of each of the following primary milestones necessary to complete the Shingle Springs project as of the end of fiscal year 2003 and 2004 and as of October 2, 2005. Both the positive and negative evidence was reviewed during Lakes’ evaluation of the critical milestones.
             
Critical Milestone   December 28, 2003   January 2, 2005   October 2, 2005
             
Federal recognition of the tribe
  Yes   Yes   Yes
Possession of usable land corresponding with needs based on the Company’s project plan
  Yes   Yes   Yes
Usable land placed in trust by Federal government
  Not necessary, as land is reservation land.   Not necessary, as land is reservation land.   Not necessary, as land is reservation land.
Usable county agreement, if applicable
  N/A   N/A   N/A
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan
  Yes   Yes   Yes
NIGC approval of management contract in current and desired form
  No, submitted to the NIGC for review in 2000.   Yes — approval received in 2004.   Yes — approval received in 2004.
 
Resolution of all litigation and legal obstacles
  No, Federal and state litigation regarding approval of highway interchange, environmental issues and other issues.
— See below.
  No, Federal and state litigation regarding approval of highway interchange, environmental issues and other issues.
— See below.
  No, Federal and state litigation regarding approval of highway interchange, environmental issues and other issues.
— See below.

44


Table of Contents

             
Critical Milestone   December 28, 2003   January 2, 2005   October 2, 2005
             
Financing for construction
  No, however the Tribe has engaged investment banks to assist with obtaining financing.   No, however the Tribe has engaged investment banks to assist with obtaining financing.   No, however the Tribe has engaged investment banks to assist with obtaining financing
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned
  No others known at this time by Lakes.   No others known at this time by Lakes.   No others known at this time by Lakes.
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      The Shingle Springs Tribe is a federally recognized tribe, has a compact with the State of California and owns approximately 160 acres of reservation land on which the casino can be built. During July 2004, Lakes received notification from the NIGC that the development and management contract between the Shingle Springs Tribe and Lakes, allowing Lakes to manage a Class II and Class III casino, was approved by the NIGC.
      In January 2005, Lakes received a favorable ruling from the federal court on all federal issues with respect to the casino development planned by the Shingle Springs Tribe. El Dorado County is appealing the federal favorable ruling related to the project.
      The most significant milestone yet to be achieved for this project is commercial access to the reservation on which the casino will be built. The Shingle Springs Tribe received state regulatory approval of a necessary interchange to access the tribal land during 2002. Neighboring El Dorado County and another local group commenced litigation in federal and state courts against the California regulatory agencies attempting to block the approval of the interchange. During January of 2004, the California Superior Court ruled in favor of the California Department of Transportation (“CalTrans”) on all of El Dorado County’s claims challenging CalTrans’ environmental review of the proposed casino project except that the court asked for clarification on one issue. The one remaining issue in the state case questions the state standards for ozone requirements of all of CalTrans projects throughout California. El Dorado County, Voices for Rural Living, CalTrans and the Shingle Springs Tribe filed an appeal and oral arguments on these appeals was heard in August 2005. In November 2005, the California Court of Appeal (“Court”) issued its decision on these appeals. The Court ruled in favor of CalTrans’ appeal, rejecting the El Dorado County’s argument that the transportation conformity analysis did not conform to state standards. The Court also rejected all but two of the legal claims asserted in the appeal by El Dorado County and Voices for Rural Living against the environmental impact report (“EIR”) prepared by CalTrans for the interchange that will connect Highway 50 to the Shingle Springs Rancheria. For the remaining two issues, the Court held that CalTrans must supplement its environmental analysis by adding some discussion to the air quality chapter to further explain the project’s contribution to overall vehicular emissions in the region, and that CalTrans also must evaluate whether a smaller casino and hotel would reduce environmental impacts. The Court acknowledged CalTrans lacks jurisdiction to require the Shingle Springs Tribe to develop a smaller casino, but nevertheless required some discussion of this alternative in the interchange EIR.
      Lakes has monitored the lawsuit in California state court closely, and Lakes believes it is likely that the state court action will be ultimately resolved in favor of the project because the current ruling not only jeopardizes a significant amount of other transportation projects in the state of California, but also because it is contrary to California law. Under state and federal environmental rules, if just one project is stopped or postponed as a result of an environmental ruling similar to the one in this matter, all other ongoing and planned transportation projects likely would be required to satisfy the same air quality requirements imposed

45


Table of Contents

by the trial court in order to proceed and they could not do so, resulting in the loss of funding for such projects. Lakes believes that this final issue in state court will ultimately be overcome because the trial court ruling is not only without precedent, but it is contrary to existing case and statutory law. Accordingly, and in light of the trial court ruling’s far-reaching and devastating impact on ongoing road projects, Lakes expects the trial court’s ruling will be reversed on appeal, meaning this project and other road projects in the area will be allowed to move forward. Construction of the interchange and casino could begin as early as the third quarter of 2006 with an estimated opening date approximately 14 months after the start of the construction.
      Under the form of tribal-state compact first signed by the State of California with both the Jamul and Shingle Springs tribes in 1999, each tribe is allowed to operate up to 350 Class III slot machines without licenses from the state. This form of compact allows tribes to operate up to an additional 1,650 Class III slot machines by obtaining licenses for the devices from the state. Under these tribal-state compacts, there is a state-wide limitation on the aggregate number of Class III slot machine licenses that are available. Tribes who have entered into new tribal-state compacts or amendments to the 1999 form of tribal-state compact in general are allowed to operate an unlimited number of Class III slot machines without the need for obtaining additional licenses, subject to the payment of additional fees to the state, including, in recent cases, fees based on a percentage of slot “net win.” Currently, neither the Jamul Tribe nor the Shingle Springs Tribe have amended their tribal-state compacts. If the compacts are not renegotiated and amended, the tribes could operate under their existing compacts which allows for up to 350 Class III gaming devices and an unlimited number of Class II gaming devices. Management believes that this number of gaming devices is adequate to equip the planned developments. Therefore, Lakes believes the availability of additional slot licenses is not an issue that could prevent the projects from progressing. The Shingle Springs project is currently planned to open with 349 Class III slot machines and approximate 1,650 Class II devices.
Jamul Tribe
Business arrangement:
      The Jamul Tribe has an approximate six-acre reservation on which the casino project is currently planned to be built. The reservation is located near San Diego, California. Plans for the casino include approximately 2,000 gaming devices and approximately 85 table games along with various restaurants and related amenities.
      Lakes acquired its initial interest in the development agreement and management contracts for the Jamul casino from Kean Argovitz Resorts-Jamul, LLC (“KAR — Jamul”) in 1999 and formed a joint venture in which the contracts were held between Lakes and KAR — Jamul. On January 30, 2003, Lakes purchased the remaining KAR — Jamul’s partnership interest in the joint venture. In connection with the purchase transaction, Lakes entered into separate agreements with the two individual owners of KAR — Jamul (Mr. Kean and Mr. Argovitz). The term of the contract is expected to be five or seven years. Under the agreement with Mr. Kean, Mr. Kean may elect to serve as a consultant to Lakes during the term of the casino management contract if he is found suitable by relevant gaming regulatory authorities. In such event, Mr. Kean will be entitled to receive annual consulting fees equal to 20% of the management fees received by Lakes from the Jamul Casino operations, less certain costs of these operations. If Mr. Kean is not found suitable by relevant gaming regulatory authorities or otherwise elects not to serve as a consultant, he will be entitled to receive annual payments of $1 million from the Jamul Casino project during the term of the respective casino management contract (but not during any renewal term of such management contract).
      Under the agreement with Mr. Argovitz, if he is found suitable by relevant gaming regulatory authorities he may elect to re-purchase his respective original equity interest in the Lakes’ subsidiary and then be entitled to obtain a 20% equity interest in Lakes’ management contract with the Jamul Tribe. If he is not found suitable or does not elect to purchase equity interests in the Lakes’ subsidiary, Mr. Argovitz may elect to receive annual payments of $1 million from the Jamul Casino project from the date of election through the term of the respective casino management contract (but not during any renewal term of such management contract).
      The development agreement provides for Lakes to make certain pre-construction advances to the Jamul Tribe of up to $30 million. Lakes is not required to fund these amounts; however, if Lakes discontinued

46


Table of Contents

the funding prior to fulfilling the obligation, Lakes would forfeit the rights under the management contract. Lakes will receive a management fee between 18% and 30% of net income of the operations annually for seven years, subject to regulatory approval of the management contract and subject to a minimum priority monthly payment to the Jamul Tribe.
      The Jamul Tribe may terminate the management contract after five years from the opening date of the casino if any of certain required elements of the project have not been developed. The management contract includes provisions that allow the Jamul Tribe to buy out the management contract after four years from the opening date. The buyout amount is calculated based upon the previous 12 months of management fees earned multiplied by the remaining number of years under the contract, discounted back to the present value at the time the buyout occurs.
Lakes’ Evaluation of the Critical Milestones:
      The following table outlines the status of each of the following primary milestones necessary to complete the Jamul project as of the end of fiscal year 2003 and 2004 and as of October 2, 2005. Both the positive and negative evidence was reviewed during Lakes’ evaluation of the critical milestones.
             
Critical Milestone   December 28, 2003   January 2, 2005   October 2, 2005
             
Federal recognition of the tribe
  Yes   Yes   Yes
Possession of usable land corresponding with needs based on the Company’s project plan
  Yes   Yes   Yes
Usable land placed in trust by Federal government
  Yes, six acres is reservation land held by the Jamul Tribe on which the casino will be built. There is an additional 82 acres contiguous to the reservation land pending BIA approval to be placed into trust that could be used for additional development of the project. The Jamul Tribe and Lakes were in the process of preparing an EIS, as described below and completing the land in trust application.   Yes, six acres is reservation land held by the Jamul Tribe on which the casino will be built. There is an additional 82 acres contiguous to the reservation land pending BIA approval to be placed into trust that could be used for additional development of the project. The Jamul Tribe and Lakes prepared an EIS and trust application, which has been submitted to, reviewed and recommended for approval by the regional office of the BIA. The Washington, D.C. office of the BIA is currently reviewing the submission.   Yes, six acres is reservation land held by the Jamul Tribe on which the casino will be built. There is an additional 82 acres contiguous to the reservation land pending BIA approval to be placed into trust that could be used for additional development of the project. The Jamul Tribe and Lakes prepared an EIS and trust application, which has been submitted to, reviewed and recommended for approval by the regional office of the BIA. The Washington, D.C. office of the BIA is currently reviewing the submission.
Usable county agreement, ifapplicable
  N/A   N/A   N/A

47


Table of Contents

             
Critical Milestone   December 28, 2003   January 2, 2005   October 2, 2005
             
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan
  Yes   Yes   Yes
NIGC approval of management contract in current and desired form
  No, submitted for approval by the NIGC in 2000 and approval is not expected to occur until the process to place land in trust by the BIA is complete.   No, submitted for approval by the NIGC in 2000. We are in communication with the NIGC and have responded to initial comments. Approval is not expected until the process to place land in trust by the BIA is complete.   No, submitted for approval by the NIGC in 2000. We are in communication with the NIGC and have responded to initial comments. Approval is not expected until the process to place land in trust by the BIA is complete.
Resolution of all litigation and legal obstacles
  N/A there has been some local opposition regarding the project, although no formal legal action has been taken.   N/A, there has been some local opposition regarding the project, although no formal legal action has been taken.   N/A, there has been some local opposition regarding the project, although no formal legal action has been taken.
Financing for construction
  No   No, however, preliminary discussions with investment bankers regarding assisting in obtaining financing have taken place.   No, however, preliminary discussions with investment bankers regarding assisting in obtaining financing have taken place.
Any other significant project milestones or contingencies, the outcome of which could have a material affecton the probability of project completion as planned
  No others known at this time by Lakes.   No others known at this time by Lakes.   No others known at this time by Lakes.
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      The Jamul Tribe is a federally recognized tribe with a compact with the State of California and has an approximate six acre reservation on which the casino is planned to be built. The primary effort in this project has been to place approximately 82 acres of land contiguous to the reservation into trust for gaming. Lakes acquired 101 acres of land contiguous to the six acres of reservation land of which 19 acres relate to land with certain easements, which will not be accepted into trust. The trust application, including an Environmental Impact Statement (“EIS”), has been prepared, submitted to, reviewed and recommended for approval by the regional office of the BIA. The Washington, D.C. office of the BIA is currently reviewing the submission to determine if the land should be taken into trust. There has been some local opposition regarding the project. An EIS is more rigorous to complete than a more typical EA (Environmental Assessment). The EIS was more intense and took longer to prepare but is considered a better method to address all potential environmental concerns surrounding this project and to mitigate potential future opposition that may delay the project.

48


Table of Contents

      The process of getting the land contiguous to the reservation placed into trust has been slow. Therefore, during August of 2005, the Jamul Tribe and Lakes formally announced plans to build the casino on the approximately six acres of reservation land held by the Jamul Tribe. Reservation land qualifies for gaming without going through a land in trust process. The approximate size of the casino and related guest amenities will not change in total, as the casino was always planned to be built on the reservation land. The approximate six-acre project would be built on various levels to accommodate essentially all of the same amenities that were planned for the project on the larger parcel of land. Therefore, the design of the project would change significantly from a complex of lower-level buildings spread out over a larger area to a multi-level resort built on a smaller parcel of land. Total square footage, nature or cost of the project are not expected to change significantly as it will be primarily the same project being built on a smaller footprint.
      Lakes has consulted with third-party advisors as to the architectural feasibility of the alternative plan and has been assured that the project can be successfully built on the reservation land. The Company has completed economic models for each alternative and concluded that either would result in a successful operation assuming that adequate financing can be obtained. Therefore, the Company believes this project will be successfully completed. The development agreement and management contract is subject to approval by the NIGC and is currently in the review process. A consulting agreement with the Jamul Tribe is also under consideration. Construction of the casino could begin in late 2006 with an estimated opening date of the casino 12 months thereafter.
      Under the form of tribal-state compact first signed by the State of California with both the Jamul and Shingle Springs tribes in 1999, each tribe is allowed to operate up to 350 Class III slot machines without licenses from the state. This form of compact allows tribes to operate up to an additional 1,650 Class III slot machines by obtaining licenses for the devices from the state. Under these tribal-state compacts, there is a state-wide limitation on the aggregate number of Class III slot machine licenses that are available to tribes. Certain tribes have entered into new tribal-state compacts or amendments to the 1999 form of tribal-state compact that allow them to operate an unlimited number of Class III slot machines without the need for obtaining additional licenses, subject to the payment of additional fees to the state, including in recent cases, fees based on a percentage of slot “net win.” Currently, neither the Jamul tribe nor the Shingle Springs tribe have amended their tribal-state compacts. If the compacts are not renegotiated and amended the tribes could operate under their existing compacts which allow for up to 350 Class III gaming devices and an unlimited number of Class II gaming devices. This number of gaming devices is adequate to equip the planned developments. Therefore, Lakes believes the availability of additional slot licenses is not an issue that could prevent the projects from progressing. The Jamul project is currently planned to open with 349 Class III slot machines and approximate 1,650 Class II devices.
Pawnee Nation of Oklahoma
Business arrangement:
      In January 2005, Lakes entered into three gaming development and consulting agreements (collectively “Pawnee Development and Consulting Agreements”) and three separate management contracts (collectively “Pawnee Management Contracts”) with three wholly-owned subsidiaries of the Pawnee Tribal Development Corporation (“Pawnee TDC)” referred to collectively as the “Pawnee Nation” in connection with assisting the Pawnee Nation in developing, equipping and managing three separate casino destinations.
      The largest of the casino resort developments will be located on approximately 800 acres of Indian gaming land owned by the Pawnee Nation in northern Oklahoma near the Kansas border. This project is planned to include a large first class casino, hotel and meeting space, multiple restaurants and bar venues, an entertainment and event center, a golf course and various other casino resort amenities. The first phase of the project is planned to include approximately 1,200 gaming devices, 24 table games, a poker room, various restaurants and bars, a 150-room hotel and parking.
      The Pawnee Nation currently operates a “Travel Plaza” at the intersection of U.S. Highway 412 and State Highway 18, approximately 25 miles from Stillwater, Oklahoma. The Pawnee Nation intends to expand the Travel Plaza to include gaming and has engaged Lakes to assist with this project. When expanded, the

49


Table of Contents

planned project will open with approximately 150 gaming devices, four table games, and a full service restaurant and bar.
      As compensation for the performance of its obligations under the management contract for each of these two locations, Lakes shall be entitled to receive a fee of 30% of net income of the respective casino (as defined in the contracts) for a period of five to seven years, depending on the scope of the facilities, less any amounts earned by any Company affiliate for consulting on the two projects. The management contracts are subject to approval of the NIGC and certain other conditions.
      The Pawnee Nation also operates its “Trading Post” Casino, which currently includes approximately 65 gaming devices along with a retail convenience store and gas station in the town of Pawnee, Oklahoma. Lakes will assist in the management of this project and in its expansion if the Pawnee Nation decides to expand the casino. As compensation for its management services on this project, Lakes will receive a management fee of approximately 30% of net income, as defined in the agreement, based on the incremental net income produced at this location during the length of the management contract, expected to be from five to seven years, depending on the scope of the facilities, less any amounts earned by any Company affiliate for consulting on the two projects subject to regulatory approval and certain other conditions.
      Prior to the approval of the Pawnee Management Contracts by the NIGC, Lakes will provide services under the Pawnee Development and Consulting Agreements to each of the three Pawnee casino projects. Under these agreements Lakes will provide advances to the Pawnee Nation, if needed, from time to time to each particular project for preliminary development costs as agreed to by Lakes and the Pawnee Nation. Any advances made will accrue interest at prime plus two percent and be repayable in 24 equal monthly installments beginning on the 25th day following the opening date for the project if the loan has not previously been repaid through the project permanent financing. The Pawnee Development and Consulting Agreements are for 12 years from the effective date of the agreements or until the project development fees and the project preliminary development loans have been fully paid, whichever date is later, subject to early termination. In addition to interest earned on the project preliminary development loan, Lakes will receive a development fixed fee equal to three percent of project costs at each location and a monthly consulting flat fee for each of the three projects of $5,000 for the Trading Post location, $25,000 for the Travel Plaza location and $250,000 for the new casino, per month for 120 months. The above development fixed fees shall be paid on the opening date of each of the projects. No monthly consulting fixed fee is earned or paid prior to the opening date of the project. After the opening date of the project the monthly consulting fixed fee shall be due and paid commencing on the 25th day of the following calendar month and each successive month.
      The Pawnee Development and Consulting Agreements and Pawnee Management Contracts are subject to NIGC review and include provisions for an early buyout of the Pawnee Development and Consulting Agreements and the Pawnee Management Contracts by the Pawnee Nation.
      Arrangement with Consultant. The Company has executed an agreement stipulating that Kevin Kean will be compensated for his consulting services (relating to the Pawnee Nation) rendered to the Company. Under this arrangement, subject to Mr. Kean obtaining certain regulatory approvals, Mr. Kean will receive 20 percent of the Company’s fee compensation, earned under the Pawnee Development and Consulting Agreements and Pawnee Management Contracts with the Pawnee Nation (i.e., six percent of the incremental total net income or 20 percent of the Company’s 30 percent share). This agreement provides that payments will be due to Mr. Kean when the Company is paid by the Pawnee Nation.

50


Table of Contents

Lakes’ Evaluation of the three Pawnee Nation Projects:
      The following table outlines the status of each of the following primary milestones necessary to complete the Pawnee Nation projects as of October 2, 2005:
             
Critical Milestone   New Casino Project   Travel Plaza   Trading Post
             
Federal recognition of the tribe
  Yes   Yes   Yes
Possession of usable land corresponding with needs based on the Company’s project plan
  Yes, the Tribe currently holds land in trust where the new casino will be built.   Yes, the Tribe is currently leasing land from tribal members, which is held in trust for the individual tribal members by the United States Government. The lease will need to be approved by the BIA.   Yes, the Trading Post is currently open.
Usable land placed in trust by Federal government
  Yes, the Tribe currently holds land in trust where the Chilocco Casino will be built.   Yes, the Tribe is currently leasing land from tribal members, which is held in trust for the individual tribal members by the United States Government. The lease will need to be approved by the BIA.   Yes, the Trading Post is currently open.
Usable county agreement, if applicable
  N/A   N/A   N/A
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan
  Yes   Yes   Yes
NIGC approval of management contract in current and desired form
  No, submitted to the NIGC for review on March 22, 2005. An EA will be prepared in order for the management contract to be approved.   No, submitted to the NIGC for review on March 22, 2005. An EA will be prepared in order for the management contract to be approved.   No, submitted to the NIGC for review on March 22, 2005.
Resolution of all litigation and legal obstacles
  None at this time.   None at this time.   None at this time.
Financing for construction
  No, preliminary discussions with lending institutions has occurred.   No, preliminary discussions with lending institutions has occurred.   None needed.

51


Table of Contents

             
Critical Milestone   New Casino Project   Travel Plaza   Trading Post
             
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned
  No others known at this time by Lakes   The acquisition of other tribal land needs to be approved by the BIA.   No others known at this time by Lakes.
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      Long-term assets have been recorded as it is considered probable that the three Pawnee Nation Projects will result in economic benefit to Lakes sufficient to recover Lakes investment. Based upon the above status of all primary milestones and the projected fees to be earned under the consulting agreements and management contracts, no impairment has been recorded. The Pawnee Trading Post is currently open and operating and the refurbishments were completed in the fourth quarter of fiscal 2005. The Pawnee Travel Plaza is currently open and expansion could be completed to include gaming as early as mid 2006. The Pawnee new casino project could open as early as mid 2007.
Iowa Tribe of Oklahoma
Business arrangement:
      On March 15, 2005, the Company, through its wholly-owned subsidiaries, entered into consulting agreements and management contracts with the Iowa Tribe of Oklahoma, a federally recognized Indian Tribe, and The Iowa Tribe of Oklahoma, a federally-chartered corporation (collectively, the “Iowa Tribe”). The agreements are effective as of January 27, 2005. The Company will provide consulting services to assist the Iowa Tribe with two separate casino destinations in Oklahoma including (i) assisting in developing a new first class casino and ancillary amenities and facilities to be located on Indian land approximately 25 miles northeast of Oklahoma City along Route 66 (the “Development Project”); and (ii) assisting with operational efforts at the Iowa Tribe’s existing Cimarron Casino, located in Perkins Oklahoma (the “Cimarron Casino”). The Company will also provide management services for the Tribe’s casino operations at each location subject to regulatory approval.
      Each of the projects has a gaming consulting agreement (“Iowa Consulting Agreement”) and a management contract (“Iowa Management Contract”), independent of the other project. Key terms relating to the agreements for the projects are as follows:
      The Development Project. For its gaming development consulting services under the Iowa Consulting Agreement related to the Development Project, the Company will receive a development fee of two percent of the project costs of the Development Project, paid upon the opening of the Development Project, and a flat monthly fee of $500,000 for a period of 120 months commencing upon the opening of the project.
      The Company has agreed to make advances to the Iowa Tribe, subject to a project budget to be agreed upon by the Company and the Iowa Tribe and certain other conditions. The development loan will be for preliminary development costs under the Development Project budget. The Company has also agreed to use reasonable efforts to assist the Iowa Tribe in obtaining permanent financing for any projects developed under the Iowa Consulting Agreement.
      The Iowa Management Contract for the Development Project is subject to the approval of the NIGC and certain other conditions. For its performance under the Iowa Management Contract, the Company will be entitled to receive management fees of approximately 30% of net income, as defined in the agreement, for each month during the term of the Iowa Management Contract less any amounts earned by any Company affiliate for consulting on the Development Project. The Iowa Management Contract term is seven years from the first day that the Company is able to commence management of the Development Project gaming

52


Table of Contents

operations under all legal and regulatory requirements (the “Commencement Date”), provided that the Iowa Tribe has the right to buy out the remaining term of the Iowa Management Contract after the Development Project has been in continuous operation for 60 months, for an amount based on the then present value of estimated future management fees. If the Iowa Tribe elects to buy-out the contract, all outstanding amounts owed to Lakes become payable if not already paid. Subject to certain conditions, the Company agrees to make advances for the Development Project’s working capital requirements, if needed, during the first six months after the Commencement Date. The advances are to be repaid through an operating note payable from revenues generated by future operations of the Development Project bearing interest at two percent over the prime rate. The Company also agrees to fund any shortfall in certain minimum monthly Development Project payments to the Iowa Tribe by means of non-interest bearing advances under the same operating note.
      Cimarron Casino. The Company has entered into a separate gaming consulting agreement (“Cimarron Consulting Agreement”) and management contract (“Cimarron Management Contract”) with the Iowa Tribe with respect to the Cimarron Casino. Many of the material provisions of these two agreements are similar to those for the Development Project, except that: (i) the Cimarron Consulting Agreement is primarily for services related to the existing operations (with the possibility of further development); (ii) the Company will provide up to a $1 million business improvement loan rather than a preliminary development loan; (iii) the fee under the Cimarron Consulting Agreement will consist entirely of a limited flat monthly fee of $50,000; and (iv) the annual fee under the Cimarron Management Contract will be 30% of net income in excess of $4 million (reduced by any amounts earned by any Company affiliate for consulting services under the Cimarron Consulting Agreement).
      Arrangement with Consultant. The Company has executed an agreement stipulating that Kevin Kean will be compensated for his consulting services (relating to the Iowa Tribe) rendered to the Company. Under this arrangement, subject to Mr. Kean obtaining certain regulatory approvals, Mr. Kean will receive 20 percent of the Company’s fee compensation that is received under the Iowa Consulting Agreement, Cimarron Consulting Agreement, Iowa Management Contract and Cimarron Management Contract with the Iowa Tribe (i.e., six percent of the incremental total net income or 20 percent of the Company’s 30 percent share). This agreement provides that payments will be due to Mr. Kean when the Company is paid by the Iowa Tribe.
Lakes’ Evaluation of the two Iowa Tribe Projects:
      The following table outlines the status of each of the following primary milestones necessary to complete the Iowa Tribe projects as of October 2, 2005:
         
    Development Project   Cimarron Casino
         
Federal recognition of the tribe
  Yes   Yes
Possession of usable land corresponding with needs based on the Company’s project plan
  Yes, the Iowa Tribe is currently leasing and acquiring land from tribal members, which is held in trust for the individual tribal members by the United States Government. These transactions will need to be approved by the BIA.   Yes, currently an open casino.
Usable land placed in trust by Federal government
  Yes, the Iowa Tribe is currently leasing and acquiring land from tribal members, which is held in trust for the individual tribal members by the United States Government. These transactions will need to be approved by the BIA.   Yes, currently an open casino.

53


Table of Contents

         
    Development Project   Cimarron Casino
         
Usable county agreement, if applicable
  N/A   N/A
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan
  Yes   Yes
NIGC approval of management contract in current and desired form
  No, submitted to the NIGC for review on April 22, 2005. An EA will be prepared in order for the management contract to be approved.   No, submitted to the NIGC for review on April 22, 2005.
Resolution of all litigation and legal obstacles
  Yes, the acquisition of other tribal land needs to be approved by the BIA.   No
Financing for construction
  No, preliminary discussions with lending institutions has occurred.   None needed as this is an open casino.
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned
  No others known at this time by Lakes.   No others known at this time by Lakes.
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      Long-term assets have been recorded as it is considered probable that the two Iowa Tribe Projects will result in economic benefit to Lakes sufficient to recover Lakes investment. Based upon the above status of all primary milestones and the projected fees to be earned under the consulting agreements and management contracts, no impairment has been recorded. The Cimarron Casino is currently open and refurbishment of the casino could be completed as early as mid 2006. The Development Project could open as early as mid 2007.
Kickapoo Tribe
      Lakes entered into consulting agreements and management contracts with the Kickapoo Tribe effective January 2005 to improve the performance of the gaming operations conducted at the Kickapoo Tribe’s existing Lucky Eagle Casino in Eagle Pass, Texas, located approximately 140 miles southwest of San Antonio. During the third quarter of fiscal 2005 the Company’s relationship with the Kickapoo Tribe deteriorated and in November 2005, Lakes and the Kickapoo Tribe terminated their business relationship. Lakes recognized an impairment charge of $0.1 million related to the intangible asset related to the acquisition of the management contract during the three months ended October 2, 2005. In addition during the three months ended October 2, 2005, the Company recorded an unrealized loss on notes receivable of $4.1 million related to the Kickapoo project. Included in the $4.1 million are unrealized losses of approximately $3.8 million related to project costs incurred that Lakes may be required to pay as a result of the terminated relationship, and approximately $0.3 million related to advances made by Lakes on the note receivable from the Kickapoo Tribe. During the nine months ended October 2, 2005, the Company recognized unrealized losses on notes receivable of approximately $5.9 million. Included in the $5.9 million are unrealized losses of approximately $5.0 million related to project costs incurred that Lakes may be required to pay as a result of the terminated relationship, and approximately $0.9 million related to advances made by Lakes on the note receivable from the Kickapoo Tribe. As of October 2, 2005, Lakes owns approximately 18 acres of land near the Kickapoo site with a cost basis of approximately $0.7 million. As a result of the terminated business relationship with the Kickapoo Tribe, Lakes intends to negotiate with the Kickapoo Tribe to reach an agreement to resolve all of the financial terms of the contracts including repayment of the advances, payment of unpaid project costs incurred, possible sale of the land owned by Lakes to the Kickapoo Tribe, and to formally terminate the

54


Table of Contents

gaming operations consulting agreement, management contract, and related ancillary agreements relating to the project.
Income Taxes
      The Company accounts for income taxes under the provisions of Statement of Financial Accounting Standards No. 109, Accounting for Income Taxes. Under this method, the Company determines deferred tax assets and liabilities based upon the difference between the financial statement and tax bases of assets and liabilities using enacted tax rates in effect for the year in which the differences are expected to affect taxable income. The tax consequences of most events recognized in the current years consolidated financial statements are included in determining income taxes currently payable. However, because tax laws and financial accounting standards differ in their recognition and measurement of assets, liabilities, equity, revenue, expenses, gains and losses, differences arise between the amount of taxable income and pretax financial income for a year and between the tax bases of assets or liabilities and their reported amounts in the consolidated financial statements.
      Because it is assumed that the reported amounts of assets and liabilities will be recovered and settled, respectively, a difference between the tax basis of an asset or a liability and its reported amount in the balance sheet will result in a taxable or a deductible amount in some future years when the related liabilities are settled or the reported amounts of the assets are recovered, hence giving rise to deferred tax assets and liabilities. The Company must then assess the likelihood that deferred tax assets will be recovered from future taxable income and to the extent management believes that recovery is not likely, they must establish a valuation allowance. The Company has established a valuation allowance against all non-capital deferred income tax assets as of October 2, 2005 and January 2, 2005. The Company has established deferred tax assets related to unrealized investment losses and related carryovers as of October 2, 2005 and January 2, 2005. The Company believes it will have sufficient capital gains in the foreseeable future to utilize these benefits due to significant appreciation in its investment in WPTE. The Company owns approximately 12.5 million shares of WPTE common stock valued at approximately $82.6 million as of December 9, 2005 based upon the closing stock price as reported by Nasdaq on December 9, 2005 of $6.62. Lakes’ basis in the WPTE common stock is minimal.
Common stock subject to repurchase
      WPTE violated certain securities laws in connection with its initial public offering by sending out written email communications to individuals that did not contain all of the information required to be in a prospectus and were not preceded or accompanied by a prospectus meeting the requirements for a prospectus. These violations could require WPTE to repurchase shares sold in the offering to direct recipients of the email communications for a period of up to one year at the offering price plus interest. WPTE sold 75,200 shares in the offering that were subject to such repurchase rights, and these shares were classified as common stock subject to repurchase as of January 2, 2005. As of August 9, 2005, the one-year anniversary of WPTE’s initial public offering, WPTE’s repurchase obligation with respect to such shares expired, and these shares were reclassified as equity in the third quarter of fiscal 2005.
Stock-based compensation:
      We account for equity-based employee compensation under the recognition and measurement principles of Accounting Principles Board (“APB”) Opinion No. 25, Accounting for Stock Issued to Employees and related Interpretations. However, Statement of Financial Accounting Standards No. 123 (revised 2004), Share-Based Payment (SFAS No. 123R) was issued in December 2004 and requires that compensation cost related to share-based employee compensation transactions be recognized in the financial statements. Share-based employee compensation transactions within the scope of SFAS No. 123R include stock options, restricted stock plans, performance-based awards, stock appreciation rights and employee share purchase plans. We have not completed our evaluation or determined the future impact of adopting SFAS No. 123R, which may be material to our results of operations when adopted no later than January 1, 2006. See Note 5 to our unaudited condensed consolidated financial statements included under Item 1 of this Quarterly Report on

55


Table of Contents

Form 10-Q for more information about Lakes’ accounting for compensation expenses, including the pro-forma effects on the periods presented had we applied SFAS 123, Accounting for Stock-Based Compensation.
Recent Accounting Pronouncements
      In December 2004, the FASB issued Statement of Financial Accounting Standards No. 153, “Exchanges of Non-monetary Assets — An Amendment of APB Opinion No. 29, “Accounting for Non-monetary Transactions”. SFAS No. 153 eliminates the exception from fair value measurement for non-monetary exchanges of similar productive assets in paragraph 21(b) of APB Opinion No. 29, and replaces it with an exception for exchanges that do not have commercial substance. SFAS No. 153 is effective for fiscal periods beginning after June 15, 2005, and has not had a material impact on the Company’s financial statements.
      In December 2004, the FASB issued Statement of Financial Accounting Standards No. 123 (revised 2004), Share-Based Payment (SFAS No. 123(R)), which amends FASB Statement No. 123 and supersedes APB Opinion No. 25, Accounting for Stock Issued to Employees, SFAS No. 123(R) requires all companies to measure compensation expense for all share-based payments (including employee stock options) at fair value and recognize the expense over the related service period. Additionally, excess tax benefits, as defined in SFAS No. 123(R), will be recognized as an addition to paid-in capital and will be reclassified from operating cash flows to financing cash flows in the consolidated statements of cash flows. SFAS No. 123(R) will be effective January 1, 2006. We are currently evaluating the effect that SFAS No. 123(R) will have on our financial position, results of operations and operating cash flows.
      In May 2005, the FASB issued SFAS No. 154, Accounting Changes and Error Corrections, a replacement of APB Opinion No. 20 and SFAS No. 3. SFAS No. 154 replaces APB Opinion No. 20, Accounting Changes and SFAS No. 3, Reporting Accounting Changes in Interim Financial Statements and changes the requirement for the accounting for and reporting of a change in accounting principles. SFAS No. 154 applies to all voluntary changes in accounting principles. It also applies to changes required by an accounting pronouncement in the unusual instance that the pronouncement does not include specific transition provisions. When a pronouncement includes specific transition provisions, those provisions should be followed. The provisions of SFAS No. 154 will be effective for accounting changes made in the fiscal year beginning after December 15, 2005. We do not presently expect to enter into any accounting changes in the foreseeable future that would be affected by adopting SFAS No. 154 when it becomes effective.
Seasonality
      The Company believes that the operations of all casinos to be managed by the Company will be affected by seasonal factors, including holidays, weather and travel conditions. WPTE’s license revenues are affected by the timetable for delivery of episodes to TRV.
Regulation and Taxes
      The Company is subject to extensive regulation by state gaming authorities. The Company will also be subject to regulation, which may or may not be similar to current state regulations, by the appropriate authorities in any jurisdiction where it may conduct gaming activities in the future. Changes in applicable laws or regulations could have an adverse effect on the Company.
      The gaming industry represents a significant source of tax revenues. From time to time, various federal legislators and officials have proposed changes in tax law, or in the administration of such law, affecting the gaming industry. It is not possible to determine the likelihood of possible changes in tax law or in the administration of such law. Such changes, if adopted, could have a material adverse effect on the Company’s results of operations and financial results.
Off-Balance Sheet Arrangements
      The Company has no off-balance sheet arrangements that have or are reasonably likely to have a current or future effect on its financial condition, changes in financial condition, revenues or expenses, results of

56


Table of Contents

operations, liquidity, capital expenditures or capital resources that is material to investors, except for the financing commitments previously discussed and except for Lakes’ investments in unconsolidated affiliates.
Private Securities Litigation Reform Act
      The Private Securities Litigation Reform Act of 1995 provides a “safe harbor” for forward-looking statements. Certain information included in this Quarterly Report on Form 10-Q and other materials filed or to be filed by the Company with the Securities and Exchange Commission (as well as information included in oral statements or other written statements made or to be made by the Company) contain statements that are forward-looking, such as plans for future expansion and other business development activities as well as other statements regarding capital spending, financing sources and the effects of regulation (including gaming and tax regulation) and competition.
      Such forward looking information involves important risks and uncertainties that could significantly affect the anticipated results in the future and, accordingly, actual results may differ materially from those expressed in any forward-looking statements made by or on behalf of the Company.
      These risks and uncertainties include, but are not limited to the relisting of Lakes’ common stock on The Nasdaq Stock Market; need for current financing to meet Lakes’ operational and development needs; those relating to the inability to complete or possible delays in completion of Lakes’ casino projects, including various regulatory approvals and numerous other conditions which must be satisfied before completion of these projects; possible termination or adverse modification of management contracts; Lakes operates in a highly competitive industry; possible changes in regulations; reliance on continued positive relationships with Indian tribes and repayment of amounts owed to Lakes by Indian tribes; possible need for future financing to meet Lakes’ expansion goals; risks of entry into new businesses; reliance on Lakes’ management; and the fact that the WPTE shares held by Lakes are currently not liquid assets, and there is no assurance that Lakes will be able to realize value from these holdings equal to the current or future market value of WPTE common stock. Because Lakes’ consolidated results of operations include the results of WPTE operations, Lakes is also subject to risks and uncertainties relating to WPTE that may have a material effect on the Company’s consolidated results of operations or the market value of the WPTE shares held by the Company, including WPTE’s significant dependence on the Travel Channel as a source of revenue; the potential that WPTE’s television programming will fail to maintain a sufficient audience; difficulty of predicting the growth of WPTE’s online casino business, which is a relatively new industry with an increasing number of market entrants; the uncertainty of the regulatory environment for online gaming, which may affect WPTE’s ability to pursue its online gaming business fully or cause WPTE’s activities to be found to be in violation of applicable United States or foreign regulations; the risk that competitors with greater financial resources or marketplace presence might develop television programming that would directly compete with WPTE’s television programming; the risk that WPTE may not be able to protect its entertainment concepts, current and future brands and other intellectual property rights; risks associated with future expansion into new or complementary businesses; the termination or impairment of WPTE’s relationships with key licensing and strategic partners; and WPTE’s dependence on its senior management team. For further information regarding the risks and uncertainties, see the “Business — Risk Factors” section of the Company’s Annual Report on Form 10-K for the fiscal year ended January 2, 2005.
LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Quantitative and Qualitative Disclosures about Market Risk; Controls and Procedures
ITEM 3. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK
      The Company’s financial instruments include cash and cash equivalents and marketable securities. The Company’s main investment objectives are the preservation of investment capital and the maximization of after-tax returns on its investment portfolio. Consequently, the Company invests with only high-credit-quality issuers and limits the amount of credit exposure to any one issuer. The Company does not use derivative instruments for speculative or investment purposes.

57


Table of Contents

      The Company’s cash and cash equivalents are not subject to significant interest rate risk due to the short maturities of these instruments. As of October 2, 2005, the carrying value of the Company’s cash and cash equivalents approximates fair value. The Company also holds short-term investments consisting of marketable debt securities (principally consisting of commercial paper, corporate bonds, and government securities) having a weighted average duration of one year or less. Consequently, such securities are not subject to significant interest rate risk.
      The Company’s primary exposure to market risk associated with changes in interest rates involves the Company’s long-term assets related to Indian casino projects in the form of notes receivable due from its tribal partners for the development and construction of Indian-owned casinos. The loans earn interest based upon a defined reference rate. The floating interest rate will generate more or less interest income if interest rates rise or fall.
      Lakes’ notes receivable from Indian tribes related to properties under development bear interest generally at prime plus one percent or two percent, however, the interest is only payable if the casino is successfully opened and distributable profits are available from casino operations. Lakes records its notes receivable at fair value and subsequent changes in fair value are recorded as income or expense in the Company’s consolidated statement of operations. As of October 2, 2005, Lakes had $77.8 million of notes receivable, at fair value with a floating interest rate (principal amount of $100.4 million, excluding advances to the Kickapoo Tribe). Based on the applicable current reference rates and assuming all other factors remain constant, interest income for a twelve month period would be approximately $8.4 million. A reference rate increase of 100 basis points would result in an increase in interest income of $1.0 million. A 100 basis point decrease in the reference rate would result in a decrease of $1.0 million in interest income over the same twelve-month period.
ITEM 4. CONTROLS AND PROCEDURES
      Under the supervision and with the participation of our management, including our chief executive officer and chief financial officer, we conducted an evaluation of our disclosure controls and procedures, as such term is defined under Rules 13a-15(e) or Rule 15d — 15(e) promulgated under the Securities Exchange Act of 1934, as of the end of the period covered by this quarterly report. Based on their evaluation, our chief executive officer and chief financial officer concluded that Lakes Entertainment, Inc.’s disclosure controls and procedures are effective.
      There have been no significant changes (including corrective actions with regard to significant deficiencies or material weaknesses) in our internal control over financial reporting during the three months ended October 2, 2005 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.
LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Part II
Other Information
ITEM 1. LEGAL PROCEEDINGS
Slot Machine Litigation
      In 1994, William H. Poulos filed a class-action lawsuit in the United States District Court for the Middle District of Florida against various parties, including Lakes’ predecessor, Grand Casinos, and numerous other parties alleged to be casino operators or slot machine manufacturers. This lawsuit was followed by several additional lawsuits of the same nature against the same, as well as additional defendants, all of which were subsequently consolidated into a single class-action pending in the United States District Court for the District of Nevada. Following a court order dismissing all pending pleadings and allowing the plaintiffs to re-file a single complaint, a complaint has been filed containing substantially identical claims, alleging that the defendants fraudulently marketed and operated casino video poker machines and electronic slot machines, and asserting common law fraud and deceit, unjust enrichment and negligent misrepresentation and claims under

58


Table of Contents

the federal Racketeering-Influenced and Corrupt Organizations Act. Various motions were filed by the defendants seeking to have this new complaint dismissed or otherwise limited. In December 1997, the Court, in general, ruled on all motions in favor of the plaintiffs. The plaintiffs then filed a motion seeking class certification and the defendants opposed it. In June 2002, the District Court entered an order denying class certification. On August 10, 2004, the Ninth Circuit Court of Appeals affirmed the District Court’s denial of class certification. On September 14, 2005, the United States District Court for the District of Nevada granted the defendants’ motions for summary judgment, and judgment was entered against the plaintiffs on that same day. The defendants have also filed motions seeking the payment of costs and attorney fees and defendants have until December 28, 2005 to complete their briefing on the motions.
      The Company has not recorded any liability for this matter as currently an estimate of any possible loss cannot be made. Management currently believes the final outcome of this matter is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
Willard Eugene Smith Litigation
      On October 24, 2003, Lakes announced that it had been named as one of a number of defendants in a counterclaim filed in state court in Harris County, Texas by Willard Eugene Smith involving Kean Argovitz Resorts, LLC (KAR) and related persons and entities. In the counterclaim, Smith asserted that, under an alleged oral agreement with Kevin Kean, he is entitled to a percentage of fees to be received by the KAR Entities or their principals relating to the Shingle Springs and Jamul Casinos that Lakes’ subsidiaries are developing in California. Smith also sought recovery of damages through the remedy of either attachment of the management fees generated from the projects or avoidance of buyout agreements between Lakes and KAR based on their conduct with respect to the alleged agreement. Trial for the above litigation commenced in April 2005. In May 2005, the jury in the state court case reached a verdict in favor of Lakes and the other defendants. The jury in the case found that there was no agreement with Smith relating to the ongoing monthly payments or the percentage of management fees. The jury also found that Smith was not entitled to damages. As a result of the verdict against Smith, a second phase of the trial, which would have sought to recover from Lakes any damages awarded, will not be necessary. Smith filed a Motion for a Partial Retrial on the issue of damages which was denied automatically by operation of law. Smith failed to timely file an appeal to the Texas Court of Appeals, so the judgment has become final.
El Dorado County, California Litigation
      On January 3, 2003, El Dorado County filed an action in the Superior Court of the State of California, seeking to prevent the construction of a highway interchange that was approved by a California state agency. The action, which was consolidated with a similar action brought by Voices for Rural Living and others, does not seek relief directly against Lakes. However, the interchange is necessary to permit the construction of a casino to be developed and managed by Lakes through a joint venture. The casino will be owned by the Shingle Springs Tribe. The matter was tried to the court on August 22, 2003. On January 2, 2004, Judge Lloyd G. Connelly, Judge of the Superior Court of the State of California, issued his ruling on the matter denying the petition in all respects except one. As to the one exception, the court sought clarification as to whether the transportation conformity determination used to determine the significance of the air quality impact of the interchange operations considered the impact on attainment of the state ambient air quality standard for ozone. The California Department of Transportation (CalTrans) prepared and filed the clarification addendum sought by the court. Prior to the court’s determination of the adequacy of the clarification, El Dorado County and Voices for Rural Living appealed Judge Connelly’s ruling to the California Court of Appeals on all of the remaining issues.
      A ruling with respect to the addendum was issued June 21, 2004 by the Superior Court of the State of California, County of Sacramento. The ruling indicated that the addendum provided to the court by CalTrans did not provide a quantitative showing to satisfy the court’s earlier request for a clarification on meeting the state ambient ozone standard. The court recognized that the information provided by CalTrans does qualitatively show that the project may comply with the state standard, but concluded that a quantitative analysis is necessary even though the court recognized that the methodology for that analysis “is not readily

59


Table of Contents

apparent”. In addition, the ruling specifically stated, “Moreover, such methodology appears necessary for the CEQA analysis of transportation projects throughout the state, including transportation projects for which respondents (i.e., CalTrans) have approval authority.” CalTrans, the Shingle Springs Tribe and Lakes responded to the court with a revised submission in August 2004. Representatives of the California Air Resources Board and the Sacramento Area Council of Governments filed declarations supporting the revised submission to the court. Opposition to that revised submission was filed, a hearing on the revised submission took place on August 20, 2004 and the court again found the revised submission of CalTrans, the Shingle Springs Tribe and Lakes to be inadequate. That ruling was separately appealed to the California Court of Appeals (the “Court”) and an oral argument for these appeals and the appeals of El Dorado County and Voices of Rural Living was held before the Court on August 29, 2005.
      The Court issued its decision on the appeals on November 8, 2005. The Court ruled in favor of CalTrans’ appeal, rejecting the El Dorado County’s argument that the transportation conformity analysis did not conform to state standards. The Court also rejected all but two of the legal claims asserted in the appeal by El Dorado County and Voices for Rural Living against the environmental impact report (“EIR”) prepared by CalTrans for the interchange that will connect Highway 50 to the Shingle Springs Rancheria. For the remaining two issues, the Court held that CalTrans must supplement its environmental analysis by adding some discussion to the air quality chapter to further explain the project’s contribution to overall vehicular emissions in the region, and that CalTrans also must evaluate whether a smaller casino and hotel would reduce environmental impacts. The Court acknowledged CalTrans lacks jurisdiction to require the Shingle Springs Tribe to develop a smaller casino, but nevertheless required some discussion of this alternative in the interchange EIR.
      The Company has not recorded any liability for this matter as management currently believes that the Court’s rulings will ultimately allow the project to commence. However, there can be no assurance that the final outcome of this matter is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
Grand Casinos, Inc. Litigation
      In connection with the establishment of Lakes as a public corporation on December 31, 1998, via a distribution of its common stock to the shareholders of Grand Casinos, the Company and Grand Casinos entered into an agreement governing the sharing or allocation of tax benefits accruing to Grand Casinos and certain affiliated companies of Grand Casinos. Lakes asserted claims against Grand Casinos for amounts to which Lakes believed it was entitled under the tax sharing agreement. On December 1, 2004, Lakes entered into a settlement agreement with Grand Casinos and its parent company, Park Place Entertainment Corporation (now known as “Caesars Entertainment, Inc.” or “Caesars”), pursuant to which Lakes received $11.3 million in December 2004 in satisfaction of its prior claim and its future rights to the tax benefits that were the subject of the dispute. Lakes will be required to provide reimbursement for its share of the disallowed benefits. This settlement income has been recorded as other income in the consolidated statement of earnings (loss) for the year ended January 2, 2005. Lakes has not recorded any tax related to the settlement payment of $11.3 million, as Lakes believes this settlement is not taxable to Lakes.
Louisiana Department of Revenue Litigation Tax Matter
      The Louisiana Department of Revenue maintains a position that Lakes owes additional Louisiana corporation income tax for the period ended January 3, 1999 and the tax years ended December 31, 1999 through December 31, 2001 and additional Louisiana corporation franchise tax for the tax years ended December 31, 2000 through December 31, 2002. This determination is the result of an audit of Louisiana tax returns filed by Lakes for the tax periods at issue and relates to the reporting of income earned by Lakes in connection with the managing of two Louisiana-based casinos. On December 20, 2004, the Secretary of the Department of Revenue of the State of Louisiana filed a petition to collect taxes in the amount of $8.6 million, excluding interest, against Lakes in the 19th Judicial District Court, East Baton Rouge Parish, Louisiana, Docket No. 527596, Section 23. In the petition to collect taxes the Department of Revenue of the state of Louisiana asserts that additional corporation income tax and corporation franchise tax are due by Lakes for

60


Table of Contents

the taxable periods set forth above. Lakes maintains that it has remitted the proper Louisiana corporation income tax and Louisiana corporation franchise tax for the taxable periods at issue. On February 14, 2005, Lakes filed an answer to the petition to collect taxes asserting all proper defenses and maintaining that no additional taxes are owed and that the petition to collect taxes should be dismissed. Management intends to vigorously contest this action by the Louisiana Department of Revenue. Lakes may be required to pay up to the $8.6 million assessment plus interest if Lakes is not successful in this matter. The Company has recorded a reserve related to this examination, which is reflected as part of income taxes payable on the Company’s consolidated balance sheets.
WPTE litigation with TRV
      On September 19, 2005, WPTE filed suit in the California Superior Court seeking to keep the Travel Channel from interfering with WPTE’s prospective contractual relationship with third party networks in connection with the sale of the broadcast rights to the PPT, and to clarify and enforce WPTE’s rights with respect to the WPT. Under WPTE’s existing agreement with TRV for the World Poker Tour program (the “WPT Agreements”), TRV is afforded the right to negotiate exclusively with WPTE with respect to certain types of programming developed by WPTE during a 60 day period. Pursuant to the WPT Agreements, WPTE submitted the PPT to TRV and began negotiations but failed to reach an agreement with TRV within the allotted negotiation window. Consequently, WPTE began discussions with other networks. While WPTE later revived its attempts to reach a deal with TRV after TRV’s exclusive bargaining window had ended, WPTE ultimately received an offer from ESPN. WPTE submitted this offer to TRV pursuant to TRV’s contractual last right to match the deal as specified under the WPT Agreements. Thereafter, TRV sent letters to WPTE and ESPN asserting, among other things, that WPTE was not entitled to complete a deal for the PPT with a third party. Following TRV’s letters, WPTE filed suit on September 19, 2005, alleging that TRV breached the WPT Agreements and interfered with WPTE’s prospective contractual relationship with ESPN, and seeking a judicial declaration of WPTE’s rights under the WPT Agreements to produce non-World Poker Tour branded programs covering poker tournaments. Subsequent to WPTE filing, ESPN withdrew its offer to WPTE to acquire the broadcast rights to the PPT. On September 22, 2005, TRV and Discovery Communications, Inc. filed an answer and cross-complaint and subsequently filed a motion for judgment on the pleadings and an “anti-SLAPP” motion, both of which were denied on November 10, 2005. Despite WPTE’s dispute with TRV, WPTE remains committed to fulfilling its obligations to TRV in connection with the World Poker Tour series.
Other Litigation
      Lakes and its subsidiaries are involved in various other inquiries, administrative proceedings, and litigation relating to contracts and other matters arising in the normal course of business. While any proceeding or litigation has an element of uncertainty, management currently believes that the final outcome of these matters, including the matters discussed above, is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
ITEM 6. EXHIBITS
         
  31 .1   Certification of CEO pursuant to Securities Exchange Act Rules 13a-15(e) and 15d-15(e) as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002
  31 .2   Certification of CFO pursuant to Securities Exchange Act Rules 13a-15(e) and 15d-15(e) as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002
  32 .1   Certification of Chief Executive Officer and Chief Financial Officer pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002

61


Table of Contents

SIGNATURES
      Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report on Form 10-Q to be signed on its behalf by the undersigned, thereunto duly authorized.
  LAKES ENTERTAINMENT, INC.
  Registrant
 
  /s/ Lyle Berman
 
 
  Lyle Berman
  Chairman of the Board and Chief Executive Officer
 
  /s/ Timothy J. Cope
 
 
  Timothy J. Cope
  President and Chief Financial Officer
Dated: December 16, 2005

62